Loading...
HomeMy WebLinkAboutContracts & Agreements_60-2018PUBLIC WORKS CONSTRUCTION CONTRACT This Public Works Construction contract ("Contract") is made and entered into this 17th day of April, 2018, by and between the City of Redlands, a municipal corporation organized and existing under the laws of the State of California (hereinafter "City"), and Three Peaks Corp (hereinafter "Contractor") City and Contractor are sometimes individually referred to herein as a "Party" and, together, as the "Parties " In consideration of the mutual promises contained herein, City and Contractor agree as follows SCOPE OF WORK Contractor shall furnish all materials and perform all of the work in accordance with the Contract Documents (as herein defined) for City's CITY OF REDLANDS SKATEPARK project 2 THE CONTRACT SUM. City shall pay Contractor the sum of one million twenty nine thousand one hundred fifty one dollars ($1,029,151) as consideration for its performance of the Work in accordance with the terms and conditions set forth in the Contract Documents Pursuant to Public Contract Code Section 22300, Contractor has the option to deposit securities with an escrow agent as a substitute for retention of earnings requirement to be withheld by City pursuant to an escrow agreement as set forth in the Public Contract Code Section 22300 3 TIME FOR COMPLETION- The Work shall be completed within one hundred eighty (180) calendar days from and after the date of the delivery to Contractor of a written Notice to Proceed by City 4 LIQUIDATED DAMAGES Contractor's failure to complete the Work within the time allowed will result in damages being sustained by City Such damages are, and will continue to be, impracticable and extremely difficult to determine Accordingly, Contractor shall pay to City, or have withheld from monies due to Contractor, the sum of five hundred dollars ($500) for each consecutive calendar day in excess of the specified time for completion of the Work Execution of this Contract shall constitute agreement by City and Contractor that five hundred dollars ($500) per day is the estimated damage to City caused by the failure of Contractor to complete the Work within the allowed time Such sum is for liquidated damages and shall not be construed as a penalty, and may be deducted from payments due Contractor if such delay occurs 5 CONTRACT DOCUMENTS The "Contract Documents" include this Contract includes all of the following Documents Notice Inviting Bids, Instructions to Bidders, Contractor's Proposal, Bid Bond, Performance Bond, Labor and Material Bond, Plans, General Conditions, General Requirements, Specifications, and any addenda thereto 6 ATTORNEYS' FEES In the event any action is commenced to enforce or interpret the terms or conditions of the Contract Documents, the prevailing Party in such action, in addition to any costs and other relief, shall be entitled to recover its reasonable attorneys' fees, including fees for use of in-house counsel by a Party 1 1 \ca\dim\Agreements\Three Peaks Corp Contract Final.docx IN WITNESS WHEREOF, the parties hereto have executed this Agreement the day and year first written above (SEAL) City of Redlands By s Paul W Foster Mayor City of Redlands County of San Bernardino, California ATTEST <z�-4 "-,Jfaue� Je e Donaldson, City Clerk ity of Redlands County of San Bernardino, Cahforma (SEAL) Erik W SirrimorJ, President Three Peaks Corp By Signature of Authorized Agent Title Signature of Authorized Agent (if necessary) Title q�&5zb Contractor's License No I \ca\djm\Agreements\Three Peaks Corp Contract Final docx Executed in Duplicate Originals Bond No 379246P Premium $13,79200 PremiuFAITHFUL FUL PERFO . 