HomeMy WebLinkAboutContracts & Agreements_180-2018 PUBLIC WORK CONSTRUCTION CONTRACT
This Public Work Construction contract ("Contract") is made and entered into this 18th day of
September,2018, by and between the City of Redlands,a municipal corporation, organized and existing
under the laws of the State of California (hereinafter "City"), and R Dependable Construction, Inc.,
hereinafter("Contractor"). City and Contractor are sometimes individually referred to herein as a"Party"
and, together, as the "Parties."
In consideration of the mutual promises contained herein, City and Contractor agree as follows:
I. SCOPE OF WORK: Contractor shall furnish all labor and will perform all of the work for the
following: Interior reconstruction of the Carriage House to include drywall, baseboards, flooring,
painting, misc. fixture installations and insulation, by the Contract Documents (as herein defined)
and Specifications for City's CARRIAGE HOUSE INTERIOR RECONSTRUCTION PROJECT
Q0L070920 18KG (the "Work").
2. CONTRACT SUM: City shall pay Contractor the sum of Sixty Thousand One Hundred Thirty
Three Dollars and Seventy Five Cents(560,1 33.75)as consideration for its performance of the Work
in accordance with the terms and conditions set forth in the Contract Documents. Pursuant to Public
Contract Code Section 22300, Contractor has the option to deposit securities with an escrow agent
as a substitute for retention of earnings required to be withheld by City pursuant to an escrow
agreement as set forth in Public Contract Code section 22300,
3. TIME FOR COMPLETION: The Work shall be completed within Forty Five (45)calendar days
from and after the date of the delivery to Contractor of the Notice to Proceed by City.
4. LIQUIDATED DAMAGES: Contractor's failure to complete the Work within the time allowed
will result in damages being sustained by City. Such damages are, and will continue to be,
impracticable and extremely difficult to determine. Accordingly, Contractor shall pay to City, or
have withheld from monies due to Contractor, the sum of Five Hundred Dollars ($500) for each
consecutive calendar day in excess of the specified time for completion of the work.
Execution of this Contract shall constitute agreement by City and Contractor that Five Hundred
Dollars ($500) per day is the estimated damage to City caused by the failure of the Contractor to
complete the work within the allowed time. Such sum is liquidated damages and shall not be
construed as a penalty,and may be deducted from payments due the Contractor if such delay occurs.
5. CONTRACT DOCUMENTS: This Contract incorporates by reference the following: Notice
Inviting Bids, Instructions to Bidders, Contractor's Proposal, Bid Bond, Plans, General Conditions,
Special Provisions and Specifications, and any addenda thereto (collectively the "Contract
Documents").
6. ATTORNEYS' FEES: In the event any legal action is commenced to enforce or interpret the terms
or conditions of the Contract Documents, the prevailing Party in such action, in addition to any costs
and other relief, shall be entitled to recover its reasonable attorneys' fees, including fees for use of
in-house counsel by a Party.
7. RESOLUTION OF CONSTRUCTION CLAIMS: Any claims by Contractor in the amount of
Three Hundred Seventy Five Thousand Dollars($375,000)or less shall he made by Contractor and
f:'.ca'c3.jni.Agreernents'PW Contract Carriage Hous4.docx ORIGINAL
processed by the City pursuant to the provisions of Part 3, Chapter 1, Article 1.5 of the Public
Contracts Code (commencing. with Section 20104). All claims shall be in writing and include the
documents necessary to substantiate the claim. Nothing in Public Contracts Code Section 201.04.2
shall extend the time limit or supersede the notice requirements provided for the filing of claims by
Contractor.
8. ELIGIBILITY OF CONTRACTOR/SUBCONTRACTOR: Contractor and all of its
subcontractors shall abide by Public Contract Code Section 6109 and Labor Code sections 1777.1
an.dior 1777.7, and certify that they are not debarred and are eligible to perform the Work.
9, ASSIGNMENT OF AGREEMENT: No assignment by Contractor of any rights or interests under
this Contract shall be binding on the City without the prior written consent of the City.
