Loading...
HomeMy WebLinkAboutContracts & Agreements_99-2015_CCv0001.pdf PUBLIC WORKS CONSTRUCTION CONTRACT This Public Works Construction contract ("Contract") made and entered into this 19t11 day of May, 2015, by and between the City of Redlands, a municipal corporation organized and existing under the laws of the State of California, (hereinafter "City"), and AToM Engineering Construction, Incorporated (hereinafter "Contractor"). City and Contractor are sometimes individually referred to herein as a "Party" and, together, as the "Parties." In consideration of the mutual promises contained herein, City and Contractor agree as follows: 1. SCOPE OF WORK: Contractor shall furnish all materials and perfonn all of the work for the following: 2015 STORM DRAIN REPAIR PROJECT, complete all items as required by the Contract Documents (as herein defined) and Specifications for City's 2015 STORM DRAIN REPAIR PROJECT, Project No. 40087. 2. THE CONTRACT SUM: City shall pay Contractor the sum of$62,398.00 as consideration for its performance of the Work in accordance with the terns and conditions set forth in the Contract Documents. Pursuant to Public Contract Code Section 22300, Contractor has the option to deposit securities with an escrow agent as a substitute for retention of earnings requirement to be withheld by City pursuant to an escrow agreement as set forth in the Public Contract Code Section 22300. 3. TIME FOR COMPLETION: The Work shall be completed within 30 calendar days from and after the date of the delivery to Contractor of a written Notice to Proceed by City. 4. LIQUIDATED DAMAGES: Contractor's failure to complete the work within the time allowed will result in damages being sustained by City. Such damages are, and will continue to be, impracticable and extremely difficult to determine. Accordingly, Contractor shall pay to City, or have withheld from monies due to Contractor, the sum of$1,000 for each consecutive calendar day in excess of the specified time for completion of Work. Execution of the Contract shall constitute agreement by City and Contractor that $1,000 per day is the estimated damage to City caused by the failure of the Contractor to complete the Work within the allowed time. Such sum is for liquidated damages and shall not be construed as a penalty, and may be deducted from payments due Contractor if such delay occurs. S. CONTRACT DOCUMENTS: This Contract includes all of the Contract documents set forth herein, to wit; Notice Inviting Bids, Instructions to Bidders, Contractor's Proposal, Bid Bond, Agreement, Perfonnance Bond, Labor and Material Bond, Plans, General Conditions, General Requirements,Technical Specifications, and any addenda thereto. 6. ATTORNEYS' FEES: In the event any legal action is commenced to enforce or interpret the terns or conditions of the Contract documents, the prevailing Party in such action, in addition to any costs and other relief, shall be entitled to recover its reasonable attorneys' fees, including fees for use of in-house counsel by a Party. CD I 7. RESOLUTION OF CONSTRUCTION CLAIMS: Claims by Contractor in the amount of $375,000 or less shall be made by Contractor and processed by the City pursuant to the provisions of Part 3, Chapter 1, Article 1.5 of the Public Contract Code (commencing with Section 20104). All claims shall be in writing and include the documents necessary to substantiate the claim. Nothing in subdivision (a) of Public Contract Code Section 20104.2 shall extend the time limit or supersede the notice requirements provided in this case from filing claims by Contractor. 8. ELIGIBILITY OF CONTRACTOR/SUBCONTRACTOR: Contractor and all of its subcontractors shall abide by California Public Contract Code, Section 6109, and California Labor Code Sections 1777.1 and/or 1777.7, and certify that they are not debarred and are eligible to work on this project. 9. ASSIGNMENT OF AGREEMENT: No assignment by a Party of any rights or interests under this Contract shall be binding on another Party without the written consent of the Party sought to be bound. 10. SUCCESSORS AND ASSIGNS: City and Contractor each binds itself and their respective successors and assigns in respect to all covenants, agreements, and obligations contained in the Contract Documents. 