'LANCE BON Adjustment ;tBases tor onFnvact alr��nactPri �€io Rdiusirneni Based on Finat Contract Price Whcrz.as, t1u, City of Redlands ( City ), State of Califor7iia, and IhmG- Peaks Corporatio,i (het-LinALr dc-gn-mated as (`Principal") hl:ve entered into an at reement dined %pril 1 ? 2018 ( ALrLLi'nLnt ) WhCreby Prins ipal A"at.,',rt l' to in;,L fl and i.oinpletc certain Public imnprw�t-nients (the Wort- ) eih-ch ;aid Agreement is €dent€lied -;s Cit, of Redlands Skatepark and is hereby referred to and made a part heron[ and Whereas, said Principal is required under the terms €ifthe Agreamerii to furnish a bond for the faithful performance of the Agreement, now, therefore we, the Principal and Developess Surely and instemnity Caitiptan� as Surety, are held and firrnl} bound unto the City in the penal sum of One Million Twenty Nine 'thousand One Hundred fifty One Dollars (51,029,151 Oil) lawful money of the United States, for the payment of which scam we bind ourselves, and our heirs, successors, executors and administrator,,;., jointly and severally firmly by these presents The condition of this obligation is such that if the above bounded Principal his or its heirs, executors administrators. successors or assigns, shall in all things stand to and abide by, and «ell and truly keep and perform the covenants, conditions and provisions in the Agreement and any alteration thereof made as thLre;tn provided, on his or its part to be ]refit and performed at the time and in the mariner therein specified, and in all respects according to their true intent and meaning, and shall faithfully fulfill the one-year guarantee of all materials and workmanship and shall defend, indernntfy and save harmless the City and its elected officials, officers, agents and employees. as therein stipulated, there this obligation Shall become hull and void othem ise it shall be and remain in full Force and effect As a part of the obligation secured hereby and in addition to the face amount specified therefor, there shall be included costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligations, all to be taxed its casts and in(.Iuded in the. judgment rLndered As a condition precedent to the satisfactory completion of the Agreement, the above obligation shill hold good for a perked of one (1) year or longer if required by the Agreement after the acceptance of the hark b3 the Cit}, during which time if the Principal shall fail to make full, complete, and satisfactcsr) repair and replaLements and totally protect the. Cii� from loss or damage mad(, evident during this period Froin the date of completion of the Work-, and resulting from or caused by defects ie materials or faulty workmanship, the above obligation in penal sum thereof shall remain in full force and effect The obligations of Surety hereunder shall continue so long as anv obligation of the Principal reniains Whenever the Principal shall be, and is declared by the Cit} to be, in default under the Agreement, the Citt leaving performed the City obligations thereunder, the Surety shall promptly reiiied� the default, or shall promptly, at the City s option Complele the Agreement in accordance with its terms and conditions, or 7 Obtain a laid or bids for completing the Agreement in act ordance with its terms; and conditions, and upon determination b4 Surety of the lowest responsive and responsible bidder, arrange for a contract between such bidder and the City, and marc available as ;work progresses sufficient funds to pay the cost of completion of the Work less the balance of the I Peat•.s Cort; Coilract Fuzat.dd'z lVarc.ement pr€cL but nol �.NCLcdin4 including oth r c-os��, and d mages for ivinich Surety niae be liable hereunder, the tiniount ,et forth above The term `"b.€lane of the Agreemwnt price,` as u,,F d in this par•�i raph shall mean flit, iota§ amount p4�abli, (0 the Principal by tht, Cit% unaCr the Aert.CMLl lit and an% modifR dtfons the-cto, less the amount pre% tousl} properly paid b% the City io ih:. princ..