Loading...
HomeMy WebLinkAboutContracts & Agreements_63-2020PUBLIC WORK CONSTRUCTION CONTRACT This Public Work Construction contract ("Contract") is made and entered into this 15th day of April, 2020, by and between the City of Redlands, a municipal corporation, organized and existing under the laws of the State of California (hereinaftei "City"), and Three Peaks Corp hereinafter ("Contractor") City and Contractor are sometimes individually referred to herein as a "Party" and, together, as the "Parties " In consideration of the mutual promises contained herein, City and Contractor agree as follows SCOPE OF WORK- Contractor shall furnish all materials and will perform all of the work for the following Habitat restoration, soil reinforcement, vegetation planting, improvement installation, complete all items as required by the Contract Documents {as herein defined) and Specifications for City's Ford Park Upper Pond Restoration Project (the "Work") 2 CONTRACT SUM City shall pay Contractor the sum of sixty eight thousand four hundred twenty seven dollars fifty cents ($68,427 50) as consideration for its performance of the Work in accordance with the terms and conditions set forth in the Contract Documents Pursuant to Public Contract Code Section 22300, Contractoi has the option to deposit securities with an escrow agent as a substitute for retention of earnings required to be withheld by City pursuant to an escrow agreement as set forth in Public Contract Code section 22300 3 TIME FOR COMPLETION The Work shall be completed within forty-five calendar days (45) from and after the date of the delivery to Contractor of the Notice to Proceed by City 4 LIQUIDATED DAMAGES Contractor's failure to complete the Work within the time allowed will result in damages being sustained by City Such damages are, and will continue to be, impracticable and extremely difficult to determine Accordingly, Contractor shall pay to City, or have withheld from monies due to Contractor, the sum of Five Hundred dollars ($500) for each consecutive calendar day in excess of the specified time for completion of the Work Execution of this Contract shall constitute agreement by City and Contractor that Five Hundred Dollars ($500 ) per day is the estimated damage to City caused by the failure of the Contractor to complete the work within the allowed time Such sum is liquidated damages and shall not be construed as a penalty, and may be deducted from payments due the Contractor if such delay occurs 5 CONTRACT DOCUMENTS This Contract incorporates by reference the following Notice Inviting Bids, Instructions to Bidders, Contractor's Proposal, Bid Bond, Agreement, Performance Bond, Labor and Material Bond, Plans, General Conditions, Special Provisions and Specifications, and any addenda thereto (collectively the "Contract Documents") 6 ATTORNEYS' FEES: In the event any action is commenced to enforce or interpret the terms or conditions of the Contract Documents, the prevailing Party in such action, in addition to any costs and other relief, shall be entitled to recover its reasonable attorneys' fees, including fees for use of in-house counsel by a Party 7 RESOLUTION OF CONSTRUCTION CLAIMS Claims by Contractor in the amount of three hundred seventy five thousand dollars ($375,000) or less shall be made by Contractor and processed by the City pursuant to the provisions of Part 3, Chapter 1, Article 1 5 of the Public Contract Code (commencing with Section 20104) All claims shall be in writing and include the documents necessary to substantiate the claim Nothing in subdivision (a) of Public Contract Code L 1ca\djm\Agreements\Three Peaks Corp Public Work Contract 4 15 20 deep Section 20104 2 shall extend the time limit or supersede the notice requirements provided in this case from filmg claims by Contractor 8. ELIGIBILITY OF CONTRACTOR/SUBCONTRACTOR Contractor and all of its subcontractors shall abide by California Public Contract Code, Section 6109, and California Labor Code Sections 1777 1 and/or 1777 7, and certify that they are not debarred and are eligible to work on this project 9 ASSIGNMENT OF AGREEMENT No assignment by a Party of any rights or interests under this Contract shall be binding on another Party without the written consent of the Party sought to be bound 10. SUCCESSORS AND ASSIGNS: City and Contractor each binds itself and their respective successors and assigns in respect to all covenants, agreements, and obligations contained in the Contract Documents 11 SEVERABILITY: Any provision or part of the Contract documents held to be void or unenforceable under any law or regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and bmdmg upon City and Contractor L Icaldim\Agreements\Three Peaks Corp Public Work Contract 4 7 20 doc.jn IN WITNESS WHEREOF, the Parties hereto have executed this Contract the day and year first written above (SEAL) ATTEST. e Donaldson, City Clerk City of Redlands B W Foster, Mayor (SEAL) Name of Contractor By Signature o'r Au orized Agent Title Signature of Authorized Agent (if necessary) Title Contractor's License No L lcaldjmlAgreements\Three Peaks Corp Public Work Contract 4 7 20 doc.jn WORKER'S COMPENSATION INSURANCE CERTIFICATION Descnption of Contract City of Redlands Facihties and Community Services Department FCS01222020JB Ford Park Upper Pond Restoration Every employer, except the State, shall secure the payment of compensation in one or more of the following ways a By being insured against liability to pay compensation by one or more insurers duly authorized to write compensation