11. SEVERABILITY: Any provision or part of the Contract documents held to be void or unenforceable under any law or regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon City and Contractor. CD 2 IN WITNESS WHEREOF, the parties hereto have executed this Agreement the day and year first written above. City of Redlands (SEAL) (Owner) By: Mayor, City of Redlands, County of San Bernardino, California ATTEST: City Clerk, ity f Redlands County of San Bernardino, California (SEAL) Name of Co 'tr ctor By: _ L Signature of Autho ' e Agent Title Signature of Authorized Agent(if necessary) Title gloa3gjq Contractor's License No. CD 3 WORKER'S COMPENSATION INSURANCE CERTIFICATION Description of Contract: City of Redlands Municipal Utilities & Engineering Department 2015 STORM DRAIN REPAIR PROJECT Project No. 40087 Labor Code, Section 3700, provides, in part that: "Every employer except the State shall secure the payment of compensation in one or more of the following ways: (a) By being insured against liability to pay compensation in one or more insurer duly authorized to write compensation insurance in this State. (b) By securing from the Director of Industrial Relations a certificate of consent to self- insure, either as an individual employer, or as one employer in a group of employers which may be given upon furnishing proof satisfactory to the Director of Industrial Relations of ability to self-insure and to pay any compensation that may become due to his or her employees. I am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against liability for worker's compensation or to undertake self-insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work of this contract. (Labor Code section 1861) Dated this �d day of , 2015. Contractor) lens— (Signa re) S' ( ficial Title) (SEAL) (Labor Code Section 1861 provides that the above certificate must be signed and filed by the Contractor with the Owner prior to performing the work of the contract.) CD 4 , CORRECTED ORIGINAL PREMIUM IS FOR CONTRACT TERM EXECUTED IN DUPLICATE AND IS SUBJECT TO ADJUSTMENT BASED ON FINAL CONTRACT PRICE BOND NO. CSB0023601 PREMIUM: $$1,560.00 FrATTTTFUL PERFOF..MANCE BOND Whereas, the City of Redlands ("City"). Statc i>f California, and ATOM EnginecrinV Construction, bncenJ3)orat.ed (17Lre?E.nitfle1' designated as "Principal.") have entered into an agreement elated May 19, 2015 ("Agrec;in nt") whereby Principal agrees to install and complete certain public improvements (the "Fork"), which said Agreement is identified as 2015 STORM DRAIN REPAIR PRC)J1wur, Project No. 40087 and is hereby referred to and madc a part hereof; and Whereas, said Principal is rc:qu.ired under the terns of the Agreement to fitmish a bond for the faithful performatace. of tale A.arecinent, now, therefore, we, the Principal and CONTRACTORS BONDING AND INSURANCE COMPANY as Surcty, are held and firmly bound unto the City in the penal sutra of sixty two thousand three hundred ninety eight dollars and zero cents ($62,398,00) lawful nioney of the United States, for the payment of which sum we bind ourselves, and our heirs, succcssors, executors and administrators,jointly and severally, firmly by these presents. The condhion of this obligation is such that if the above bounded Principal, his or its heirs, executors. adrninistrattors, successors or assigns, shall in all things stand to and abide by, andwell and truly keep and perform the covenants, conditions and provisioris in the Agreement and any alteration thereof made as therein provided, on his or its part, to be kept and performed at the time and in the rnainner therein specified, and in all respects according to their true intent and meaning, and shall faithfully U1111 the one-year Guarantee of all materials and workmanship, and shall defend, indemnify and save harmless the City and its elected officials, officers,agents and employees, as therein stipulated, then this obligation,shall, become null and void; other-vise it shall be and remain in full force:and Effect. As a part of the obligation secured hereby and in addition to the face amount specified therefor, there shall be included costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in suLccssfully en-forcing such obligations, all to be tax as casts and included in the judgment rendered. As as condition prcoedcnt to the satisfactory completion of the Agreement, the above obHoation shrill hold