=pol Surt.t) c,,pressl, aorck:s that th:. C its, may reject 3n,� Contractor or subcontractor %% iuch vlaN bc. propnswcl by SUF--tv in futfillment Of its obhi-,aifons it) tht, e%Lnt of default by the Principal Surety shall not utilize the Prtricipal in completing she-grecment nor sliall Surety accept a bid lrom the Principal for cornpli-tion of the Work if the City, when declaring the Principal in default, notifies Surety of the City s objection to tile: Principal s further participation to the completion of the Work No rwht of action small accrue on Elie bond to or for the use of an} person or corporation other than. the Cite named herein or the successors or assigns of the City Any sunt under this bond must be instituted within the applicable statute of limitations period The said Surety, for value received, hc.reby stipulates and agrees that no change, extension of time, alteration of addition to the ternis of the Agreement of to the work to be performed thereunder of the Spt,cifica€ioris aCLo npanying the seine shall in any way affeLl its obligatimis on this bond, and it does hereby %%atye notice of any such change, extension of time, alteration or addition to the terms of the Agreement or to the work or to the specifications No find settlement bC,WC ,r, the City and the Principal shall abridge the right of any beneficiary hereunder whose claim may be unsatisfied The Principal and Surety agree that if the City is required to engage the services of any a€torniry i=t connection -with the enforcement of this bond, each shall pay the City's reasonable attorneys' fct!s incurred, with or without suit, in addition to the above stun In witness wlic .of, this instrument his beenduly executed by the Principal and Surety abo�,e named. 011E 2019 (SEAL) (SEAL) Three Peaks Cor (Contractor) Ergr'g rt�7 m its (Signature) President (Seal and Noiarial Acknowledgement of Surety) I Pears Cnr. Cnnira[t F1M]! ;f-3cr DeveltzparZ&rety and Indemnity Company uretY3 BY Sarah [ s (i ma€tire) . omey to ac Address A4ZMr Blvd Shifa 3flU Telephone ( 714 )784-5660 CALIFORNIA ALL-PURPOSE AC O1 LEDGME T Glvil code § A notary public or other officer Completing this certificate verifies only the identity of the individual who signed the document to which this cer<ificate is attached and not the trutnfulness accuracy or validity of that document STATE OF CALIFORNIA Co,inty of San: Die o On Q I Z01B before me Janice R Martin Dat- In5En ',arnr a' Nmar e-raft€v a, it appon s �)a die oiii-*` >�_s personally appaared Sarah M >'r 'Y r F ;u R'` ut ° z� Gy - JAt�ICE f� te�yyR�tl�t COMM #2158852 0 NOTARY PUBLIC CAlJF RWA 0 SANDIEGOCOUNTY A My Commission t;.xpiies JJLV 29.2020) 1189 Notary Public, who proved to me on the basis of satisfactory evidence to be the person* whose narne(Q isINO subscribed to the within instrument and acknowleaged to me that UN/she ffl# i executed the same in AWFher,'WWauthorized capacity(W, and that by C fk;her/ftV¢ signatureQM on the instrument the person( or the entity upon behalf of which the person(## acted, executed the instrument I certify under PENALTY OF PERJURY under the lags of the State of Calaornia that the foregoing paragraph is true and correct Witness my hand and official sea! Signatu _ ala a Hoch, $e --Anne Signal P.,tii Janice R Martin Though the information below is not required by faw, if may prove valuable to persalts retying on the document and could prevent fraudulent removal and reattachment of the form to another document Description of Attached Document Title or Type of Document Document Date Signerfs) Other Than Named Above Capacity(les) Claimed by Signer(s) Signer's Name Individual Corporate Officer —Title(s) El partner ❑I irriite�! 