Loading...
HomeMy WebLinkAboutContracts & Agreements_209-2014_CCv0001.pdf PUBLIC WORK CONSTRUCTION CONTRACT This Public Work Construction Contract ("Contract") is made and entered into this 22"d day of October, 2014, by and between the City of Redlands, a municipal corporation, organized and existing under the laws of the State of California(hereinafter"City"), and Allison Mechanical, Inc. (hereinafter "Contractor"). City and Contractor are sometimes individually referred to herein as a "Party" and, together, as the"Parties." In consideration of the mutual promises contained herein, City and Contractor agree as follows: 1. SCOPE OF WORK: Contractor shall furnish all materials and will perform all of the work for the following: AK SMILEY LIBRARY HVAC UPGRADE, PROJECT NUMBER QOL08212014KG, complete, as required by the Contract Documents (as herein defined) and Specifications for City's AK SMILEY LIBRARY HVAC UPGRADE (the"Work"). 2. CONTRACT SUM: City shall pay Contractor the sum of Ninety One Thousand Four Hundred Fifty Three Dollars ($91,453.) as consideration for its performance of the Work in accordance with the terms and conditions set forth in the Contract Documents. Pursuant to Public Contract Code Section 22300, Contractor has the option to deposit securities with an escrow agent as a substitute for retention of earnings required to be withheld by City pursuant to an escrow agreement as set forth in Public Contract Code section 22300. 3. TIME FOR COMPLETION: The Work shall be completed within ninety (90) calendar days from and after the date of the delivery to Contractor of the Notice to Proceed by City. 4. LIQUIDATED DAMAGES: Contractor's failure to complete the Work within the time allowed will result in damages being sustained by City. Such damages are, and will continue to be, impracticable and extremely difficult to determine. Accordingly, Contractor shall pay to City, or have withheld from monies due to Contractor, the sum of Five Hundred Dollars ($500) for each consecutive calendar day in excess of the specified time for completion of the Work. Execution of this Contract shall constitute agreement by City and Contractor that Five Hundred Dollars ($500) per day is the estimated damage to City caused by the failure of the Contractor to complete the Work within the allowed time. Such sum is liquidated damages and shall not be construed as a penalty, and may be deducted from payments due the Contractor if such delay occurs. 5. CONTRACT DOCUMENTS: This Contract incorporates by reference the following: Notice Inviting Bids, Instructions to Bidders, Contractor's Proposal, Bid Bond, Agreement Perfonnance, Labor and Material Bond, Plans, General Conditions, Special Provisions and Specifications, and any addenda thereto (collectively the"Contract Documents"). 6. ATTORNEYS' FEES: In the event any action is commenced to enforce or interpret the terms or conditions of the Contract Documents, the prevailing Party in such action, in addition to any costs and other relief, shall be entitled to recover its reasonable attorneys' fees, including fees for use of in-house counsel by a Party. 7. RESOLUTION OF CONSTRUCTION CLAIMS: Any claims by Contractor in the amount of Three Hundred Seventy Five Thousand Dollars ($375,000) or less shall be made by Contractor and processed by the City pursuant to the provisions of Part 3, Chapter 1, Article 1.5 of the Public IAca\djm\Agreements\Allison Mechanical Contract Smiley Library HVAC 11.4.14.doc and processed by the City pursuant to the provisions of Part 3, Chapter 1, Article 1.5 of the Public Contract Code (commencing with Section 20104). All claims shall be in writing and include the documents necessary to substantiate the claim. Nothing in Public Contract Code Section 20104.2 shall extend the time limit or supersede the notice requirements provided for the fling of claims by Contractor. 8. ELIGIBILITY OF CONTRACTOR/SUBCONTRACTOR: Contractor and all of its subcontractors shall abide by Public Contract Code Section 6109 and Labor Code sections 1777.1 and/or 1777.7, and certify that they are not debarred and are eligible to perform the Work. 9. ASSIGNMENT OF AGREEMENT: No assignment by Contractor of any rights or interests under this Contract shall be binding on City without the prior written consent of City. 10. SUCCESSORS AND ASSIGNS: City and Contractor each binds itself and their respective successors and assigns in respect to all covenants, agreements, and obligations contained in the Contract Documents. 