Loading...
HomeMy WebLinkAboutContracts & Agreements_228-2018 PUBLIC WORKS CONSTRUCTION CONTRACT This Public Works Construction contract ("Contract") made and entered into this 4ii' day of December 2018, by and between the City of Redlands, a municipal corporation organized and existing under the laws of the State of California, (hereinafter "City"), and LC Paving & Sealing, Incorporated (hereinafter"Contractor") City and Contractor are sometimes individually referred to herein as a`Party"and, together, as the"Parties " In consideration of the mutual promises contained herein, City and Contractor agree as follows 1 SCOPE OF WORK Contractor shall furnish all materials and will perform all of the work for the following 17/18 CDBG Alley Paving Improvements,complete all items as required by the Contract Documents (as herein defined) and Specifications for City's 17/18 CDBG Alley Paving Improvements, Project No 43063 2 THE CONTRACT SUM City shall pay Contractor the sum of Three Hundred Sixty Eight Thousand Three Hundred One Dollars and Ninety Seven Cents ($368,301 97) as consideration for its performance of the Work in accordance with the terms and conditions set forth in the Contract Documents Pursuant to Public Contract Code Section 22300, Contractor has the option to deposit securities with an escrow agent as a substitute for retention of earnings requirement to be withheld by City pursuant to an escrow agreement as set forth in the Public Contract Code Section 22300 3 TIME FOR COMPLETION The Work shall be completed within sixty calendar days (60) frorn and after the date of the delivery to Contractor of a written Notice to Proceed by City 4 LIQUIDATED DAMAGES: Contractor's failure to complete the work within the time allowed will result in damages being sustained by City Such damages are, and will continue to be, impracticable and extremely difficult to determine Accordingly, Contractor shall pay to City, or have withheld from monies due to Contractor, the sum of hive Hundred Dollars ($500) for each consecutive calendar day in excess of the specified time for completion of Work Execution of the Contract shall constitute agreement by City and Contractor that Five Hundred Dollars ($500) per day is the estimated damage to City caused by the failure of the Contractor to complete the Work within the allowed time Such sum is for liquidated damages and shall not be construed as a penalty, and may be deducted from payments due Contractor if such delay occurs 5 CONTRACT DOCUMENTS This Contract incorporates by reference the following Notice Inviting Bids, Instructions to Bidders, Contractor's Proposal, Bid Bond, Agreement, Performance Bond, Labor and Material Bond, Plans, General Conditions, Special Provisions and Specifications, County of San Bernardino Community Development and Housing Labor Compliance Contract Addendum, and any addenda thereto (collectively the"Contract Documents") 6 ATTORNEYS' FEES In the event any legal action is commenced to enforce or interpret the terms or conditions of the Contract documents,the prevailing Party in such action, in addition to any costs and other relief, shall be entitled to recover its reasonable attorneys' fees, including fees for use of in-house counsel by a Party CD I L 1caldJrn\Agreecnents\LC Paving&Sealing, Incorporate docx 7 RESOLUTION OF CONSTRUCTION CLAIMS Claims by Contractor in the amount of Three Hundred Seventy Five Thousand Dollars ($375,000) or less shall be made by Contractor and processed by the City pursuant to the provisions of Part 3, Chapter 1, Article 1 5 of the Public Contract Code (commencing with Section 20104) All claims shall be in writing and include the documents necessary to substantiate the claim Nothing in subdivision (a) of Public Contract Code Section 20104 2 shall extend the time limit or supersede the notice requirements provided in this case from filing claims by Contractor 8 ELIGIBILITY OF CONTRACTOR/SUBCONTRACTOR: Contractor and all of its subcontractors shall abide by California Public Contract Code, Section 6109, and California Labor Code Sections 1777 1 and/or 1777 7, and certify that they are not debarred and are eligible to work on this project Contractor is also eligible to work on federally funded projects 9 ASSIGNMENT OF AGREEMENT No assignment by a Party of any rights or interests under this Contract shall be binding on another Party without the written consent of the Party sought to be bound 10 SUCCESSORS AND ASSIGNS City and Contractor each binds itself and their respective successors and assigns in respect to all covenants, agreements, and