10. SUCCESSORS AND ASSIGNS: City and Contractor each binds itself and their respective
successors and assigns in respect to all covenants, agreements, and obligations contained in the
Contract Documents.
11.. SEVERABILITY: Any provision or part of the Contract Documents held to be void or
unenforceable under any law or regulation shall be deemed stricken, and all remaining provisions
shall continue to be valid and binding upon City and Contractor.
f:'ca,djn Agreemecits'PW Contract Carriage House.docx
IN WITNESS WHEREOF, the Parties hereto have executed this Contract the day and year first written
above.
City afRedlands
(SEAL)
(1$21::
Paul Foster, Mayor
ATTEST: pfaster acityofredlands.org
J ne Donaldson, City Clerk
,ldonaldson(acityofrediands.org
(SEAL)
ROSEMARY PADILLA
R Dependable Construction, lnc.
Bv:
Signature of Authorized er t
PRESIDENT
Title
Signature of Authorized Agent(if necessary)
Title
944088
Contractor's License No.
3
I:'ca'djm.Agrecrnents'.PW Contract Carriage House.docx
WORKER'S COMPENSATION INSURANCE CERTIFICATION
Description of Contract: Carriage House Interior Reconstruction-QOL07052018KG
Every employer, except the State, shall secure the payment of compensation in one or more of the
following ways:
a. By being insured against liability to pay compensation by one or more insurers duly
authorized to write compensation insurance in this State.
b. By securing from the Director of Industrial Relations, a certificate of consent to self-
insure, either as an individual employer, or as one employer in a group of employers,
which may be given upon furnishing proof satisfactory to the Director of Industrial
Relations of ability to self-insure and to pay any compensation that may become due
to his or her employees.
CHECK ONE
X I am aware of the provisions of Section 3700 of the Labor Code which requires every employer
to be insured against liability for Workers' Compensation or to undertake self-insurance in
accordance with the provisions of that Code, and I will comply with such provisions before
commencing the performance of the work and activities required or permitted under this Agreement.
(Labor Code §1861).
I. affirm that at all times, in performing the work and activities required or permitted under this
Agreement, 1 shall not employ any person in any manner such that I become subject to the workers'
compensation laws of California. However, at any time, if I employ any person such that I become
subject to the workers' compensation laws of California, immediately I shall provide the City with a
certificate of consent to self-insure, or a certification of workers' compensation insurance.
I certify under penalty of perjury under the laws of the State of California that the information and
representations made in this certificate are true and correct.
Dated this 6 day ofSEPTEMBER20I8.
R DEPENDABLE CONST
(Contractor)
(Signature)
PRESIDENT
(Official Title)
(SEAL)
(Labor Code Section 186I provides that the above certificate must be signed and filed by the Contractor with the
Owner prior to performing the work of the contract.)
4
I:Ica\djm\Agreements\PW Contract Carriage House.docx
Bond#SXACSU 0728800
Premium: $1503.00
FAITHFUL PERFORMANCE BOND
Whereas, the City of Redlands ("City"), State of California, and * (hereinafter designated as
"Principal")have entered into an agreement dated** ,2018("Agreement")whereby Principal agrees to install and complete
certain public improvements (the"Work"),which said Agreement is identified as and
is hereby referred to and made a part hereof;and CARRIAGE HOUSE INTERIOR RECONSTRUCTION PROJECT Q0L07092018KG
Whereas,said Principal is required under the terms of the Agreement to furnish a bond for the faithful performance of •
the Agreement,now,therefore,we,the Principal and Allegheny Casualty company as Surety,are held and firmly bound unto
the City in the penal sum of *"`* Dollars($ 60,133.75 )lawful money of the United
States,for the payment of which sum we bind ourselves, and our heirs, successors, executors and administrators,jointly and
severally,firmly by these presents,
The condition of this obligation is such that if the above bounded Principal, his or its heirs, executors,administrators,
successors or assigns,shall in all things stand to and abide by, and well and truly keep and perform the covenants,conditions
and provisions in the Agreement and any alteration thereof made as therein provided,on his or its part,to be kept and performed
at the time and in the manner therein specified, and in all respects according to their true intent and meaning,and shall faithfully
fulfill the one-year guarantee of all materials and workmanship,and shall defend,indemnify and save harmless the City and its
elected officials,officers,agents and employees,as therein stipulated,then this obligation shall become null and void;otherwise
it shall be and remain in full force and effect.
