HomeMy WebLinkAboutContracts & Agreements_26-2011_CCv0001.pdf PUBLIC WORK CONSTRUCTION CONTRACT
This Public Work Construction contract ('Contract'') made and entered into this_15 _day of March,
2011, by and between the City of Redlands, a municipal corporation organized and existing under the
laws of the State of California, (hereinafter "City"), and KAD Paving Company (hereinafter
"Contractor"), City and Contractor are sometimes individually referred to herein as a"Party" and,
together, as the"Parties."
In consideration of the mutual promises contained herein, City and Contractor agree as follows:
1. SCOPE OF WORK: Contractor shall furnish all materials and perform aft of the work for the
following: construction of 2009-2010 Pedestrian Ramp and Sidewalk Infill Project, Contract
No. 243300-43027, complete all items as required by the Contract Documents(as herein defined)
and Specifications.
1 THE CONTRACT SUM: City shall pay Contractor the sum of$260,340.00 as consideration,for
its performance of the Work in accordance with the terms and conditions set forth in the Contract
Documents. Pursuant to Public Contract Code Section 22300, Contractor has the option to
deposit securities with an escrow agent as a substitute for retention of earnings requirement to be
withheld by City pursuant to an escrow agreement as set forth in the Public Contract Code
Section 22300,
3. TIME FOR COMPLETION: The Work shall be completed within Thirty(30)work days from
and after the date of the delivery to Contractor of a written Notice to Proceed by City.
4. LIQUIDATED DAMAGES: Contractor's failure to complete the work within the time allowed
will result in damages being sustained by City. Such damages are, and will continue to be,
impracticable and extremely difficult to determine, Accordingly, Contractor shall pay to City, or
have withheld from monies due to Contractor, the sum of Five Hundred Dollars($500) for each
consecutive calendar day in excess of the specified time for completion of Work.
Execution of the Contract, shall constitute agreement by City and Contractor that Five Hundred
Dollars ($500)per day is the estimated damage to City caused by the failure of the Contractor to
complete the Work within the allowed time. Such sum is for liquidated damages and shall not be
construed as a penalty, and may be deducted from payments due Contractor if such delay occurs.
5, CONTRACT DOCUMENTS: This Contract includes all of the Contract documents set forth
herein, to wit; Notice Inviting Bids, Instructions to Bidders, Contractor's Proposal, Bid Bond,
Agreement, Performance Bond, Labor and Material Bond, Plans, General Conditions, Special
Conditions, Special Provisions and Specifications, and any addenda thereto.
6, ATTORNEYS' FEES: In the event any legal action is commenced to enforce or interpret the
terms or conditions of the Contract documents, the prevailing Party in such action, in addition,to
any costs and other relief, shall be entitled to recover,its reasonable attorneys' fees, including fees
for use of in-house counsel by a Party.
7. RESOLUTION OF CONSTRUCTION CLAIMS: Claims by Contractor in the amount of
$3 75,000 or less shall be made by Contractor and processed by the City pursuant to the
C6 -1
provisions cit,Part 3, Chapter 1, Article L5 of the Public Conti-act Code (colunicticing with
Section 20104). All claims shall be in writing and include the docurnents necessary to
Substantiate the claim. Nothing in subdivision (a) of Public Contract Code Section 20104.2 shall
extend the time limit or supersede the notice requirements provided in this case fi-om filing
claims by Contractor.
8. ELIGIBILITY OF CONTRACTORI SUBCONTRACTOR: Contractor and all of its
subcontractons, shall abide by California Public Contract Code, Section 6109, and California
Labor Code Sections 1777.1 and/or 1777.7, and ecrtif,that they are not debarred and are eligible
to work on this prqject.
9, ASSIGNMENT OF AGREEMENT: No assignment by a. Party of any rights or interests under
this Contract shall be binding on another Party without the written consent of the Party sought to
be bound.
10. SUCCESSORS AND ASSIG,NS: City and Contractor each binds itself arid their respective
successors and assigns in respect to all covenants, agreements, and obligations contained in the
Contract Documents.
I I. SEVERABILITY: Any provision or part of the Contract documents held to be void or
unenforceable under any]a,.),, or regulation shall be deemedstricken, and all remaining provisions
shall continue to be valid and binding upon City and Contractor.
CD-2
IN WITNESS WHEREOF, the, pat-ties hereto have executed this A-reen-ient the day and year first w'ritten
above,
City of Redlands
(SEAL) (OW11CO
fl,
-
Mayor, --------------
City of Redlands, County of
San Bernardino, California
ATTEST:
City C�Ier:k,. Cily, f Redlands
County of San Bernardino, California (SEAL)
NI
Name of Contractor
By: re "4K
S i-g-m-�reof Author d Aggent
A-) az
Title
Signature ofAuthorized Agent if necessary)
Title
Contractor's License No.