0 General 21 Atio,ney in Fart E3 Trustee Guardian or Conservaior �,t Other Stgner is Representing Number of Pages Signer's Name ❑ Individual (] Corporate Officer—rtie(s) 0 Partner ❑ Limited ❑General ❑ Attorney in Fact ❑ Trustee n Guard.an or Conservator [] Other S;finer is Representing POWER OF A170FZNEY FOR OE VELOPERS SURETY AND INDEMNITY COMPANY INDEMNITY COMPANY OF CALIFORNIA PO Box t9775 IRVINE, CA- 926-M J949) 2513M KNOW ALL W Tt;ESE PRESENT1 S that :x .apt as expressk hnutead DEVELOPERS SLREi Y AND INDEM.14i M51Ah'Y ad INDEMNITY COMPANY OF CA: IFi)RN1k do each hereby make mmfitula and appa.nt Lawrence F Mc Maharn, Sarah Myers, jointly or severally`.. as that: he and to rrake, execute de&cf and zci�;,k* lar and on b0atl of said mrporati=. as surati m lard. mdsr11k1rqs and aortra� at sarryshr 9-V acrd gran'uN unix sal d Atte }(s) -in -Fact ka Pmer 1-1d authority to do and t3 riarn every act necsssay, regjrshe or pupef to be dons in =Mein the rewdh a$ each of sald corparatfims =0 de but resa mrrg to each o! saida+k.ss 10 PoNer of substitution and mv=hM and allot i~ a acts of said Attomey{sHn-Fact pn- uant lodress- pesens are hereby ra0bed aad cw*med This Povm of Allw ay Is gran''Bd and 1s sbnetd by facsimle under and by aulTat of the fokwing rgscsutkns ad*, -d by of DIM, -'ors of D-�VEt.4FEZRa" SURETY ANSI WO=lt FI Y COMPANY and 1NDs W ITY COk PAW OF CALIFO;INIA agactve as of January 1 st, 2ik13 RESO�.Yci}, Llal a camb4riatlon of any two: of the CF,almmn of the Board f3uR RmsidmI. E= -A -m Vrce•Fresident Seng Vice-PmIdem or Ary Vaa PresIden! of &a rzrperatiom be, ano that eaw of chert hereby is, aursrarlted to eXOMta the Pumf olAtiorney qualifying the atratr- (a) Warned it taw Payer of Altorrnay to gxecuie on bahaii or tits corpora)" b=15 underakvrgs and mnhaCs of sarei}strip and tt•.a+ the 5ecre€ary a ar-gA.ss1Wnl Semtary at eitherof the cormrat= be aril each of tfrern Iteraby Es, autnonaed bat5asl the momtkrn cf any stsh Pomr of Atto,Tey RESOLVED, FLIRT -HER that bre sutures of such officers fray tie afiued to any3ucb Pier o!Allomay or to anp cedi5mte relafing tirereto by fartroa, and aly suctt PomerafAwmay ex cee urate beanng srrch far -arils signatures shag be vasa and binding upon the corparatloas when so affixed and In the future Wh raspad to any bond, unde€ta Ln arcontract aT sUrBlpship to WP It rig shachad IN 1? "MESS WI-T;REGF, DEVELOPERS SURETY AND WDE-EMNriY CWPAW and L'dDEMNI Y C©tAPANY OF CALTFORWA have sevmrry utrsed three ins to tee Signal try !heir respsctvenfucarsand alasto-dby#LeIrraspa—ZWOSecratayorAssistart5ecmtaryovs%day of February 2017 s•,irr ;3y- � q•r AND Oarr;eTYtrrrng SarrlsrVuePreskienl � � a� ��s� � pF� � . 1935 ?�r� OCT s "® By uk iseT Mark La�='- Presidzrt ';�'73�4 r€»r �' r' c-alrrpp+'�P� A Watery ptrblrc ar other afcer campteirng this card Kate vet€rises only the ldenilly of the Individual vaho signed the datum nE to which this ceriI11=19 Is attached and not the truthfulness, accuracy, ar vah6ty of that document Stale of cawcrrrg county of Orange on abapkii,2017 Ware the Luclil Ravrrxrn ttol P brc ala We Inam F&M vdTtu d uW oaci r personally appeared Daniel Yamq and Hart l gnsdon Iesffifa) d SrgSstzl I'h11iT. � E Pfau Notary Steal Above %110 pmved to me an the basis of satWactory evd t-= to be the p=:rs*s) whose names) Is.'are sutmrbed to OrtwitfkIn Irstnrrnsni and ac#.novrtedged io tri that hefsheltl>wy executed the same n Whe their atsfted capadty{Iss) and ffrat by hWharOzIr s�nafumjs) on the iratrumeni the persofs) or fhe Enu'iy upon behaN iJ w; Joh the per N5) Bd-Ad extc:rted the imIq=m •,' I certly underPENA?.TY OF PERJURY undea tura lavas of the Stateal Ca5famra that the romong paragraph Is true and cara=t. WFtMESS rnyhand and ofr4al seal SkInature Lucdt Fara d N0iary Pubk CERTIFICATP v The