11. SEVERABILITY: Any provision or part of the Contract Documents held to be void or unenforceable under any law or regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon City and Contractor. I:\ca\djm\Agreements\AlIison Mechanical Contract Smiley Library HVAC 11.4.14.doc IN WITNESS WHEREOF, the Parties hereto have executed this Contract the day and year first written above. City of Redlands (SEAL) By:jA— Pete A—guilar, ayor ATTEST: Sarn hwin, eta lerk E."k L) 01,4 /L"t' Allison Mechanica I,Inc. Signat of Authorize("gent i -J/1 L Title I.." Signature of Authorized Aigent(if necessary) Title Contractor's License o. f:'kc,-,tY,(Ijni',,Agreements\Allist)n Mechanical Contract Sunley Library 14VAC 11,4.14,doc WORKER'S COMPENSATION INSURANCE CERTIFICATION Description of Contract: City of Redlands–Quality of Life Department AK Smiley Library HVAC Upgrade,Project Number QOL08212014KG Every employer, except the State, shall secure the payment of compensation in one or more of the following ways: a. By being insured against liability to pay compensation by one or more insurers duly authorized to write compensation insurance in this State. b. By securing from the Director of Industrial Relations, a certificate of consent to self-insure, either as an individual employer, or as one employer in a group of employers, which may be given upon furnishing proof satisfactory to the Director of Industrial Relations of ability to self-insure and to pay any compensation that may become due to his or her employees. CHECK ONE I am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against liability for Workers' Compensation or to undertake self-insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work and activities required or permitted under this Agreement. (Labor Code §1861). I affirm that at all times, in performing the work and activities required or permitted under this Agreement, I shall not employ any person in any manner such that I become subject to the workers' compensation laws of California. However,at any time, if I employ any person such that I become subject to the workers' compensation laws of California, immediately I shall provide the City with a certificate of consent to self-insure,or a certification of workers' compensation insurance. I certify under penalty of perjury under the laws of the State of California that the information and representations made in this certificate are true and correct. Dated this day of 2014. (Contr ct ) —^ (Signatu/r :2 192 ( fficial Title) (SEAL) Labor Code Section 1861 provides that the above certificate must be signed and filed by the Contractor with the Owner prior to performing the work of the contract.) l:\ca\djm\Agreements\Allison Mechanical Contract Smiley Library HVAC 11.4.14.doc ttf fllfkt UM igPREDICATED ON ;WE MAI COWRACT PRICE AND ORIGHNAL ,'3t! ,1CJr,r,,T t16 Ar hJSIMENT IS UM IN TWO ORIGINAL COL7IT R ARTS BOND lupe. 024058564 COUNTERPART NO. CJS PR MIM $1,317.00 FAITHFUL PERFORMANCE BOND Whereas, the City of Redlands, C'City"}, State of California, and Allison Mechanical, Inc, (hereinafter designated as "Principal")have entered into on agreement dated November 4,2014 "Agreement")whereby Principal agrees to install and complete certain public improvements (the"Work"),which said Agreement is identified as Ali SMILEY LIBRARY RAC UPGRADE Project Number QOL 8 1 014 C and is hereby referred to and made a part hereof,and Whereas, said Principal is required ander the terms of the Agreement to furnish"a bond for the faithful performance of the Agreement,now,therefore, e,the principal and tab ,as Surety,are held and firmly bound unto the City in the penal sura of Ninety One Thousand Four Hundred Fifty Three ($91,453.)lawful money of the united States,for the payment of which sutra"vro bind ourselves,and our heirs,successors,executors and administrators,jointly and severally,firmly by these presents, (1) The Ohio Casualty insurance Company The condition of this obligations is such that if the above bounded Principal, his or its heirs, executors, administrators,successors or assigns,shall in all things stared to and abide by,and avelt atad truly keep and perform the covenants,conditions and provisions in the Agreement and any alteration thereofaxxade as therein provided,on his or its part,to be kept arid performed at the time and in