insurance in this State b By securing from the Director of Industrial Relations, a certificate of consent to self - insure, either as an individual employer, or as one employer in a group of employers, which may be given upon furnishing proof satisfactory to the Director of Industrial Relations of ability to self -insure and to pay any compensation that may become due to his or her employees CHECK ONE I am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against liability for Workers' Compensation or to undertake self-insurance m accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work and activities required or permitted under this Agreement (Labor Code §1861) I affirm that at all times, in performing the work and activities required or permitted under this Agreement, I shall not employ any person in any manner such that I become subject to the workers' compensation laws of California However, at any time, if I employ any person such that I become subject to the workers' compensation laws of California, immediately I shall provide the City with a certificate of consent to self -insure, or a certification of workers' compensation insurance I certify under penalty of perjury under the laws of the State of California that the information and representations made m this certificate are true and correct Dated this4--- - day of , 2020 (SEAL) 0 actor) (Signature) (Official Title) (Labor Code Section 1861 provides that the above certificate must be signed and filed by the Contractor with the Owner prior to performing the work of the contract ) L lcaldjtn\Agreerents\Three Peaks Corp Public Work Contract 4 7 20 doc jn FAITHFUL PERFORMANCE BOND Bond No 24243522 Premium $985 00 Subject to Adjustment Based on Final Contract Price Whereas, the City of Redlands ("City"), State of California, and Three Peaks Corp (hereinafter designated as "Principal") have entered into an aglreement dated April 21, 20X20_ ( `Agreement") whereby Principal agrees to install and complete certain public improvements (the `Work"), which said Agreement is identified as Ford Park Upper Pond Restoration — FCS01222020JB and is hereby referred to and made a part hereof, and Whereas, said Pi incipal is required under the terms of the Agreement to furnish a bond fot the faithful performance of the Work, now, therefore, we, the Principal and, The Ohio Casualty Insurance Company , as Surety, are held and firmly bound unto the City in the penal sum of Sixty Eight Thousand Four Hundred Twenty* dollars ($ 68 427 50 ) lawful money of the United States, foi the payment of which sum we bind ourselves, and out heirs, successors, executors and administrators, jointly and severally, firmly by these presents *Seven & 50/100 The condition of this obligation is such that if the above bounded Principal, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and provisions in the Agreement and any alteration thereof made as therein provided, on his 01 its part, to be kept and performed at the time and in the mannei therein specified, and in all respects according to then true intent and meaning, and shall faithfully fulfill the one-year guarantee of all materials and workmanship, and shall defend, indemnify and save harmless the City and its elected officials, officers, agents and employees, as therein stipulated, then this obligation shall become null and void, otherwise it shall be and remain in full force and effect As a part of the obligation secured hereby and in addition to the face amount specified therefor, there shall be included costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligations, all to be taxed as costs and included in the judgment rendered As a condition precedent to the satisfactory completion of the Work, the above obligation shall hold good foi a period of one (1) year or longei if required by the Agreement after the acceptance of the work by the City, during which time if the Piincipal shall fail to make full, complete, and satisfactory repair and replacements and totally protect the City from loss or damage made evident dut ing this period from the date of completion of the Work, and resulting from oi caused by defective materials 01 faulty workmanship, the above obligation in penal sum thereof shall remain in full force and effect The obligations of Surety hereunder shall continue so long as any obligation of the Principal remains Whenever the Piincipal shall be, and is declared by the City to be, in default under the Agreement, the City having performed the City obligations thereunder, the Surety shall promptly remedy the default, oi shall promptly, at the City's option Complete the Work in accordance with its terms and conditions, or 2 Obtain a bid or bids foi completing the Work in accordance with its terms and conditions, and upon determination by Surety of the lowest responsive and responsible bidder, arrange foi a contract between such bidder and the City, and make available as work progresses sufficient funds to pay the cost of completion of the Work less the balance of the Agreement pi ice, C lUsersljrinartinlAppDatalLocallMicrosott\WindowsllNetCachelContent Outlool\MJOCAZVJ\Public Work Contract PW 3 1 doc but not exceeding, including other costs and damages for which Surety may be liable hereunder, the amount set forth above The term "balance of the Agreement price," as used in this paragraph, shall mean the total amount payable to the Principal iby the City under the Agreement and any modifications thereto, less the amount previously properly paid by the City to the Principal Surety