As a part of the obligation secured hereby and in addition to the face amount specified therefor,there shall be included
costs and reasonable expenses and fees, including reasonable attorneys'fees, incurred by the City in successfully enforcing
such obligations,all to be taxed as costs and included in the judgment rendered.
As a condition precedent to the satisfactory completion of the Agreement,the above obligation shall hold good for a
period of one(1)year or longer if required by the Agreement after the acceptance of the work by the City,during which time if the
Principal shall fail to make full, complete, and satisfactory repair and replacements and totally protect the City from loss or
damage made evident during this period from the date of completion of the Work, and resulting from or caused by defective
materials or faulty workmanship,the above obligation in penal sum thereof shall remain in full force and effect.
The obligations of Surety hereunder shall continue so long as any obligation of the Principal remains.
Whenever the Principal shall be, and is declared by the City to be, in default under the Agreement,the City having
performed the City obligations thereunder,the Surety shall promptly remedy the default,or shall promptly,at the City's option
1. Complete the Agreement in accordance with its terms and conditions;or
2. Obtain a bid or bids for completing the Agreement in accordance with its terms and conditions,and upon determination
by Surety of the lowest responsive and responsible bidder,arrange for a contract between such bidder and the City,and make
available as work progresses sufficient funds to pay the cost of completion of the Work less the balance of the Agreement price,
but not exceeding,including other costs and damages for which Surety may be table hereunder,the amount set forth above.
The term"balance of the Agreement price," as used in this paragraph,shall mean the total amount payable to the Principal by
the City under the Agreement and any modifications thereto,less the amount previously properly paid by the City to the Principal,
Surety expressly agrees that the City may reject any contractor or subcontractor which may be proposed by Surety in
fulfillment of its obligations in the event of default by the Principal.
* R Dependable Construction, Inc.
*`September 18th
*** Sixty Thousand One Hundred Thirty-Three and 75/100
CD-4
Q0L07092078KG—Carriage House Interior Reconstruction ORIGINAL
Surety shall not utilize the Principal in completing the Agreement nor shall Surety accept a bid from the Principal for
completion of the Work if the City,when declaring the Principal in default, notifies Surety of the City's objection to the Principal's
further participation in the completion of the Work.
No right of action shall accrue on the bond to or for the use of any person or corporation other than the City named
herein or the successors or assigns of the City. Any suit under this bond must be instituted within the applicable statute of
limitations period.
The said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or
addition to the terms of the agreement or to the work to be performed thereunder or the Specifications accompanying the same
shall in any way affect its obligations en this bond, and it does hereby waive notice of any such change, extension of time,
alteration or addition to the terms of the agreement or to the work or to the specifications.
No final settlement between the City and the Principal shall abridge the right of any beneficiary hereunder whose claim
may be unsatisfied.
The Principal and Surety agree that if the City is required to engage the services of any attorney in connection with the
enforcement of this bond, each shall pay the City's reasonable attorneys'fees incurred, with or without suit, in addition to the
above sun.
The Surety hereby stipulates and agrees that no change, extension of time alteration or addition to the terms of the
Agreement or to the Work to be performed thereunder or the specifications accompanying the same shall in any way affect its
obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the
terms of the agreement or to the work or to the specifications.
In witness whereof, this instrument has been duly executed by the Principal and Surety above named, on
September 6th,2018.