the manner therein specified,and in all respects according to their true intent and meaning, and shall faithfully fulfill the one-year guarantee of all materials and workmanship, arid shall` defend, indemnify and save barmless the City and its elected officials, officers, agents and employees, as therein stipulated,then this obligation shall become null and void;otherwise it shall be and remain in full forcc and effect. As a part ofthe obligation secured hereby'and in addition to the face amountspecified therefor,there shall be. included costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the. City in successfully enforcing such obligations,all to be taxed as costs and included in;the judgment rendered,; As a condition precedent to the satisfactorycompletion of the Agreement,the above obligation shall hold good for a period of cane(t)year or longer if required by the Agreement after the acceptance of the work by the City,;during' which time if the Principal shall fail to snake full,complete,arid satisfactory repair and;replacements and totally protect the Cityfrom lass or damage made evident during this period from the date of completion of the Work, and resulting from or caused by defective materials or faulty workmanship the above obligation in penal sunt thereof shall remain in full force and effect. The obligations of Surety hereunder shall continue so long as any obligations of the Principal retrains; Whenever the Principal shall be,and is declared by the City to be,in default cinder the Agreement,the Pity having performed the City obligations thereunder, the Surety shall promptly remedy the default,or shall promptly,at the City's option, L Complete the Agreement in accordance with its tents and conditions;or 2, Obtain a bid or bidet for completing the Agreement in accordance with its tennis and conditions,and upon determination by Surety of the lowest responsive and responsible bidder,arrange for a contract between such bidder and the City,"acrd make available as work progresses sufficient funds to fray the cost of completion of the Mork less the balance of the Agreement price,but not exceeding,including ladies•assts and damages for which Surety may be liable hereunder,the amount set forth above, The to "balance of the Agreement lance,"as used in this paragraph,shall mean the tectal amount payable to the Principal by the City under the Agreement and any modifications thereto, less the amount previously properly!said by the City to the Principal. Surety expressly agrees that the City may reject any contractor or subcontractor which may be proposed by Surety in fulfillment of its obligations in the event ofdefault by the Principal, Surety .shall not utilize the Principal in completing the Agreement nor shall Surety accept a laid from the Principal for completion of the Work if the City,when declaring the Principal in default,notifies Surety of the City's objection to the Principal's further participation in the,completion of the Work, No right of action shall accrue can the bond to or for the use of any person or corporation other than the City named herein or the successors or assigns of he City. Any suit under this brand must be instituted within the applicable statute of limitations period. I:\cMdJm\AgreememskA1lison Mechanical Contract Smiley Library HVAC tIAA 4. oc The said Surety;for value received,hereby stipulates and agrees that no change,extension Of tire,alteration or addition to the teras of the Agreement or to tire work to be performed thereunder or the Specifications accompanying the sante shall in any way affect its obligations on this bond, and it dries hereby wive»Mace of any such change, extension of time,alteration or addition to the terms of the Agreement or to the work or to the specifications, No final settlement between the City and the.principal shall abridge the right of any beneficiary hereunder whose claim may be unsatisfied. The Principal and Surety agree that of the City is required to engage the services of any attorney in connection with the enforcement of this_bond,each shalt}gay theCity's reasorrat le attorneys'fees incurred,with or vrithot t strit,in addition to the above,surra, In witness whereof, this instrument has been duly executed by the Principal and Surety above named, on October 27 2014 Allison isort P3 ctaaraica2, Inc The ohio casualty insurance company 19SS r e Tsat�xG, ? CA 37 9325 Skypark Ct., Suite 