obligations contained in the Contract Documents i 1 SEVERABILITY Any provision or pail of the Contract documents held to be void or unenforceable under any law or regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon City and Contractor CD 2 L 1caldjin\Agreements\LC Paving&Sealing, Incorporate docx IN WITNESS WHEREOF, the parties hereto have executed this Agreement the day and year first written above City of Redlands (SEAL) (Owner) By , Paul W Foster, Mayor ATTEST Je Donaldson,City Clerk (SEAL) G Tn Y1 A 1 Name of Contractor J By Signa o Aut razed Agent Title Signature of Authorized Agent(if necessary) Title Contractor's License No. CD 3 L 1caldJm\Agreernents\LC Paving&Seating, Incorporate doex WORKER'S COMPENSATION INSURANCE CERTIFICATION Description of Contract City of Redlands Municipal Utilities&Engineering Department 17/18 CDBG Alley Paving Improvements Project No 43063 Every employer, except the State, shall secure the payment of compensation in one or more of the following ways a By being insured against liability to pay compensation in one or more insurers duly authorized to write compensation insurance in this State b By securing from the Director of Industrial Relations, a certificate of consent to self- insure, either as an individual employer, or as one employer in a group of employers, which may be given upon furnishing proof satisfactory to the Director of Industrial Relations of ability to self-insure and to pay any compensation that may become due to his or her employees CHECK ONE V I am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against liability for worker's compensation or to undertake self-insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work and activities required or permitted under this Agreement (Labor Code section §1861) I affirm that all times, in performing the work and activities required or permuted under this Agreement, I shall not employ any person in any manner such that 1 become subject to the workers' compensation laws of California However, at any time, if I employ any person such that I become subject to the workers' compensation laws of California, immediately I shall provide the City with a certificate of consent to self-insure, or a certification of workers' compensation insurance I certify under penalty of perjury under the laws of the State of California that the information and representations made in this certificate are true and correct Dated this_/� day of megg 2018 n ctor) —/)U (Signature) (Official Title) (SEAL) (Labor Code Section 1861 provides that the above certificate must be signed and filed by the Contractor with the Owner prior to performing the work of the contract) CD 4 L IcaldJm\Agreements\LC Paving&Sealing,Incorporate doex Bond No CMGP0001836 Premium $6,525 00 FAITHFUL PERFORMANCE BOND Whereas, the City of Redlands ("City"), State of California, and LC Paving & Sealing, Incorporated (hereinafter designated as "Principal") have entered into an agreement dated December 4, 2018 ('Agreement") whereby Principal agrees to install and complete certain public improvements (the "Work"), which said Agreement is identified as 17/18 CDBG Alley Paving Improvements, Project No 43063 and is hereby referred to and made a part hereof, and Whereas,said Principal is required under the terms of the Agreement to furnish a bond for the faithful performance of the Agreement, now, therefore, we, the Principal and Argonaut Insurance Company , as Surety, are held and firmly bound unto the City in the penal sum of Three Hundred Sixty Eight Thousand Three Hundred One Dollars and Ninety Seven Cents ($368,301 97) lawful money of the United States, for the payment of which sum we bind ourselves,and our heirs, successors, executors and administrators,jointly and severally, firmly by these presents The condition of this obligation is such that if the above bounded Principal, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and provisions in the Agreement and any alteration thereof made as therein provided, on his or its part,to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall faithfully fulfill the one-year guarantee of all materials and workmanship, and shall defend, indemnify and save harmless the City and its elected officials, officers, agents and employees,as therein stipulated,then this obligation shall become null and void,otherwise it shall be and remain in full force and effect As a part of the obligation secured hereby and in addition to the face amount specified therefor, there shall be included costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligations, all