(SEAL) (SEAL)
R Dependable Construction, Inc. Alle heny Casualty Company
(Contractor) (Sure
BY:
( ' ) ignature) Kyle T. Baker,Attorney-in-Fact
Rosemary Ella resident Address: 2400 E. Katella Ave#250
(Seal and Notarial Acknowledgement of Surety) Anaheim, CA 92806
Telephone: (714)602-9170 (Surety)
951-553-7400 (Agent)
•
CD-5
CQOL0709201 eKG—Carriage House interior Reconstruction
POWER OF ATTORNEY Bond# SXACSU 0728800
INTERNATIONAL FIDELITY INSURANCE COMPANY
ALLEGHENY CASUALTY COMPANY
One Newark Center,20'h Floor,Newark,New Jersey 07102-5207 PHONE:(973)624-7200
KNOW ALL MEN BY THESE PRESENTS: That INTERNATIONAL FIDELITY INSURANCE COMPANY,a corporation organized and existing under the
laws of the State of New Jersey, and ALLEGHENY CASUALTY COMPANY a corporation organized and existing under the laws of the State of New
Jersey,having their principal office in the City of Newark,New Jersey,do hereby constitute and appoint
TIMOTHY C. BAKER, KAREN A. EBY, KYLE T. BAKER.
Murrietta, CA.
their true and lawful attorney(s)-in-fact to execute, seal and deliver for and on its behalf as surety, any and all bonds and undertakings, contracts of
indemnity and other writings obligatory in the nature thereof,which are or may be allowed,required or permitted by law,statute,rule,regulation,contract
or otherwise, and the execution of such instrument(s) in pursuance of these presents, shall be as binding upon the said INTERNATIONAL FIDELITY
INSURANCE COMPANY and ALLEGHENY CASUALTY COMPANY, as fully and amply, to all intents and purposes, as if the same had been duly
executed and acknowledged by their regularly elected officers at their principal offices.
This Power of Attorney is executed, and may be revoked, pursuant to and by authority of the By-Laws of INTERNATIONAL FIDELITY INSURANCE
COMPANY and ALLEGHENY CASUALTY COMPANY and is granted under and by authority of the following resolution adopted by the Board of
Directors of INTERNATIONAL FIDELITY INSURANCE COMPANY at a meeting duly held on the 20th day of July,2010 and by the Board of
Directors of ALLEGHENY CASUALTY COMPANY at a meeting duly held on the 10th day of July,2015
"RESOLVED, that (1) the Chief Executive Officer, President, Executive Vice President, Vice President, or Secretary of the Corporation shall have the
power to appoint,and to revoke the appointments of,Attorneys-in-Fact or agents with power and authority as defined or limited in their respective powers
of attorney, and to execute on behalf of the Corporation and affix the Corporation's seal thereto, bonds, undertakings, recognizances, contracts of
indemnity and other written obligations in the nature thereof or related thereto; and(2)any such Officers of the Corporation may appoint and revoke the
appointments of joint-control custodians, agents for acceptance of process, and Attorneys-in-fact with authority to execute waivers and consents on
behalf of the Corporation;and(3)the signature of any such Officer of the Corporation and the Corporation's seal may be affixed by facsimile to any power
of attorney or certification given for the execution of any bond, undertaking, recognizance, contract of indemnity or other written obligation in the nature
thereof or related tnereto, such signature and seals when so used whether heretofore or hereafter, being hereby adopted by the Corporation as the
original signature of such officer and the original seat of the Corporation,to be valid and binding upon the Corporation with the same force and effect as
though manually affixed."
IN WITNESS WHEREOF,INTERNATIONAL FIDELITY INSURANCE COMPANY and
ALLEGHENY CASUALTY COMPANY have each executed and attested these presents
on this 31st day of December,2016
WiTY 1Q S STATE OF NEW JERSEY isUq�'c
�pi`��Rq County of Essex ��
T t.s� 4r
jE'wG' �` George R.James \ *�`
* Executive Vice President (International Fidelity Insurance Company)and `
Vice President (Allegheny Casualty Company) " vVJsi:sc
On this 31st day of December,2016 ,before me came the individual who executed the preceding instrument,to me personally known,and,
being by me duly sworn,said he is the therein described and authorized officer of INTERNATIONAL FIDELITY INSURANCE COMPANY and
of ALLEGHENY CASUALTY COMPANY;that the seals affixed to said instrument are the Corporate Seals of said Companies;that the said Corporate
Seals and his signature were duly affixed by order of the Boards of Directors of said Companies.