200, San Diego, CA 92123 (858)2 Sy d Sy is 3u1` B. Gladding, Attorney Lkca�djrrAAgreernentsWlison Mechanical Contract Smiley Library 14 AC 11A14,do THIS IPOWER,OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED RED BACKGROUND. This Powitirof,attorney limits the acts of those named herein,and they have no authority to bind the Company except in the imannerand to the extent herein stated, Certificate No c329066 American Fire and Casualty Company Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company ISSUED tNC CRTC t QS COUNTERPART C No. (7I BOND NO. 024058554 POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS`.: That American Fire&Casualty Company and The Ohio Casualty insurance Company are corporations duly organized under the laves of the State of New Hampshire;that Liberty Mutual Insurance Company is a corporation duly organized under the law of the State of Massachusetts,and Mat American Insurance Company is a corporation duly organized gander the laws of the State of Indiana therein collectively called the"Colne les"),pursuant to and by authority herein set forth,does hereby name,constitute and appoint, Christta r r I.Torres Julia .tldin Kenrietfr A.Coate all of the city of Riverside state of CA' each individually if there be more than one named,Its true and lawful attorney-in-fact to make,execute,seal,acknowledge and deliver,for add on its behalf as surety and as its act and deed,any and all undertakings,bonds,recognizances and other surety obligations,in pursuance of these presents and shall be as binding upon the Companies asl f they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF,this Power of Attorney has been subscribed by an authorized officer or officol of the Companies and the corporate seals of the Companies have been afffxed- thereto this 25rar day of October ?c1 Ara American Fire and Casualty Company 10 The Otho Casualty Insurance Company Liberty Mutual Insurance Company West American Insurance Company By: STATE OF WASHINGTON sp Gr€go,� .Davenport,Assistant eerei-ary COUNTY OF KiNG Gln this 25111 day o€ October 3013,before personally appeared Gregory W. Davenport,lobo acknowledged himself to be the Assistant Secret of American as IF- 04) Fire and Casualty'Company.Liberty Mutual Insure Company,The Ohio Casualty Company,and West A i Insurance Company,and that hen as such, i authorized so to do, ' 462 exe3- Wcute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as duly authorized officer. IN WITNESS WHEREOF,I have hereunto subscribed my name and affixed my notarial seal at Seattle,Washington„on the day and year first above written, 010 y: KD Riley.Nit Public wdY This PowerofAttomey is made and executed pursuant to and byautherryofthe following By-laws andAuthorizations ofAmedcan Fire and Casualty Company,The Ohio Casualty Insurance iie Company,Liberty Mutual insurance Company,and WestAmerican Insurance Company Mich resolutions are nolo in full force and effect ruing as folk's � . dr ARTICLE IV-OFFICERS-Sections 12.Power of Attorney,Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President,and subject p to such limitation as the Chairman or the President may prescribe,shall appoint such attomeyss-in-fact,as may be necessary to act in behalf of the Corporation to make,execute,seal, o acknowledge and deliver as surety any and all undertakings,bonds recognizances and other surety obligators. Such atorrjeys-in-fact;subject to the limitations set forth in their respective;.5 powers of attorney,shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. Men so -(i executed,such instrurnemsshall be a binding asif signed by the Presidentand attested to by the Secretary.Any power or authority granted to any representative or y-in-fact under the provisions of this article may be revoked at any time by the Board,the Chairman,the President or by the officer or officers granting such pourer or authority, 4)0 q ARTICLE E All-Execution of Contracts-SECTION ,Surety Bonds orad Undertakings,Any officer of the Company authorized for that purpose in uniting by the chairman or the president, Co 9: and subject to such limitations as the chairman or the president may prescribe shall appoint such attorneys-in-fact„as may be necessary to act in behalf of the Company to make;execute, 04 seal,acknowledge and deliver as surety any and all undertakings,bonds,rectignizances and other surety obligations. Such attorneys-in-fact subject to the