undff srned as Seautary o. As-sm1ant Sarxs'rary of DEVELOr ERS SURETY AND INDEhtttfTY CWAPANY orfM ENINITY COMPANY OF CALJ;O N A, dot=s hereby M-,Vy that the fcrgoinq Pcww a[Allmey ramWaz frit trial fora and has rwi bwA revoked anti furthe=rs- fhai Cee proves ons rt refs- resp utretts at respective Boards ai ihreclrrrs ct safd mrpcva9ens set WrM bt ttrs Poftf ar`Altoeneey are fa fore as of the date cI this Certir=F-4 •,frill fir„ Thr s Cort ricale s exscutead In the Clry of Imne C�tarnfa, Ws 1St day 0 May 2418 .,.'' z't AS rna , ��ylPAtdp � Ely Cask ! Word Asgsbnt5ry . a: Fo lu rsSv , a r RTS -1002 [WJ17) ° r ! Executed Duplicate 4nginals Band No 379246P Premium is Included in Performance Bond k�-hereas the City Council of the Citi of Redlands State of California. and Tlinue Peaks Corporation (herLinaPk-r designated as "Principal ') have entered into an agreement (the `Agreement ) whereby Principal agrees to install and complete certain designated public irnpros-cments (the `Work"), %,� hick said agreement, dated April 17. 2018, and identi Red as City of Redlands Skatepark is hereby referred to and made a part hereof, and Whereas, tinder the terries of the Agreement, Principal is required before cornir►cnding the performance of the Worl,, to file a good and sufficient Labor and Matenal bored with the City of Redlands to secure the claims to "hie h reference is made in Title 3 (commencing with Section 9550) of Part Ca of Diviston 4 of the Civil Code of the State of Calitornia Now, therefore, said Principal and the undersigned as corporate surety are held firmly bound unto the City and all contractors, subcontractors, laborers, material meat and outer persons employed in the performance of the Agreement and referred to to the aforesaid Code of Civil PrOLedure in the sum of One Million Twenty Nine Thousand One Hundred Fifty One Dollars (S 3,029, 151 00) for materials furnished or labor thereon of any Lind or for amounts due gander the Unemployment Insurance Act with respect to such wort: or labor, that said surety will pay the same; Lit an amount not exceeding the ainount hereinabo%e set forth and also in case suit is brought upon this band. will pay, in addition to the face amount thereof, costs and reasonable expenses and fees_ including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligation, to be m4 and fixed b) the court and to be taxed as costs and to be included in the judgment theruin rendered It is hereby expressly stipulated and agreed that this bond shall insure to the benefit of any and all persons, companies and corporations entitled to file claims under Title 3 (commencing with Section 9550) of Fart 6 of Di% €stop 4 of the Cis it Code, so as to give a right of a.tiori to them or their assigns in any suit brought upon this bored Should the condition of this bond be fully performed, then this obligation shall become null and void, otherwise it shall be and remain in full force and effect The suretw hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or the specifications accompanying the same shall in any manner affect its obligations on this bond, and it sloes hereby waive notice of any such change, extension of time, alteration or addition t tsa%tiim\Agreements -Nwee Peaks Corp Contm-t =ina! eac$ In %1 i[ cq. �lt.rwf thi, rosin umm2w h v; the un duly c-\LCU[Ld 17, [bu Pr€tt ip d €od ab t r��€tt�ect, (In Ma.y 1 , 2018 (SEAL) Thrge PeaksCorr), Erik Simr arcs r (Signature) President (Sea! and Notanal Ackn€ v ledge€nem of Surety 1 jca`djm%A.gree-nent$\7mreC- Pea U. Corp Contract F=na€.docs (SEAL) Dzegvefo ers Sure and Indemnity Cam art (S retY) BY Sarahyarn (5 ; tore} Attorney-€n-Facl Address 5 121 _._... Telephone ( 714 ) 784-5afi0 A notary public or other Officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached and not the truthfulness, accuracy or validity of that document STATE OG CALIFORNIA County of San Die a Can MAY 0 12018 oe€are me, Janice R Martin Date _...... ` blur` Nwm� 01 ivu,ary Exal?iv as it a:)Pears ^I to otficlat sr -al , Notary Pubiic. personally appeared Sarah tvlyers — �___ — s`i8rttrrsE C%t Ssi€n.5€eS{ • JANICE R MARTIN' COMMI #2159852 e# in Cry NOTARY PUBLIC CALIFORNIA C,g SAN OtEGO COUNTY my com"Sslort aplres JULY 29 2020 who proved to me on the bests of satisfactory evidence to be the personal, whose name(ggh isle subscribed to the within instrument ar-d acknowledged to me that UdishetflYy executed the same in Aidlherlffft authorized capacityftM, and that by 1110herifflhIN signaturei#'I an the instrument the personN, or the entity uL= behalf of which the person(4b acted, executed the instrument I certify under PENALTY OF PERJURY under the !aws of the State of California that the foregoing paragraph is true and correct Witness my hand and official seal Signa _. Pia- e Wn?ar j 5ca' Ar--,-,, 5 gas! . e of :rntary Pvn^ i- Janice R Martin OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document Description of Attached Document Title or Type of Document Document Gate S,gner(s) Other Than Named Above Capacity(ies) Claimed by Signer(s) Signer's Name Individual Corporate Orficer—Title(s) — ❑ Partrer ❑Limited ❑ General 9 Attorney in Fact ❑ Trustee Guardian or Corlservalor ❑ Other Signer .s Represenono Number of Pages Signer's Name ❑ Individual [] Corporate Officer —Title(s) ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guarcian or Conservator F-1 Other signer is Representing POWER OF ATTORNEY FOR DEVELOPERS SURETY AND INDEMNITY COMPANY 114DEMMWY COMPANY Or CALIFORNIA PC Boz 19725, IRVINE CA 92M (449) 263.3100 fttdDW AL BY THESE PRESENTS Ihai except as exp,-.ssly ]MIed, DEVELOPERS SURE Y ANO [NDEh1Nf-iY t;C1h".PANY and IN0.cMN1iY CCk%APAfN OF CALIFOMLk do ea�h hSsetry make an 6wW and appoint —Lawrence F Nic Mahon, Sarah Myhre jointly or severally* a: Lha: true end la*lul#1ttmy(s)•6FFz-l. to rnake exectde &Fmu ar-dackno le�* ler and on behalf of said mrpratiors as surebas bands urdadalrn;s and con. -ads of. suretyshtpgw tg anli granurtg unb sald Amro (spr Fact N! mer aro autha* to do and la periar n avary a:� ne;,essaq rEquislta of pDW to b� louse to cnn2r, tion therewith as eat ai sahi Car tai is x da, but rEser rx; to Harp or said t a paratkans fullpier of sty rlutsan sntf tEvxaU r and all of the guzuant IC U preset, are hereby mHed and rmfaned. Ties Power 01AHMar Is g.•anled and il signed 4 fass110e iirtder and by Out# of the foGtrvnrtg rasa utters adapted try the respective 6aanl5 of lymi ta's of OEVELOPERS SURE Y ANI) h" V-WIITYCCX PAFIY a .d ll,'DEf N[i-Y taONIPAW OF CALIFORNIA. elfeMe as of fanuary 1st 2Wa AES434Wt9D, that a carn1r; alron or any Mo of the CPahrran eat Me Boar,, the Fms�denL Executive Vr=-Prasideni Sen*x 1%cLPmIdenl or any Va Pmldenr of the t am[we be, and that each or ttie n hereby 4 eufnarized to execute hs Pmt er orAttonvsy, quzUft thS attorney(s) narned in Me Pawet cJAtPGmey b axecWa on be a9 tri L•ne czqxraIbas widertakinp and contracts of suretyship, am that he Secraary cr airy Assistant Secretur of either of the caTarat[= bs, and each or them namby is, outnonzad to ahest the exetzrtioo of any stxh Pater of Atiomay FEESDLV:D, FURTER, that Via a nalures of suoh ol(rers may be aguad to any such Payer of AII&TOy V. to any eer Acata relating t,'tareto by tatsun:ta, and any such PoNerolA'+wnoy Pr catlicale boating suets laeSUrale slgralum Shall be valid and biniFirg upm the Corpa:atrons when so aUized and in the futurevrith rezpact to any bond urxfertaktig or con!ract of Surelyshlp to wficzzh U b erachad IN YwTNESS WHEREW, D-n-tLOFERS SUIT.M AHD INDEl, Mf COMFPkW and [NO=-kt14 TY COMPANY OF £AUFORPM have sommTy caused 6tese presents to be sk ned by their mTactve oiUw+z and at€asted by httr rasa Setnotary orA&s1shnt Sezary th�s 6th day of February 2017 A notary public or other officer compleling this carUficate ver7es only the idenlity of the inaivtdual who slgnild the document to which this cerliCrcale is attached and not the truthfulness, accurarcy, ar validity of that document state of cartf*rna County, of Prange {h Febnwary g. 2017 betare rna---..................._.