10llll ""+++ IN TESTIMONY WHEREOF,I have hereunto set my hand affixed my Official Seal,at the City of Newark,
,`%` P,� (�,,+, New Jersey the day and year first above written.
:r 410.•s4r m. -
NA 9 • �}s tare 0c: Cathy Cruz a Notary Public of New Jersey
- •• ' ��Q`� My Commission Expires April 16,2019
NEW CERTIFICATION
'+++l+lll still/111j1,
I,the undersigned officer of INTERNATIONAL FIDELITY INSURANCE COMPANY and ALLEGHENY CASUALTY COMPANY do hereby certify that I
have compared the foregoing copy of the Power of Attorney and affidavit,and the copy of the Sections of the By-Laws of said Companies as set forth in
said Power of Attorney,with the originals on file in the home of said companies,and that the same are correct transcripts thereof,and of the whole of the
said originals,and that the said Power of Attorney has not been revoked and is now in full force and effect.
IN TESTIMONY WHEREOF,I have hereunto set my hand on this day, September 06,2018
4444,411fritee
A02155/Diamond Valley Insurance Services,Inc.
Maria H.Branco,Assistant Secretary
CALIFORNIA ALL- PURPOSE
CERTIFICATE OF ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity
of the individual who signed the document to which this certificate is attached,
and not the truthfulness, accuracy, or validity of that document.
State of Californiai }
County of /f)1/E/ ct6k }
On��"'t/ j here me, ,f�f .£ 3L1 , 'a/ 2/ aZhe__)
(Here inse me end title of the officer?
personally appeared 9(
i..( T:16311 '
who pro ed to me on the basis of sasfactory evidence to be the persons whose
me �ls ' subscribed to the wi instrument and acknowledged to e that
It y executed the same in is/ r/t lr authorized capacity s), and that by
Is/',,.Or signatureX on the instrument the person or the entity upon behalf of
ich the person{$ acted, executed the instrument.
T `
I certify under PENALTY OF PERJURY under the laws of the State of California that
the foregoing paragraph is true and correct.
,�l., ,, K.A,EBY
3 comm. #2156b15 z
W NESS m . d and .,'icial S:1. a■ r-� Notary Public •California o
_� z *, Riverside Country
�:�;;�.t ` Coma,, ,lies 1,2020
Notary Public :ignature (No .ry Public Seal)
ADDITIONAL OPTIONAL INFORMATION INSTRUCTIONS FOR COMPLETING THIS FORM
This form complies with current California statutes regarding notary wording and,
DESCRIPTION OF THE ATTACHED DOCUMENT £needed,should be completed and attached to the document.Acknowledgments
from other states may he completed for documents being sent to that state so long
as the wording does not requite the California notate to violate Caltfoi nta notary
law.
(Title or description of attached document) • State and County information must be the State and County where the document
signer(s)personally appeared before the notan public for acknowledgment.
• Date of notarization must be the date that the signer(s)personally appeared which
(Title or description of attached document continued) must also be the same date the acknowledgment is completed.
• The notary public must print his or her name as it appears within his or her
Number of Pages Document Date commission followed by a comma and then your title(notary public).
• Print the name(s) of document signer(s) who personally appear at the time of
notarization.
CAPACITY CLAIMED BY THE SIGNER • Indicate the correct singular or plural forms by crossing off incorrect forms(i e.
he.she they, is ewe)or circling the correct forms.Failure to correctly indicate this
❑ Individual (s) information may lead to rejection of document recording,
❑ Corporate Officer • The notary seal impression must be clear and photographically reproducible.