limitations set forth in their 0 respective powers of attorney,shall have full power to bind the Company by their signature and execution of any such instruments arta to attach thereto the seal of the Company, When so 00 executed such instruments shall be as binding as if signed by the president and attested by the secretary, to Certificate of Resignation-`Che President of the Company„acting pursuant to the Bylaws of the Company,authorizes Gregory W,Davenport,Assistant Secretary to appoint such alto ys-in-fact as may be necessary to act on behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings,binds;recogniz nces and other surety obligations. Authorization-Ey unanimous consent of the Company's Board of Directors,the Company consents that facsitirdle or machanicafly reproduced signature of any ass€scant secretary of the Company,wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds.shall be valid and briding upon the Company with the same force and effect as though manually affixed, I,David M,Carey,the undersigned,Assistant Secretary,of American Fire and Casualty Company,The Ohio Casualty insurance Company,Liberty Mutual Insurance Company,and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full,true and coned copy of the Power of Attorney executed by said Companies, is in full force and e0ect and has not been revoked. OCT 2 7 2D14 IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed the seals of said Companies this day of 20 y. David M.Care,Assistant Secretary 1 go of Start Lots 12873 092012 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State r California County of Riverside ^ before m , � h i D. Fisher, Ngtgry Pub]is .,. Her..In.u,f Name and TitC,rf1€ane'GBriac�r personally appeared Julia .aa�d,n(L — who proved to me on the basis ofsatisfactory evidence to he the perso !Anse nam is su s :r'i ed tri the within instrument grid acknowledged to tie that she/�_- executed the-same in- .i/her/tf e ulhori ed �r .capacity , and that by ' /herA . si n tureH on the ` COMM.#2028911 instrument the person(s), or the entity upon behalf of �{ CALIFORNIAwhich the person* acted, executed the instrument, RIVERSIDE COUNTY coffm i .2017 1 certliy under ISE'€ A13Y OF PERJURY Linder the law of the State of California that the foregoing paragraph is tale and Correct WITNESS my hind and official ;I, a ipn tUre _ PC ace Notary Seal b y S,gna, Re of n,N y PGbk OPTIONAL r hotrg h the information beflosfl is not required by kgvv, i1 my parva valuable to persons telyinp on the docurnpn and could Present fr oduant rerraov l and reattachment of th;s form to ati Miter document i es rkiptfort of Attached Document Titie or type e,Doctwneni: Document Date: � �. Tp _ Nurnber of Pages: € ner(s) Other Than Narned Aboves _---none ap&cAtoyr(le Claimed by Signer(s) Signer's flame:A_Jul ia B. G1addi nci Signer's 1 r�rrre: El i Individual' t.ji IndividUal L'' Corporate Officer—Till s : L-1 Psriner--0 Limited t` "ref Brat � :a t_:1 Partner --r 7 Urnited EJ General ��111­11 Attorney in P`,ret � �b t� [�srrasy ifr 1 apt Top of tr u .a her ,� Ton sr L, EI`trst l 1r`ufsten D GU rdian or Conservator 11 G[Jardian or Conservator Signer Is Representing- Signer Is Representiing _ .�­ 5�Ua arti,G €3�E PS f..tg a_rr a &R� nsn F✓C W C=, �t ¢ Iwie3rfii C, 5# as =v, eaare i PE.¢p, r I`s3 5kg.7 Rc 444 IoSSMKIM IS PREDICATED ON THE i~ingt SStRadT PICT AND ORIGINAL IS Slf Tf T TO AW11,ITMENT ECNO NO. 02405856 ISS,rD 114 TWO Cr I- NAL COUNTERPARTSPREMIUM: INCLUDED Zit THE PREMIUM COUNTERPART NO. OF CHARGED FOR THE PERFORMANCE BOND LABOR AND HATERIAL BOND Whereas,the City Council of the City of Redlands;State of California,and Allison Mechanical Inc.; (hereinafter designated as"Principal")have entered into an Agreement(the"Agreerrame')whereby Principal agrees to install and complete certain designated public improvements(the"Work"),which said agreement, dated'November 4 2014, and identified as AIC SMILEY LIBRARY k)SiAC UPGRADE-PROJECTi.MBER QOL0821201 €KG i hereby referred to and made a part hereof,an Whereas,ander the terms of the Agreement,Principal is required before commending the perfornxnance of Clic Work, to file a good and:sufficient Labor and Material bond with tate City of Redlands to,secure the claims to which: reference is made in Title T (commencing with Section 9550)of Part 6 of Invision 4 of the Civil Code of the:State o California, Now,therefore, said Principal and the undersigned as