to be taxed as costs and included in the judgment rendered As a condition precedent to the satisfactory completion of the Agreement, the above obligation shall hold good for a period of one(1)year or longer if required by the Agreement after the acceptance of the work by the City, during which time if the Principal shall fail to make full, complete,and satisfactory repair and replacements and totally protect the City from loss or damage made evident during this period from the date of completion of the Work, and resulting from or caused by defective materials or faulty workmanship, the above obligation in penal sum thereof shall remain in full force and effect.The obligations of Surety hereunder shall continue so long as any obligation of the Principal remains Whenever the Principal shall be, and is declared by the City to be, in default under the Agreement, the City having performed the City obligations thereunder, the Surety shall promptly remedy the default, or shall promptly, at the City's option I Complete the Agreement in accordance with its terms and conditions; or 2 Obtain a bid or bids for completing the Agreement in accordance with its terms and conditions, and upon determination by Surety of the lowest responsive and responsible bidder, arrange for a contract between such bidder and the City, and make available as work progresses CD 5 L%caldjm\Agreernents\LC Paving&Sealing, Incorporate docx sufficient funds to pay the cost of completion of the Work less the balance of the Agreement price, but not exceeding, including other costs and damages for which Surety may be liable hereunder, the amount set forth above The term "balance of the Agreement price,"as used in this paragraph, shall mean the total amount payable to the Principal by the City under the Agreement and any modifications thereto, less the amount previously properly paid by the City to the Principal Surety expressly agrees that the City may reject any contractor or subcontractor which may be proposed by Surety in fulfillment of its obligations In the event of default by the Principal Surety shall not utilize the Principal in completing the Agreement nor shall Surety accept a bid from the Principal for completion of the Work if the City, when declaring the Principal in default, notifies Surety of the City's objection to the Principal's further participation in the completion of the Work No right of action shall accrue on the bond to or for the use of any person or corporation other than the City named herein or the successors or assigns of the City Any suit under this bond must be instituted within the applicable statute of limitations period The said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or to the work to be performed thereunder or the Specifications accompanying the same shall In any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Agreement or to the work or to the specifications No final settlement between the City and the Principal shall abridge the right of any beneficiary hereunder whose claim may be unsatisfied The Principal and Surety agree that if the City is required to engage the services of any attorney in connection with the enforcement of this bond, each shall pay the City's reasonable attorneys' fees incurred, with or without suit, in addition to the above sum. In witness whereof, this instrument has been duly executed by the Principal and Surety above named, on November 29th 2018 (SEAL) (SEAL) avm Se in nc Aegionaut lns a2pe Company actor) U0. ) BY abriella ra y { gnature} tgna�Fe'Attorney-in-Feat Addr 5 IA-2033 ' e turaa Blvd , (Seal and Notarial Acknowledgement of Surety) 26 W o land Hills CA 91364 Telephone ( 866 ) 363-2642 CD 6 L 1ca\djmlAgreements\LC Paving&Sealing,Incorporate docx ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached and not the truthfulness, accuracy, or validity of that document State of California County of San Diego ) On • �G� before me, Marisa Haas, Notary Public (insert name and title of the officer) personally appeared Jose A Salinas who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies) and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted executed the instrument I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct MARISA ANN HAAS WITNESS my hand and official seal Commission # 2122991 z z ,-: Notary Public-California n z San Diego County My Comm Ex Tres Aug15,2019 Signature (Seal) CMGP0001836 Argonaut Insurance Company $6,525 00 Deliveries Only: 225 W. Washington, 24th Floor Chicago, IL 60606 United States Postal Service: P.O. Box 469011, San