Impression must not cover text or lines. If seal impression smudges.re-seal if a
(Title) sufficient area permits.otherwise complete a different acknowledgment form.
• Signature of the rrotan public must match the signature on file with the office of
❑ Partner(s)
the county clerk.
O Attorney-in-Fact + Additional information is not required but could help to ensure this
❑ Trustee(s) acknowledgment is not misused or attached to a different document.
Other . Indicate title or type of attached document,number of pages and date.
❑ 'Indicate the capacity claimed by the signer. if the claimed capacity is a
corporate officer,indicate the title(i.e.CEO.CFO,Secretor)).
• Securely attach this document to the signed document with a staple
Bond#SXACSU 0728800
LABOR AND MATERIAL PAYMENT BOND
•
Whereas,the City Council of the City of Redlands,State of California,and R Dependable Construction, Inc.
(hereinafter designated as"Principar)have entered into an agreement(the"Agreement")whereby Principal
agrees to install and complete certain designated public improvements(the"Work'),which said agreement,dated September 18th
2018,and identified as * is hereby referred to and made a part hereof;and
Whereas, under the terms of the Agreement, Principal is required before commencing upon the performance of the Work,to file a good
and sufficient payment bond with the City of Redlands to secure the claims to which reference is made in Title 3(commencing with Section 9000)of
Part 6 of Division 4 of the Civil Code of the State of California.
Now, therefore, said Principal and the undersigned as corporate surety, are held firmly bound unto the City and all contractors,
subcontractors,laborers,material men and other persons employed in the performance of the aforesaid Agreement and referred to in the aforesaid
Code of Civil Procedure in the sum of ** Dollars($60,133.75)for materials furnished or labor thereon of any kind,
or for amounts due under the Unemployment Insurance Act with respect to such work or labor,that said surety will pay the same in an amount not
exceeding the amount hereinabove set forth, and also in case suit is brought upon this bond,will pay,in addition to the face amount thereof,costs
and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligation, to be
awarded and fixed by the court,and to be taxed as costs and to be included in the iudgment therein rendered.
It is hereby expressly stipulated and agreed that this bond shall insure to the benefit of any and all persons,companies and corporations
entitled to file claims under Title 3(commencing with Section 9000)of Part 6 of Division 4 of the Civil Code,so as to give a right of action to them or
their assigns in any suit brought upon this bond.
Should the condition of this bond be fully performed,then this obligation shall become null and void,otherwise it shall be and remain in full
force and effect.
The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or the
specifications accompanying the same shall in any manner affect its obligations on this bond,and it does hereby waive notice of any such change,
extension of time,alteration or addition.
In witness whereof,this instrument has been duly executed by the Principal and surety above named,on September 6th
2018 .
(SEAL) (SEAL)
R Dependable Constructio Allegheny asualty Company
( actor) (Surety)
BY:
(Sign ure) Rosema i , President (Srgnatu yle T. Baker,Attorney-in-Fact
Address: 2400 E. Katella Ave#250
Anaheim, CA 92806
(Seal and Notarial Acknowledgment of Surety) Telephone(714) 602-9170 (Surety)
951-553-7400 (Agent)
CD-6
* CARRIAGE HOUSE INTERIOR RECONSTRUCTION PROJECT Q0L07092018KG
** Sixty Thousand One Hundred Thirty-Three and 751100
QQL4709201.9KG—Carnage House lnteriorReconstruction
POWER OF ATTORNEY Bond# SXACSU 0728800
INTERNATIONAL FIDELITY INSURANCE COMPANY
ALLEGHENY CASUALTY COMPANY
One Newark Center,20th Floor,Newark,New Jersey 07102-5207 PHONE:(973)624-7200
KNOW ALL MEN BY THESE PRESENTS: That INTERNATIONAL FIDELITY INSURANCE COMPANY,a corporation organized and existing under the
laws of the State of New Jersey, and ALLEGHENY CASUALTY COMPANY a corporation organized and existing under the laws of the State of New
Jersey,having their principal office in the City of Newark,New Jersey,do hereby constitute and appoint
TIMOTHY C. BAKER, KAREN A. EBY, KYLE T. BAKER.