good for a period of one (1) year or longer if required by the Agreement after the acceptance of the work by the City, during which time if the Principal shrill fail to make full, complete, and satisfactory repair and replacements and totally protect the: City frorn loss or damage made evident during this period from the; date of completion of the Work, and resulting rrorn or caused by detective'materials or faulty workmanship,the above obligation in penal sum thereof shard remain in fill fbrce acid efficct. `nie obligations of Surety heremider shall continue so long as any obligation of the Principal remains. Whenever the Principal shall be, and is declaired by the City to be, in default under the Agreement. the City halving perfon-ied this;City obligations thereunder, the Surety shall promptly remedy the default, or shrill promptly,at the City's option: 1. Complete the Agreement in accordance with its terns and conditions; or 2. Obtain a bid or bids for completing the: Agreement in accordance with its terms and conditions, and upon determination by Surety of the lowest responsive and responsible binder, arrange toe• ai contrast between such bidder and the City, and make available as work progresses sufficient funds to pay the cost of completion of the Work less the balance of the CD 5 Agrecrrient price. but not exceeding. including other costs and damages fur"high Surety may be lladhlc hereunder, the amount set I,Orth above. "1-lie terra "balance of the.Agreement price," as used iii this; para(mtph, sh dl meati the total amount payable to 'lie Principal by the Cite' under the Agrecincnt and any modifications thereto, less the amount previously prnperly paid by the City to the Principal. Surety expressly agrees that the City may reject any contractor or subcontractor "which may be proposed by Surety in fulfillment of its obligations in the event or default by the Principal. surcty shall not utilize the Principal in completing the Agreement nor shall Surety accept a bid room the Principal for completion of the Wnrk if the City, when declaring the Principal in :fefat:lt. notifiics Surety of the City's objection to the Principal's further participation in the completion of tine Work. No right of action shall accrue on the bond to or for the use of any person or corporation :ether than the City named herein or the successors or assigns of the City. Any suit under this bond ntust be instituted within the applicable statute of limitations period. The said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the term~ of the Agreement or to the work to be perCurmed thereunder or the Specifications acconipwiying the same shall in any "fay at-lect its obli atiors oil this bond, and it docs hereby waive notice of any such change, extension of time, alteration or addition to the terms fir the Agreement or to the work or to the specifications, No final settlement between the City and the Principal shrill abridge the richt of any beneficiary hereunder-whose claim may be unsatisfied" 'Ihe Principal and Surety agree that if the City is required to engage the -services of any attorney in connection with the enforcement of this bond; each shall pay the City's reasonable attorneys' fees incurred. -.with or x'thout suit, in addition to the above sun:. In 'kvitness whereof; this instrument has been duly executed by the Principal and Surety above nanned, on JUNE 01 2015. (SEAL) (SEAL) ATOM ENGINEERING CONSTRUCTION, INC. CONTRACTORS BONDING AND INSURANCE COMPANY {Ste) (SI Ilat�r Uf(:) Address: � MARK D.IATMLA,ATTORNEY-IN-FACT (Deal and Notarial Acknowiled--anent of Surety) 111 PACIFICA, SUITE 350, IRVINE, CA 92618 Telephone: ( 949 )-341-9169 CD 6 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California ) County of SAN DIEGO ) On 6/1/2015 before me, MICHELLE M. BASUIL, NOTARY PUBLIC Date Here Insert Name and Title of the Officer personally appeared MARK D. IATAROLA Name(&) of SignerH who proved to me on the basis of satisfactory evidence to be the person(s) whose names) is/ere subscribed to the within instrument and acknowledged to me that he/sey executed the same in his eir authorized capacity(+es),and that by his/49644e#signature(s)on the instrument the person(6), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. MICHELLE M. BASUIL WITNESS my hand and official seal. COMM # 2034911 SAN DIEGO