-- --- L x nt Ravin , fbtary i�uyc petsonallyappeared Denial Koung and Warki.ansdan LUCILLE RA ISD CotnmlSslert 20al9 s -or Notary Fa"C catlirlmla orange Courtly M Gtlmm. EXDirat DC1=1 Pian Plotary SoalAlaove who prsaed b nta on the basis of sat!sfaclmy evidence to be the person(s) wrhosa narrw(s) islare subvcnsed to tha Within instrument aM ackn€ wLN� to n Mt ha;sbtrillny exLcilad the sauna n h4lberlLh authoriaed capaaiy(fes), and that W h4rhuftheir s�natrze(s) on the ti-zh mens the p-=an(s) or 1:e entity upon behat' or wtdch the persons) octad executed the Instament I certify under PENAL Y OF PERJURY under the laws of the Stale or Ca;i1w9a that Via tareptq paragraph Is true and maect. t'+'f TIYESS my nand and offrdaf sear �alura tuctojhmd Hiavy Pum CERTIFICATE Site undrrsk}r as SeMtary a ASsislant Secretary of DEVELOPERS SUREW AND IN"BE M Y GV-PA`tY or INDEMNITY COMPANY OF CAL1FORHA, does heraby eerily that the iaregoing Power of Attorney remarm in ftdf forca and bas not been revoked W furthenroTe that the pr lons of the resdu w.5 of the respecf€+e 9aarHs of C)rre=rs of said rorpcMons Set lorth In Ilm Power olAttnrrtey aro in force as of the dale of this Ced5cafe Tiffs Car€if[rats is executed In the city or Inane CzlikrnWa, this 1 s( day of May 2018utorq'`�- d4g11 AEd?o `�34��:•"�pµ�"t^� tet••- BGG Sia GFj,����9' EY z( iU w Cassiad rrkstard,hs9Dhnt5 Lary ;cS' p rs•s= x. AES -1{l02 (S+CIt lF) ,,'iiiiill�jl!\y�' '� 1 if ll,ill By _ ` �!'tgayn�ra R �,ykS�Atdkp� Dan�elYo:urg Ses�arV',�Priont � _. �}L��; AL1 ; ;z 19 T 5 qC° a BY `liilll�l41,140 A notary public or other officer compleling this carUficate ver7es only the idenlity of the inaivtdual who slgnild the document to which this cerliCrcale is attached and not the truthfulness, accurarcy, ar validity of that document state of cartf*rna County, of Prange {h Febnwary g. 2017 betare rna---..................._.-- --- L x nt Ravin , fbtary i�uyc petsonallyappeared Denial Koung and Warki.ansdan LUCILLE RA ISD CotnmlSslert 20al9 s -or Notary Fa"C catlirlmla orange Courtly M Gtlmm. EXDirat DC1=1 Pian Plotary SoalAlaove who prsaed b nta on the basis of sat!sfaclmy evidence to be the person(s) wrhosa narrw(s) islare subvcnsed to tha Within instrument aM ackn€ wLN� to n Mt ha;sbtrillny exLcilad the sauna n h4lberlLh authoriaed capaaiy(fes), and that W h4rhuftheir s�natrze(s) on the ti-zh mens the p-=an(s) or 1:e entity upon behat' or wtdch the persons) octad executed the Instament I certify under PENAL Y OF PERJURY under the laws of the Stale or Ca;i1w9a that Via tareptq paragraph Is true and maect. t'+'f TIYESS my nand and offrdaf sear �alura tuctojhmd Hiavy Pum CERTIFICATE Site undrrsk}r as SeMtary a ASsislant Secretary of DEVELOPERS SUREW AND IN"BE M Y GV-PA`tY or INDEMNITY COMPANY OF CAL1FORHA, does heraby eerily that the iaregoing Power of Attorney remarm in ftdf forca and bas not been revoked W furthenroTe that the pr lons of the resdu w.5 of the respecf€+e 9aarHs of C)rre=rs of said rorpcMons Set lorth In Ilm Power olAttnrrtey aro in force as of the dale of this Ced5cafe Tiffs Car€if[rats is executed In the city or Inane CzlikrnWa, this 1 s( day of May 2018utorq'`�- d4g11 AEd?o `�34��:•"�pµ�"t^� tet••- BGG Sia GFj,����9' EY z( iU w Cassiad rrkstard,hs9Dhnt5 Lary ;cS' p rs•s= x. AES -1{l02 (S+CIt lF) ,,'iiiiill�jl!\y�' '