Murrietta, CA.
their true and lawful attomey(s)-in-fact to execute, seal and deliver for and on its behalf as surety, any and all bonds and undertakings, contracts of
indemnity and other writings obligatory in the nature thereof,which are or may be allowed,required or permitted by law,statute,rule,regulation,contract
or otherwise, and the execution of such instrument(s) in pursuance of these presents, shall be as binding upon the said INTERNATIONAL FIDELITY
INSURANCE COMPANY and ALLEGHENY CASUALTY COMPANY, as fully and amply, to all intents and purposes, as if the same had been duly
executed and acknowledged by their regularly elected officers at their principal offices.
This Power of Attorney is executed, and may be revoked, pursuant to and by authority of the By-Laws of INTERNATIONAL FIDELITY INSURANCE
COMPANY and ALLEGHENY CASUALTY COMPANY and is granted under and by authority of the following resolution adopted by the Board of
Directors of INTERNATIONAL FIDELITY INSURANCE COMPANY at a meeting duly held on the 20th day of July,2010 and by the Board of
Directors of ALLEGHENY CASUALTY COMPANY at a meeting duly held on the 10th day of July,2015
"RESOLVED, that (1) the Chief Executive Officer, President, Executive Vice President,Vice President, or Secretary of the Corporation shall have the
power to appoint,and to revoke the appointments of,Attorneys-in-Fact or agents with power and authority as defined or limited in their respective powers
of attorney, and to execute on behalf of the Corporation and affix the Corporation's seal thereto, bonds, undertakings, recognizances, contracts of
indemnity and other written obligations in the nature thereof or related thereto; and (2)any such Officers of the Corporation may appoint and revoke the
appointments of joint-control custodians, agents for acceptance of process, and Attorneys-in-fact with authority to execute waivers and consents on
behalf of the Corporation;and(3)the signature of any such Officer of the Corporation and the Corporation's seal may be affixed by facsimile to any power
of attorney or certification given for the execution of any bond, undertaking, recognizance,contract of indemnity or other written obligation in the nature
thereof or related thereto, such signature and seals when so used whether heretofore or hereafter, being hereby adopted by the Corporation as the
original signature of such officer and the original seal of the Corporation,to be valid and binding upon the Corporation with the same force and effect as
though manually affixed."
IN WITNESS WHEREOF,INTERNATIONAL FIDELITY INSURANCE COMPANY and
ALLEGHENY CASUALTY COMPANY have each executed and attested these presents
on this 31st day of December,2016
txt a•/it o, STATE OF NEW JERSEY GASUA4pr
�s
PDr�g 'y County of Essex it (;)1.4ig �" SEA ft.' / rU q
rrl
Tie; O George R.James t\
'149 Viv4 Executive Vice President (International Fidelity Insurance Company)and
Vice President (Allegheny Casualty Company) 't'�y JEftS�
On this 31st day of December,2016 ,before me came the individual who executed the preceding instrument,to me personally known,and,
being by me duly sworn,said he is the therein described and authorized officer of INTERNATIONAL FIDELITY INSURANCE COMPANY and
of ALLEGHENY CASUALTY COMPANY;that the seals affixed to said instrument are the Corporate Seals of said Companies;that the said Corporate
Seals and his signature were duly affixed by order of the Boards of Directors of said Companies.
``",rmrC , IN TESTIMONY WHEREOF,I have hereunto set my hand affixed my Official Seal,at the City of Newark,
'
GP▪ " Y.. .C'R(,�'j '�,, New Jersey the day and year first above written.
4.•
NOTARY
,•��p
GP-•i m.