expressly agrees that the City may reject any contractor or subcontractor which may be proposed by Surety in fulfillment of its obligations in the event of default by the Principal Surety shall not utilize the Principal in completing the Work nor shall Surety accept a bid from the Principal for completion of the Work if the City, when declaring the Principal in default, notifies Surety of the City's objection to the Principal's further participation in the completion of the Work No right of action shall accrue on the bond to or for the use of any person or corporation other than the City named herein or the successors or assigns of the City Any suit under this bond must be instituted within the applicable statute of limitations period The said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or to the work to be performed thereunder or the Specifications accompanying the same shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Agreement or to the work or to the specifications No final settlement between the City and the Principal shall abridge the right of any beneficiary hereunder whose claim may be unsatisfied The Principal and Surety agree that if the City is required to engage the services of any attorney in connection with the enforcement of this bond, each shall pay the City's reasonable attorneys' fees incurred, with or without suit, in addition to the above sum In witness whereof, this instrument has been duly executed by the Principal and Surety above named, on March 18 , 20)I 20 Three Peaks Corp (SEAL) (SEAL) The Ohio Casualty Insurance Company (contractor) (Surety) BY Ei in .ns Signature) Law i- McMahon (Signature) AtteIL Fact President Address 790 The City Drive South, Suite 200 Orange, CA 92868 (Seal and Notarial Acknowledgment of Telephone ( 714 )634-5712 Surety) C IUsersljrmartinlAppDatalLocallMicrosoft\Windows\INetCache\Content Outlook1MJOEAZVJ\Public Work Contract.PW-3 1 doc CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT Civil Code § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness accuracy or validity of that document STATE OF CAtIFORNIA County of San Diego / I On MA g 2020 before me, Janice R Martin , Notary Public, Date Insert Name of Notary exactly as it appears on the official seal personally appeared Lawrence F McMahon Name(s) of Signer(s) .. ;, -T.,.4,.,,,— im �- 3 '� ' y� ,` ` `",,, who proved to me on the basis of satisfactory evidence to be the person(f,) whose name* is/t/M subscribed to the within instrument and acknowledged to me that hetaterg / °'�executed the same in his/Jy f aiAlt authorized capacity{, , /j, JA�itC R. MARTIN IN and that byhis! COMM #2158352 TI hf, tJ itj signature4 on the instrument the'person(jj, or the entity upon behalf of which the person NOTARY PUBLIC CALIFORNIA „y acted, executed the instrument SAN fJiEGO COI��JTY t, My Commission Expires JULY29 2e29 1 certify under PENALTY OF PERJURY under the laws of `"�'„.=,.`'3."'m'., the State of California that the foregoing paragraph is true and correct Witness my hand and official seal Signa# Piece Notary Seal Above Signatures N Mary Public Janice R Martin OPTIONA L Though the information below is not required by law, tt may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document Description of Attached Document Title or Type of Document Document Date Number of Pages Signer(s) Other Than Named Above Capacity(ies) Claimed by Signer(s) Signer s Name Signer's Name ■ Individual ❑ Individual • Corporate Officer —Title(s) ❑ Corporate Officer Title(s) • Partner • Limited ■ General • Partner ❑ Limited ❑ General g Attorney in Fact ■ Trustee RIGHT THUMBPRINT ❑ Attorney in Fact OF SIGNER ❑ Trustee RIGHT THUMBPRINT OF SIGNER • Guardian or Conservator • Other Top of thumb here • Guardian or Conservator • Other Top of thumb here Signer is Representing Signer is Representing Surety Company Liberty Mutual Insurance Company The Ohio Casualty insurance Company West American Insurance Company --7/ r By / �J David M Carey Assistant Secretary State of PENNSYLVANIA County of MONTGOMERY ss On this 23rd day of October , 2018 before me personally appeared David M Carey who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance Company The Ohio Casualty Company and West Amencan Insurance Company and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia Pennsylvania on the day and year first above written COMMONWEALTH OF PENNSYLVANIA Notarial Seal Teresa Paslella Notary Pubtic Upper Merron Twp Montgomery County My Commission Expires March 28 2021 Member PenrsyInarna Aesociat on of Notaries By Ltdz,„) eresa Pastella Notary Pubic This Power of Attorney is made and executed pursuant to and by authority of the following By laws and Authorizations of The Ohio Casualty Insurance Company Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in hill force and effect reading as follows ARTICLE IV— OFFICERS Section 12 Power of Attorney Any officer or other official of the Corporation authonzed for that purpose in wnting by the Chairman or the President and subject to such limitation as the Chairman or the Prestdent may prescnbe shall appoint such attomeys-in-fact as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recograzances and other surety obligations Such attorneys -in fact subject to the limitations set forth in their respective powers of attorney shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation When so executed such instruments shall be as binding as if signed by the President and attested to by the Secretary Any power or authority granted to any representative or