COUNTY $ Signature y a NOTARY PUBLIC-CALIFORNIA z g MY COMMISSION EXPIRES Signature f Notary Public AUG. 24, 2017 Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: MARK D. IATAROLA Signer's Name: I I Corporate Officer — Title(s): ❑Corporate Officer — Title(s): '_I Partner — ❑ Limited ❑General ❑ Partner — Iu_I Limited ❑General I� Individual X Attorney in Fact ❑ Individual ❑Attorney in Fact 1 Trustee ❑ Guardian or Conservator ❑Trustee ❑Guardian or Conservator i 1 Other: ❑ Other: Signer Is Representing: Signer Is Representing: Q 02014 National Notary Association •www.Nationa[Notary.org • 1-800-US NOTARY(1-800-876-6827) Item#5907 RSI c f� POWER OF ATTORNEY anALICompany RLI Insurance Company 9025 N.Lindbergh Dr.[Peoria,IL 61615 Contractors Bonding and Insurance Company Pbone:(800)645-2402 I Fax:(309)689-2036 Know All Men by These Presents: That this Power of Attorney is not valid or in effect unless attached to the bond which it authorizes executed, but may be detached by the approving officer if desired. That this Power of Attorney may be effective and given to either or both of RLI Insurance Company and Contractors Bonding and Insurance Company,required for the applicable bond. That RLI Insurance Company and/or Contractors Bonding and Insurance Company, each Illinois corporations (as applicable), each authorized and licensed to do business in all states and the District of Columbia do hereby make,constitute and appoint: Mark D.Iatarola,Michelle M.Basuil,John Maloney.Helen Maloney,jointly or severally in the City of Escondido , State of California , as Attorney in Fact,with full power and authority hereby conferred upon him/her to sign, execute, acknowledge and deliver for and on its behalf as Surety, in general, any and all bonds, undertakings,and recognizances in an amount not to exceed Ten Million Dollars ( $10,000,000.00 }for any single obligation. The acknowledgment and execution of such bond by the said Attorney in Fact shall be as binding upon this Company as if such bond had been executed and acknowledged by the regularly elected officers of this Company. RLI Insurance Company and Contractors Bonding and Insurance Company, as applicable, have each further certified that the following is a true and exact copy of the Resolution adopted by the Board of Directors of each such corporation,and now in force,to-wit; "All bonds, policies, undertakings, Powers of Attorney or other obligations of the Corporation shall be executed in the corporate name of the Corporation by the President,Secretary,any Assistant Secretary,Treasurer,or any Vice President,or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or Agents who shall have authority to issue bonds, policies or undertakings in the name of the Corporation. The corporate seal is not necessary for the validity of any bonds, policies, undertakings,Powers of Attorney or other obligations of the Corporation. The signature of any such officer and the corporate seal may be printed by facsimile or other electronic image." IN WITNESS WHEREOF, RLI Insurance Company and/or Contractors Bonding and Insurance Company,as applicable,have caused these presents to be executed by its respective Vice President with its corporate seal affixed this 27th day of April,2015. RLI Insurance Company �Na�y''' "Poce CO � :� � ' •°�A'e Contractors Bonding and Insurance Company dy AL G0µP01¢440F+P Oq a v, 4 SEAL ,D SEAL .: = State of Illinois yo° •~} -' Roy C.Die Vice President SS .. 'S 1LLiNa�S„r'` (L 1 N d� ,,`. County of Peoria CERTIFICATE On this 27th day of April 2015 I, the undersigned officer of RLI Insurance Company, and/or before me, a Notary Public, personally appeared Roy C. Die , who Contractors Bonding and Insurance Company, each Illinois. being by me duly sworn, acknowledged that he signed the above Power of corporations, do hereby certify that the attached Power of Attorney is Attorney as the aforesaid officer of the RLI Insurance Company and/or in full force and effect and is irrevocable; and furthermore, that the Contractors Bonding and Insurance Company, and acknowledged said Resolution of the Company as set forth in the Power of Attorney, is instrument to be the voluntary act and deed of said corporation. now in force. In testimony whereof,I have hereunto set my hand and the seal of the RLI Insurance Company and/or Contractors Bonding