`▪a PUBLIC 0:
.: `P,.'. o*i 2n;g .' � Cathy Cruz a Notary Public of New Jersey
•.,,,,,,'• ��-�$ My Commission Expires April 16,2019
CERTIFICATION
I,the undersigned officer of INTERNATIONAL FIDELITY INSURANCE COMPANY and ALLEGHENY CASUALTY COMPANY do hereby certify that I
have compared the foregoing copy of the Power of Attorney and affidavit,and the copy of the Sections of the By-Laws of said Companies as set forth in
said Power of Attorney,with the originals on file in the home of said companies,and that the same are correct transcripts thereof,and of the whole of the
said originals,and that the said Power of Attorney has not been revoked and is now in full force and effect.
IN TESTIMONY WHEREOF,I have hereunto set my hand on this day, September 06,2018
41-11-"W"
A02155/Diamond Valley Insurance Services,Inc. ��
Maria H.Branco,Assistant Secretary
A. -I. 111.Aw•-. .. .. ._.
CALIFORNIA ALL- PURPOSE
CERTIFICATE OF ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity
of the individual who signed the document to which this certificate is attached,
i and not the truthfulness, accuracy, or validity of that document.
State of Califo7-)
nia /e }
County of / ��S�/`l }
Onal'"" hn fore me, 411,/).el it. ;CAM
YJ ' �-� (Here rose me a'id title of the officevaac)
personally appeared 9 ' C.(' l , �-L' ,
who pro ed to me on the basis of satisfactory evidence to be the person,,�whose
me ' subscribed to the wi " instrument and acknowledged to me that
R ry executed the same in is ' r/t Ir authorized capacity s), and that by
r,, r signature/Von the instrument the person , or the entity upon behalf of
ich the person acted, executed the instrument.
. j "
I certify under PENALTY OF PERJURY under the laws of the State of California that
the foregoing parag aph . -- - - a • correct. ply
IliY' y,�.,.- - L A EPA
- �!!� . t COMM. #2156615 z
rES
d • offi-is l seal. -1 :,4,' - Notary Public•California o
.� .oy - .
r z -+) Riverside County
*:t,.,.o Comm. .lies 1 2020
Nota Public Signatu e (Notary Public Seal)
♦ ♦
ADDITIONAL OPTIONAL INFORMATION INSTRUCTIONS FOR COMPLETING THIS FORM
This farm crmrphes with current California statutes regarding notary warding and,
DESCRIPTION OF THE ATTACHED DOCUMENT if needed,should he completed and attached to the document.Acknowledgments
from other states may he completed for documents being sent to that slate so long
as the wording does not require the Cultfornia notary to violate Cahformn norm?:
lair.
(Title or description of attached document) • State and County information must be the State and County where the document
signer(s)personally appeared before the notary public for acknowledgment
• Date of notarization must be the date that the signer(s)personally appeared which
(Title or description of attached document continued) must also be the same date the acknowledgment is completed.
• The notary public must print his or her name as it appears within his or her
Number of Pages Document Date commission followed by.a comma and then your title(notary public).
• Print the name(s) of document signer(s) who personally appear at the time of
notarization.
CAPACITY CLAIMED BY THE SIGNER • Indicate the correct singular or plural forms by crossing off incorrect forms(i.e.
he she they, is eee)or circling the correct forms.Failure to correctly indicate this
❑ Individual (s) information may lead to resection of document recording-
❑ Corporate Officer • The notary seal impression must be clear and photographically reproducible.
Impression must not cover text or lines. If seal impression smudges,re-seal if a
(Title) sufficient area permits.otherwise complete a different acknowledgment form.
0 Partner(s) • Signature of the notary public must match the signature on file with the office of
the county clerk.
❑ Attorney-in-Fact + Additional information is not required but could help to ensure this
❑ Trustee(s) acknowledgment is not misused or attached to a different document.
Other •. Indicate title or type of attached document.number of pages and date.
❑ — Indicate the capacity claimed by the signer. if the claimed capacity is a
corporate officer,indicate the title(i.e.CEO,CFO.Secretary).
• Securely attach this document to the signed document with a staple