corporate surety,are held firmly bound unto the City and all contractors, subcontractors, laborers, material men. and Cather persons employed in the perforroance of the Agreement and referred to in the aforesaid Code of Civil Procedure in the sum of Ninety One Thousand Four hundred Fifty Three Dollars(S91,431)for materials famished or labor,thercorn of any kind; or for amounts due under the Unemployment Insurance Act with respect to such work or labor,that said:surety will pay the sane in an amount not exceeding the amount hereinabove set forth,and also in case'•,suit is brought Capon this bond, will pay,in addition to the face amount thereof,costs and reasonable expenses and fees;including reasonable attorneys' fees,incurred by the City in successfully enforcing such obligation, to be awarded and fixed by the court, and to be taxed as costs and to be included in the Judgment therein rendered, it is hereby expressly stipulated and agreed that this frond shall insure to the benefit of any and all persons, companies and corporations entitled to file claims under Title T(commencing with Section 9550)o f Part 6 of Division 4 of the Civil Code;so as to give a right of action to them or their assigns in any suit brought upon this bond. Should the condition of this bond be fully performed, then this ,obligation shall become mull and void, otherwise it shall be and remain in full force and effect. The surety hereby stipulates and agrees that no change,extension of time,alteration,or addition to the terms of the Agreement or the specifications accompanying the same shall in any manner affect its obligations on this bond,and it doses hereby waive notice of any such change,extension of time,alteration or addition: In witness whereof, this instrument has been duly executed by the Principal and surety above named, on octLber,27 2014 (SEAL) 1 (SEA Allis Mechanical, , n P � T tahio casu,lty insurance rampaal (C actor) t+ utefiy x � (S great,, ) (SignCss, 932S EiaB�. zaodrA taxn In-HAddrrk Ct,, Suite 2rlta aCA 92123 (Seal and Notarial Acknowledgment edgment of Surety) Telephone(856) 255-3988 T:,ca\djr-an`t, grcernentsiAlfison Mechanical Contract Sa iiey Library HVAC 1 I.4.x4.dcoe I i �, � A i � P � . ,. _ .* � x _ - w '� �< � r • � a w - � - g • x r a � � � x a m, � '. 8 yl# i• ,'..� .. fig.. � }. a. .,. •. .. W w,. � ,,: w .. � 4 s w: t r ati � ... - .� ., - � $. i', * e... � t .. 8 a. 4 � R �..,,. a .,�i .-. 4 m k a +� � M m fi ! ti � M r CALIFORNIA ALL aa, State of California County of Riverside __OCT 2_ tyeti —Stephanie D. iLster �Icrt�r FtstaTf� On larr rye, tp _ _ —T m Hem Inserr r Na.ne anr�'trtte�1.@;��7Sr,rn..t personally appeared Jul i a B. Cl addi Namos)Ua S jilrega) who prove to me on the basis of satisfactory evidence t be the persor1("whose narniSUbscribed to the within instrument and acknowledged to me that 4+a/she/*i-ey executed the setae in4ils/her/iheif aulhorized capaartyr " r and that by `" /hobibeir signature(s) on the .#'2028911 instrument Atha; etsan�, car the entity capon behalf of NOTtw �PUBLIC- as ,a which theperson(e)acted, execUtecl the instrument, E trVV0 N my conmkm is, pi I certify Linder PENALTY OF PERJURY under the laws of the State of California that the foregoing pearacJraph is true and correct. WITNESS my hand and official s )�. Signature— Race Notary Seat*Above sagr`,ttrar _— — OPrIONAL drtrarcgh the inform,ad"on below is not required by tarn it rr"rayprove v altrirrle to persons relying on the docurnent' atrrt MUM pAvent fraudutent roaaroval and reaHactrrtrerft ref tial;forfn to another ctnnrar ent Desevil2tion of Attached Docuniant Tit[a or Type of Doctfrnenic Document Crate: � _ .. � Number of Pages- Signer(s) f Pages:Sign r(s) Other Than c ert Above r none Conpa'City lr Claimed by t tgnrer Signer's N arae: Jul i . B. Glad!lLf _ Signer's Narnc:.:H._ El Individual 'D individual' F-1 Corporate'Officer--Title(s): .. LJ Corporate Offi r _-Title(s)-- 0, tle(s).0, Partner---0 Limited 0 General tai Partner--F Llr„nru-rd LJ General L Attorney in t=act EAttorney In Fact 0 6t ._ __ - tarrt aurni) re Top, or thumb here ' 1ruste l Guardian or Conservator FUarrtaor Conservator Other: [.3 ther: Signer Is Representing: Signer I ke iles m .u�y,� .. '�s,'t.vv't.G�p ti,*,�u-..`v'�. "."..:. ""-&"," __rw,... ::._^'�,'�w �-�.,._ >..:.,.w`� ..W. ",:e _ 'a.�.:r==.`:s_.�vM v'r``_vw.`u• _ _."."+. .��.�wt:. 0,2007 @ rafio A Noary a;„on,Geta.Q35q De Solo rave.