attorney in fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority ARTICLE XIII — Execution of Contracts Section 5 Surety Bonds and Undertakings Any officer of the Company authorized for that purpose in writing by the chairman or the president and subject to such limitations as the chairman or the president may prescnbe shall appoint such attorneys -in fact as may be necessary to act in behalf of the Company to make execute, seal, acknowledge and deliver as surety any and all undertakings bonds recogruzances and other surety obligations Such attomeys-in fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company When so executed such instruments shall be as binding as if signed by the president and attested by the secretary Certificate of Designation — The President of the Company acting pursuant to the Bylaws of the Company authonzes David M Carey, Assistant Secretary to appoint such attorneys -in fact as may be necessary to act on behalf of the Company to make execute seal acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations Authorization — By unanimous consent of the Company's Board of Directors the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds shall be valid and binding upon the Company with the same force and effect as though manually affixed I, Renee C Llewellyn the undersigned Assistant Secretary The Ohio Casualty Insurance Company Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the anginal power of attorney of which the foregoing is a full true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked IN TESTIMONY WHEREOF I have hereunto set my hand and affixed the seals of said Companies this 18th day of March , 2020 Liberty Mutual- SURETY This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated Liberty Mutual insurance Company The Ohlo Casualty Insurance Company West American Insurance Company POWER OF ATTORNEY Certificate No 8197174 KNOWN ALL PERSONS BY THESE PRESENTS That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the Companies } pursuant to and by authority herein set forth does hereby name constitute and appoint Janice Martin Lawrence r McMahon Sarah ivlyers all of the city of San Diego state of CA each individually if there be more than one named its true and lawful attorney in fact to make, execute seal acknowledge and deliver for and on its behalf as surety and as its act and deed any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons IN WITNESS WHEREOF this Power of Attorney has been subscribed by an authonzed officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 23rd day of Octobei 2018 a) 0 m o m N CD 0 0? CO O � a) o) �m zs ea O co -HO a --r rU O� C mN 0) N co L 43 o c o2 >o▪ 0i O c Z 0 m -o rn rn 6) rn a 0 0 U Lit E mQ 00 _ M "4' O (B O n5 L Q c) c o a) a) cs 75 >o 03 N E c9 c°D 00 0 EY LMS 12873 LMIC OCIC WAIC Multi Co 062018 0 By °enae C Lieweflyn Assistant Secretary Bond No 24243522 Premium is Included in Performance Bond LABOR AND MATERIAL BOND Whereas, the City Council of the City of Redlands, State of California, and Three Peas Corp (hereinafter designated as "Priv ipal") have entered into an agreement (the "Agreement') whereby Principal agrees to install and complete certain designated public improvements (the "Work"), which said agreement, dated April 21, 2020, and identified as Ford Park Upper Pond Restoration — FCS01222020JB is hereby referred to and made a part hereof, and Whereas, under the terms of the Agreement, Principal is required before commending the performance of the Work, to file a good and sufficient Labor and Material bond with the City of Redlands to secure the claims to which reference is made in Title 3 (commencing with Section 9550) of Part 6 of Division 4 of the Civil Code of the State of California Now, therefore, said Principal and the undersigned as corporate surety, are held firmly bound unto the City and all contractors, subcontractors, laborers, material men and other persons employed in the performance of the Agreement and referred to in the aforesaid Code of Civil Procedure in the sum of Sixty Eight Thousand*dollars ($68 427 50) for materials furnished or labor thereon of any kind, or for amounts due under the Unemployment Insurance Act with respect to such work or labor, that said surety will pay the same in an amount not exceeding the amount hereinabove set forth, and also in case suit is brought upon this bond, will pay, in addition to the face amount thereof, costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligation, to be awarded and fixed by the court, and to be taxed as costs and to be included in the judgment therein rendered *Four Hundred Twenty Seven & 50/100 It is hereby expressly stipulated and agreed that this bond shall insure to the benefit of any and all persons, companies and corporations entitled to file claims under Title 3 (commencing with Section 9550) of Part 6 of Division 4 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond Should the condition of this bond be fully performed, then this obligation shall become null and void, otherwise it shall be and remain in full force and effect The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or the specifications accompanying the same shall in any manner affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition In witness whereof, this instrument has been duly executed by the Principal and surety above named, on March 18 , 201(20 (SEAL) Three Peaks (SEAL) orp The Ohio Casualty Insurance Company {Contractor) (Surety) BY rik Simmons President (Signature) (Seal and Notarial Acknowledgement