Antonio, TX 78246 POWER OF ATTORNEY KNOW ALL MEIN BY THESE PRESENTS That the Argonaut Insurance Company,a Corporation duly organized and existing under the laws of the State of Illinois and having its principal office in the County of Cook Illinois does hereby nominate constitute and appoint Gabnella Grade,Shilo Lee Losino,Stephanie Mope Shear ' **VAOe Their true and IaA ful agent(s)and attorney(s)-m-fact,each intheir separate capacity if more than one is named above,to make execute seal and deliver for and on its behalf as surety,and as its act and deed any and all bonds contracts,agreements of indemnity and other undertakings in suretyship provided,however,that the penal sum of any one such instrument executed hereunder shall not exceed the sum of S 10,000,000.00 This Power of Attorney is granted and is simed and sealed under and by the authority of the following Resolution adopted by the Board of Directors of Argonaut Insurance Company "RFSOI VI D,Tliat the President,Senior Vice President Vice President,Assistant'Vice President,Secretary,Treasurer and each of them hereby is authorized to execute powers of attorney,and such authority can be executed by use of facsimile signature,which may be attested or acknowledged by any officer or attorney,of the Company,qualifying the attorney or attorneys named in the given power t attorney,to execute in behalf of and acknowledge as the act and deed of the Argonaut Insurance Company,all bond undertakings and contracts of sure ip,and.to affix the corporate seal thereto" IN WITNESS WIIERI'01' Argonaut insurance Company has causedi s I seal to be hereunto affixed and these presents to be signed by its duly authorized officer out the Sth day of May,2017 •• *. Argonaut Insurance Company — x: 1948 :z. by * Joshua C Betz Senior Vice President STA fE OF TEXAS • �`'�.,,,." • • COUNTY OF I4ARRIS SS On this 8th da) of May 2017 A D.,before me,a Notary Public of the State of Texas,in and for the County of Barris,duly commissioned and qualified,came FHI-AI30VL OI-FIC.ER OI Ii 1L'COMPANY,to life personally known to be the individual and officer described in,and who executed the preceding instrument, and he acknowledged the execution of same,and being by me duly sworn,deposed and said that he is the officer of the said Company aforesaid,and that the seal affixed to the preceding instrument is the Corporate Seal of said Company,and the said Corporate Seal and his signature as officer were duly affixed and subscribed to the said instrument by the authority and direction of the said i-orporation and that Resolution adopted by the Board of Directors of said Company referred to in the preceding instrument is now in force IN TESTIMONY WHLRLOF,I have hereunto set my hand,and affixed my Official Seal at the County of Hams,the day and year first above written E' tllliIts`rn YZ�xsIn i`•�tYP`q:,s KATNLEEi�,iR ,uit:EKS �' .,f, Nur�ryPublrt; $,N,P4iT9xa6 -111-r'`:va) Comm Expi rea 07 It-2U2i (Notary Public} 7f�ia. ''•i,�„# idolery{p 567802 B I the undersigned Officer of the Argonaut Insurance Company,Illinois Corporation,do hereby certify that the original POWER OF ATTORNEY of which the foregoing is a full true and correct copy is still in full force and effect and has not been revoked IN WITNESS WHEREOF,I have hereunto set my hand and affixed the Seal of said Company on the 29th day of November 2018 Sarah Heineman VP Underwriting Surety THIS DOCUMENT IS NOT VALID UNLESS THE WORDS ARGO POWER OF ATTORNEYARE IN BLUE IF YOU HAVE QUESTIONS ON errTur•?%rrrrrrV nP•rMQ nnrtntaFnrr CAT i 01AX All -RAM CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached and not the truthfulness,accuracy,or validity of that document State of California ) County of LOS ANGELES ) On NOV 2 ` 2018 before me, SHIRLEY GIGGLES, NOTARY PUBLIC Date Here Insert Name and Title of the Officer personally appeared GABRIELLA GRADY Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name($) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/theft signature(s)on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument I certify under PENALTY OF PERJURY Under the laws of the State of California that the foregoing paragraph SHIRZEY GIGGLES is true and correct "� Molar; a, Catifornia WITNESS hand d official seal z ,� w Los Kr;;ies County z Z ` ` Comrliss�c, # 21,33817 n fly Corru F= 1 Signat Srgna o otary Public Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document Description of Attached Document Title or Type of Document Document Date Number of Pages Signer(s) Other Than Named Above Capacity(ies) Claimer! by Signer(s) Signer's