and Insurance Company this 1 9T day of ,BINE M15 . RLI Insurance Company Jacqu ine M.Bockle Notary Public Contractors Bonding and Insurance Company NQTY "OFFICIAL SEAL" Roy C.Die Vice President PUSUC JACQUELINE NL.BOCKLER $�Fx QF mis[rrs COMMISSION EXPIRES 01114118 0456693020212 A0059115 CORRECTED ORIGINAL EXECUTED IN DUPLICATE BOND NO. CSB0023601 PREMIUM INCLUDED IN PERFORMANCE BOND LABOR A vD MATERIA.L BOND Whereas, the City C-uuneil of the City of l,edlands, State of California, and A'1•okf P.ngineering Construction, lncotpomed (hereinafter designaled as "Principar') have entered into an agreement (the "A grccni,mi") wllct-chy Principal aii Tees to Wall and c ompive certain designated public improvements (tile--Work,-). which said apmcmcm, dated May ori, 2011 :md identified as 20M STORNI DRAIN REPAIR PROJECT, Project No. 4(1()87 is hereby referred tui art! made a part hereof; and Whereas, under the tarns of the :l vcmmn, Principal is required before co;ntnending the performance of the WmI to file a good and suffleVent labor ,fuel NAmerial bond with the City of Redlands w sume sumthe ddrns to which reference is trade in Title 3 (mrarno cin__ with Section 9550) of Part 6 of Division 4 of the C•iail Code ofthe time of C:alifcm ia. NoNN, therefore. s<tici Principal and the undusigned as corporate surety, are held firmly bound unto the C by and a1l contractors, subcontractors, laborers, material 1-nen and other persons employed in the perti,rmance of the Al,rccnicm and referred to in the aforesaid Code. of Cavil Pavedurc in the sum of sixty two Thousand three hundred ninety eight dollars and zero cents ($02,398.00) for materials i'urnished or labor thereon of any kind, or for amounts due under the Unemploymcat Insurance ;let with respect to such work- or labor-, that said surety will Pay the same in an amount not exceeding the amount hereinabove set !«rth, and slsa in cafe shit is bmu,ltt upon this bond, will pay, in addition to the face amount thereof,costs and rmsonahle expenses and fees, including reckonable attot•neys' fees, incuxred by the City in successfully enforcing such *Hgahon, to be awarded and fixed by the court, and to be taxed as casts and to he included in the judgrent therein rendered. Ii is l:crehy expresmy stipultt ed and agrecd :hat this bond shall insure to the benefit of any and all perz�ons,companies and corporations entitled to no claims under Title:3 (commencing with Section 9550) of Part 6 of Mviskn 4 uFthe Civil Code, so as to give a right of action to kern or their assigns in any suit brought ulxm this bond, Should the condition of this bond be fully peribi-med, then this obligation shall become null and void. otherwise 4 shall be and rernain in :ell force and effect. The surety 1-lereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or tite specifications accompanying the same shall in any manner affect its obligations on this bond, and it does hereby waive notice ofany such change, extension of Time, alte:ratloll or addition. 1n witness whereof' this hIstnttnent has been duly etccuted by the Principal and surety above named, on JUNE 01 2015. (SEAL) (SEAL) AT M ENGINEERING CONSTRUCTION, INC. CONTRACTORS BONDING AND INSURANCE COMPANY f- C orthactr 0 BY: azure) (St<gnature t MARK D. IATARbLA,ATTORNEY-IN-FACT RNEY-IN-FACT Seal and Notarial :Acknow1cogenucnt of Sure(y} 111 PACIFICA, SUITE 850, IRVINE CA 92618 Telcphnne; ( 949 ) 341-9169 CD CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§ 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California ) County of SAN DIEGO ) On 6/1/2015 before me, MICHELLE M. BASUIL, NOTARY PUBLIC Date Here Insert Name and Title of the Officer personally appeared MARK D. IATAROLA Name(&)of Signero who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/tee subscribed to the within instrument and acknowledged to me that he/94e*# ey executed the same in hWherAheii authorized capacity0e6),and that by his/4eW44eif signature(s)on the instrument the person(e), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. MICHELLE M. BASUIL WITNESS my hand and official seal. 5 COMM# 203491 1 a SAN DIEGO COUNTY g �l l Z = � Si nature , '� NOTARY PUBLIC-CALIFORNIA Z MY COMMISSION EXPIRES Signature of Notary Public AUG. 24, 2017 Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: MARK D. IATAROLA Signer's Name: ❑Corporate Officer — Title(s): ❑Corporate Officer — Title(s): ❑Partner — LJ Limited ❑General ❑ Partner — ❑ Limited L1 General ❑ Individual ®Attorney in Fact ❑ Individual ❑Attorney in Fact ❑Trustee ❑Guardian or Conservator ❑Trustee ❑Guardian or Conservator E Other: ❑ Other: Signer Is Representing: Signer Is Representing: r ©2014 National Notary Association -www.NationalNotary.org - 1-800-US NOTARY(1-800-876-6827) Item#5907 RLI Ckic POWER OF ATTORNEY an RLI Company RLI Insurance Company 9025 N.Lindbergh Dr.I Peoria,IL 61615 Contractors Bonding and Insurance Company Phone:(800)645-2402 1 Fax:(309)689-2036 Know All Men by These Presents: That this Power of Attorney is not valid or in effect unless attached to the bond which it authorizes executed,but may be detached by the approving officer if desired. That this Power of Attorney may be effective and given to either or both of RLI Insurance Company and Contractors Bonding and Insurance Company,required for the applicable bond. That RLI Insurance. Company and/or Contractors Bonding and Insurance Company, each Illinois corporations (as applicable), each authorized and licensed to do business in all states and the District of Columbia do hereby make,constitute and appoint: Mark D.Iatarola,Michelle M.Basuil,John Maloney,Helen Maloney,iointly or severally in the City of Escondido , State of California ,as Attorney in Fact,with full power and authority hereby conferred upon him/her to sign, execute, acknowledge and deliver for and on its behalf as Surety, in general, any and all bonds, undertakings,and recognizances in an amount not to exceed Ten Million Dollars ( $1.0,000,000,00 )for any single obligation. The acknowledgment and execution of such bond by the said Attorney in Fact shall be as binding upon this Company as if such bond had been executed and acknowledged by the regularly elected officers of this Company. RLI Insurance Company and Contractors Bonding and Insurance Company, as applicable, have each further certified that the following is a true and exact copy of the Resolution adopted by the Board of Directors of each such corporation,and now in force,to-wit: "All bonds, policies, undertakings, Powers of Attorney or other obligations of the Corporation shall be executed in the corporate name of the Corporation by the President,Secretary,any Assistant Secretary,Treasurer,or any Vice President,or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or Agents who shall have authority to issue bonds, policies or undertakings in the name of the Corporation. The corporate seal is not necessary for the validity of any bonds, policies, undertakings,Powers of Attorney or other obligations of the Corporation. The signature of any such officer and the corporate seal may be printed by facsimile or other electronic image." IN WITNESS WHEREOF,RLI Insurance Company and/or Contractors Bonding and Insurance Company,as applicable,have caused these presents to be executed by its respective lice President with its corporate seal affixed this 27th day of Anri1,2015. ,1`„,Iglellllly,,,r ,, RLI Insurance Company G AND .�” "Ca eas,A. Contractors Bonding and Insurance Company =r` SEAL ;= = SEAL State of Illinois fZo� ' •.,,,,. •tom; - Roy C.Die Vice President S$ LLINOI •• LINO IND /I,��Inrulnn,INr`' County of Peoria CERTIFICATE On this 27th day of April 2015 I, the undersigned officer of RLI Insurance Company, and/or before me, a Notary Public, personally appeared Roy C. Die who Contractors Bonding and Insurance Company, each Illinois being by me duly sworn, acknowledged that he signed the above Power of corporations, do hereby certify that the attached Power of Attorney is Attorney as the aforesaid officer of the RLI Insurance Company and/or in full force and effect and is irrevocable; and furthermore, that the Contractors Bonding and Insurance Company, and acknowledged said Resolution of the Company as set forth in the Power of Attorney, is instrument to be the voluntary act and deed of said corporation, now in force. In testimony whereof,I have hereunto set my hand and the seal of the RLI Insurance Company and/or Contractors Bonding and Insurance Company this I ST day of .TUNE , 2015. RLI Insurance Company Jacqu ine M.Bockle Notary Public Contractors Bonding and Insurance Company `OFFICILSEAL" Roy C.Die Vice President JACQUELINERCOMMISSION EO oassssaozoziz A0059115