of Surety) Lawrence r McMahon Attorney in Fact (Signature) Address 790 The City Drive South, Suite 200 Orange, CA 92868 Telephone ( 714 ) 634-5712 C lUserslirmarhnlAppDatalLocal\MicrosoftlWindowslINetCachelContent.Outlook1MJOEAZVJ\Public Work Contract.PW-3 1 doc CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT Civil Code § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document, to which this certificate is attached, and not the truthfulness, accuracy or validity of that document STATE OF CALIFORNIA County of San Diego } on MAR t 8 2020 Date before me, Janice R Martin personally appeared Lawrence F McMahon Insert Name of Notary exactly as it appears on the official seal , Notary Public Names) of Signers) N (L COMM #2158352 tp '�`_ NOTARY PUBLIC -CALIFORNIA 11) n —„,” SAN DIEGO COUNTY (2 N'" My Commission Expires 44; JULY 2??, 2020 �z,�r ;: ;-WA-:-- �- "I Place Notary Seal Above who proved to me on the basis of satisfactory evidence to be the person(h whose name( ,+) is/ f, subscribed to the within instrument and acknowledged to me that he/#0100 executed the same in his/Of/Mit authorized capacity(f,)) and that by his/WOW signature{,) on the instrument the person(J. ), or the entity upon behalf of which the person() acted, executed the instrument I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct Witness mind and official seal Signet OPTIONAL Signatur otary Public Janice R Martin Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document Description of Attached Document Title or Type of Document Document Date Signer(s) Other Than Named Above Capacity(ies) Claimed by Signer(s) Signer's Name ❑ Individual ❑ Corporate Officer —Titles) Number of Pages E Partner ❑ Limited ❑ General • Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other Signer is Representing Surety Company RIGHT THUMBPRINT OF SIGNER Top of thumb here Signer's Name ❑ Individual ❑ Corporate Officer —Title(s) ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other Signer is Representing RIGHT THUMBPRINT OF SIGNER Top of thumb here Liberty Mutual SURETY This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company Certificate No 8197174 POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS That The Oh o Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the Companies"}, pursuant to and by authority herein set forth does hereby name constitute and appoint Janice Martin, Lawrence F McMahon, Sarah Myers all of the city of San Diego state of CA each individually if there be more than one named its true and lawful attorney -in fact to make execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 23rd day of October , 2018 rn a) a) _cn �m rnU oco a3� -0 _-0 c. o • m 6 O o c� co0) o co co E• � L o to •H L Zi e t4 c > v o Z o State of PENNSYLVANIA County of MONTGOMERY ss On this 23rd day of October 2018 before me personally appeared David M Carey who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer IN WITNESS WHEREOF I have hereunto subscribed my name and affixed my notarial seal at King of Prussia Pennsylvania on the day and year first above written By Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company David M Carey Assistant Secretary COMMONWEALTH OF PENNSYLVANIA Notarial Seal Teresa Pastella, Notary Public Upper MenonTwp. Montgomery County My Commission E Aires March 28 2021 Memher Pennsylvania Association of Notaries By e�«a Pe:�ei�. Notary Public eresa Pastella, Public This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company and West American Insurance Company which resolutions are now in full force and effect reading as follows. ARTICLE IV — OFFICERS Section 12 Power of Attorney Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys in -fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings bonds, recognizances and other surety obligations Such attorneys -in -fact, subject to the limitations set forth in their respective powers of attorney shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation When so executed such instruments shall be as binding as if signed by the President and attested to by the Secretary Any power or authority granted to any representative or attorney in fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority ARTICLE XIII — Execution of Contracts Section 5 Surety Bonds and undertakings Any officer of the Company authonzed for that purpose in wnting by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such attorneys -in fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations Such attorneys -in fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company When so executed such instruments shall be as binding as if signed by the president and attested by the secretary Certificate of Designation -- The President of the Company, acing pursuant to the Bylaws of the Company, authorizes David M Carey Assistant Secretary to appoint such attorneys -in fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations Authorization — By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds shall be valid and binding upon the Company with the same force and effect as though manually affixed. I Renee C Llewellyn the undersigned Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company and West American Insurance Company do hereby certify That the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked 1N TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 18th day of March , 2020 0) ta 0) rA -o c c 0 —E o W m E ac) o cri 0 I Q O 0) o0 7- c ▪ CO E 'eco o0 LMS 12873 LMIC OCIC WAIC Multi Co 362018 By ranee C Llewellyn Assistant Secretary