Name Signer's Name ❑Corporate Officer — Title(s) ❑Corporate Officer — Title(s) ❑ Partner — ❑ Limited 7:; Genera4 ❑ Partner -- ❑Limited ❑ General ❑ Individual 1 Attorney in Fact F. Individual ©Attorney in Fact ❑Trustee Guardian or Conservator C Trustee ❑Guardian or Conservator ❑Other IJ Other Signer Is Representing Signer Is Representing 02014 National Notary Association www National Notary org • 1-800-US NOTARY(1-800-876-6827) Item#5907 Bond No CMGP0001836 Premium included LABOR AND MATERIAL, BOND Whereas, the City Council of the City of Redlands, State of California, and LC Paving & Sealing, Incorporated (hereinafter designated as "Principal") have entered into an agreement (the `Agreement") whereby Principal agrees to install and complete certain designated public improvements (the "Work"), which said agreement, dated December 4, 2018, and identified as 17/18 CDBG Alley Paving Improvements,Project No 43063 is hereby referred to and made a part hereof, and Whereas, under the terms of the Agreement, Principal is required before commending the performance of the Work, to file a good and sufficient Labor and Material bond with the City of Redlands to secure the claims to which reference is made in Title 3 (commencing with Section 9550)of Part 6 of Division 4 of the Civil Code of the State of California Now, therefore, said Principal and the undersigned as corporate surety, are held firmly bound unto the City and all contractors, subcontractors, laborers, material men and other persons employed in the performance of the Agreement and referred to in the aforesaid Code of Civil Procedure in the sum Three Hundred Sixty Eight Thousand Three Hundred One Dollars and Ninety Seven Cents ($368,301 97) for materials furnished or labor thereon of any kind, or for amounts due under the Unemployment Insurance Act with respect to such work or labor, that said surety will pay the same in an amount not exceeding the amount hereinabove set forth, and also in case suit is brought upon this bond, will pay, in addition to the face amount thereof, costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligation, to be awarded and fixed by the court, and to be taxed as costs and to be included in the judgment therein rendered It is hereby expressly stipulated and agreed that this bond shall insure to the benefit of any and all persons, companies and corporations entitled to file claims under Title 3 (commencing with Section 9550)of Part 6 of Division 4 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond Should the condition of this bond be fully performed,then this obligation shall become null and void, otherwise it shall be and remain in full force and effect The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or the specifications accompanying the same shall in any manner affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition. CD 7 L Icaldjrn\Agreements\LC Paving&Sealing,Incorporate doex In witness whereof, this instrument has been duly executed by the Principal and surety above named, on November 29 , 201 S (SEAL} (SEAL} C P v► 5e i , Inc Argo au#Insur crompany o ctor} Sur ryBYSi ature ( gracy} SI urorney-in-Fact Address do C GIA 20335 Ventura Blvd (Seal and Notarial Acknowledgement of Surety) Ste 426 Wo4aq&Hi11s CA 91364 Telephone 8 6 ) 363-2642 CD 8 L IcaldjmlAgreementsiLC Paving& Sealing, Incorporate docx ACKNOWLEDGMENT r A notary public or other officer completing this certificate verifies only the Identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document State of California County of San Diego ) On aL 22y 2-0 Y1 before me, Marisa Maas, Notary Public (Insert name and title of the officer) personally appeared Jose A Salinas who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies) and that by his/her/their signature(s) on the instrument the person(s) or the entity upon behalf of which the person(s) acted, executed the instrument I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct MARISA ANN HAAS WITNESS my hand and official seal Commission#2122991 z . Notary Public California z _ San Diego County D M Comm Expires Aug15 2019 Signature i (Seal) CMGP0001836 Argonaut Insurance Company $6,525 00 Deliveries Only: 225 W. Washington, 24th Floor Chicago, IL 60606 United States Postal Service: P.O. Box 469011, San Antonio, TX 78246 POWER OF ATTORNEY KNOB'ALL MLN BY THESE PRESENTS That the Argonaut Insurance Company,a Corporation duly organized and existing under the laws of the State of Illinois and having its principal office in the County of Cook,Illinois does hereby nominate,constitute and appoint Gabrieila Grady,Shilo Lee Losino Stephanie Ho Shear Their true and lawful agent(s)and attorney(s) in fact,each in their separate capacity if more than one is named above,to make,execute,seal and deliver for and on its behalf as surety,and as its act and deed any and all bonds contracts agreements of indemnity and other undertakings in suretyship provided however that the penal sum of any one such instrument executed hereunder shall not exceed the sum of $1-.00 This Power of AttorneN is granted and is signed and scaled under and by the authority of the tollo�r inR I2_ ilution adopted by the Board of Directors of Argonaut Insurance Company '® "RFSOl VI D That the President,Sentor Vice President Vice President Assistant VicKr ident,Secretary Treasurer and each of them hereby is authorized to execute powers of attorney,and sue i authority can be executed by use of facsimile signature,which may be attested or acknowledged by any officer or attorney,of the Company,qualifying the attorney or attorneys named in the given power of attorney,to execute in behalf of and acknowledge as the act and deed of the Argonaut Insurance Company all bond undertakings and contracts of suretyship,and to affix the corporate seal thereto" IN WITNESS WHEREOF,Argonaut Insurance Company has caused its official seal to be hereunto affixed and these presents to be signed by its duly authorized officer on the 8th day of May 2017 1 „W..„ Argonaut insurance Company SEAL: xd; ism by hLrhGkS••Y: STAT>;OI•TEXAS Joshua C Betz, Senior Vice President I'''�••,r""��, COIN Y OF HARRIS SS On this M day of May,2017 A.D.,hcfore me,a Notary Public of the State of Texas,in and for the County of Harris duly commissioned and qualified came IT IL ABOVE OFFICER OI '11 lt_COMPANY to me personally known to be the individual and officer described in,and who executed the preceding mstruinent, and he acknowledged the execution of same and being by me duly sworn,deposed and said that he is the officer of the said Company aforesaid,and that the seal affixed to the preceding instrument is the Corporate Seal of said Company,and the said Corporate Seal and his signature as officer were duly affixed and subscribed to the said instrument by the authority and direction of the said corporation and that Resolution adopted by the Board of Directors of said Company referred to in the preceding instrument is nn}v in force IN TESTfM0NY kA`HL,.RI:OF I have hereunto set my hand,and affixed my Official Seal at the County of Harris,the day and year first above written +o, KATHLEEN M MEEKS « ,<� Nr,iary Rudlie state of Texas (notary Public) „e r' Comm Expiroa 07 16-2021 (Votary ID 557902-8 I,the undersigned Officer of the Argonaut Insurance Company Illinois Corporation,do hereby certtfy that the original POWER OF ATTORNEY of which the foregoing is a full,trite and correct copy is still in full force and effect and has not been revoked IN WITNESS WHEREOF i have hereunto set my hand,and affixed the Seat of said Company on the 29th day of November 2018 .r„rvu r. Sarah Heineman VP-Underwntmg Surety THIS DOCUMENT IS NOT VALID UNLESS THE WORDS ARGO POWER OF ATTORNEYARE IN BLUE.IF YOU HAVE QUESTIONS ON AUTHIMT1MY OF THIS n0C'11MFNT CAT i l7101 A'tt _.QAM CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 118/9 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document State of California ) County of LOS ANGELES On NOV 2 9 2018 before me, SHIRLEY GIGGLES, NOTARY PUBLIC Date Here Insert Name and Title of the Officer personally appeared GABRIELLA GRADY Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s)on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument I certify under PENALTY OF PERJURY under the laws ' of the State of California that the foregoing paragraph SH,RLFY GIGGLES is true and correct hfctir! ? ,.c California WITNESS hand d official seal i pa.� Los Ange,es County a z Cornmissir,. - 2'r3"t7 My Gomm G, Signature Sr e o Notary Aublic Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document Description of Attached Document Title or Type of Document Document Date Number of Pages Signer(s) Other Than Named Above Capacity(ies) Claimed by Signer(s) Signer's Name Signer's Name ❑Corporate Officer — Title(s) Corporate Officer — Title(s) 0 Partner — ❑ Limited [] General ❑ Partner — Limited � General ❑ Individual ❑Attorney in Fact ❑ Individual ❑Attorney in Fact ❑Trustee ❑Guardian or Conservator ❑Trustee ❑Guardian or Conservator ❑ Other L] Other Signer Is Representing Signer Is Representing 02014 National Notary Association •www National Notary org • 1-800-US NOTARY(1-800-876-6827) Item#5907