CD-3
Municipal Utilities and Engineering Department.
2009-2010 PEDESTRIAN RAMP AND SIDEWALK INFILL
PROJECT,PROJECT NO.2433004302
Labor Code;Section,3700,provides,in part that:
"Every employer except the Mate shall secure the payment of compensation in one or more of the following
ways.
(a) By being insured against liability to pay compensation in one or more insurer duly authorized
to write compensation insurance in this State.
(b)' By securing from the Director of Industrial Relations a>certificate of consent toself-insure,
either as an individual employer,or as one employer in a group of employers which may be
given upon furnishing proof satisfactory to the Director of Industrial Relations of ability to
self-insure and to pay any compensation that may become due to his or her employees.
I am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against
liability for worlt is compensation or to undertake self-insurance in accordance with the provisions ofthat Code,and
will comply with such provisions before commencing the p rfort once of the work of this contract.(LaborCode section
1861) ,
Dated this day of 2011
(Contractor)
e a,
(signature)
(Official Title)
(SEAL)
(Labor Cade Section 1861 provides that the above certificate roust be signed and filed by the Contractor with the
Owner for to performing the work ofthe contract.)
CD-
BOND NOC 20-SUR-210761
BOND PREMIUM 6,207.tio WHICH IS SUBJECT TO CHANGE BASED ON THE:rINAL CC7IaTRACT AMOUR T
BOND EXECUTED IN DUPLICATEOMNCE BOND'
Whereas, the City Council of the City of Redlands, State of California, and KAD Paving t.`mpanyaroma`ie;t
designated as"Principal")have entered into air an—eineat-,xhereby Principal agrees to ilastali;unci eoaa�lale€c certain
designated public improvements,which said a r ennent,_dined 2011 and identified asco ciion
of 009-2010 PEDESTRIAN RAMP AND SIDEWALK INTILL PROJECT, PROJECT NO. 0-
4302 7 is hereby referred to and iniade a part hereof;and
Whereas,said Principalis required gander the tens s of said agreement to furnish a bond foi-the performance of said
project.
Now,therefore,paid Principal tal a€Ick AAaRICAN SAFETY L.es iir rr syxahc cOMheld tlirlY boundPI � , e
unto the City of Redlands(hereinafter,call"City"),in the penal sicca of T OI-Ltt NQR I?�txT� r,11.��vs��[a�ttREI.1fti fsRED FORTY
--Dollars(,;)()oL4o.gq __.v.)lawful l raoric of the United States,for the psaytiient of> A-llich
:surra well and truly-to be facade; we bind ourselve=s, our heirs,successors, executors acid administrators jointly and
severally,firmly by these presents
The condition of this obligation is such that if the;-above bounded Principal,his or hers heirs,executors,administrator.;
successors or assigns, shall in all things stand to and abide by, and well and truly keep perform the covenants.
conditions and provisions in the said a reerneyzat and anyalteration,thereof made as thereinprovided,or his or their part,:
to be kept and perfortneid at the tiarie and in the mariner therein specified, and in all respects according to their tries
intent and nieaning,and shall defend,inters ify and save harmless the City, its elected officials,officers agents and'
employees,as therein stipulated.then this obligation shall become null arid void;otherwise its call be anti centum in full-
force and.effect.
As a part of the obli adon secured hereby and in addition the face amount specified therefore,there shall be included
costs and reasonable expenses and tees, including reasonable attorney's fees incurred by the City in successfully
enforcing.such obligation.all to be taped as coasts and included in azny judgyment rendered.
The surety hereby stipulates and agrees(flat ano`change,extension of time,alteration or addition to the tertius of aIle
iaagree rnent or to the work to be performed thereunder or the specifications accompanying the same shall in any%vise
affect its obligations on this botnd,and it does Hereby{waiver notice of any such change,extension of time.alteration or
addition to the terms of the agreement or to the work or to the specifications.
11
In witness whereof, this instrument has been duly executed by the Principal and surety above; named, on
MARC1 :9TH 2011
�A
K A I7 PAVING COMPANY"DBA K A D ENGINEERING A14 ERIC'AN SAI ETA`CASUALTY INSURANCE COMPANY
t�?Fd't'
(Contra ( irety) r
t r
' i r9attlre" — ail titre} r T,;w5[aLL,ICK.ATTOR_NE`r 4N-FAC'T
m ,
Address,-
2 5901
ddress:25941 C:AL.AIJA� t3oLLT VARr3,SUITE I081C'AT AE ySiA ;CA 91305'.
(Seat and Notarial=Acloaaen lecl sax tat of� Surety) t`el hone(1IItl,} s7I-Eo6o
y
D-5
ACKNOWLEDGMENT
State of California
COUnty of
Oil March 9, 2011 before me, Peter Austin :weft,
my PubLic
(insert name and title of the officer)
persornaHy appeared
who proved to me on the basis of satisfactory evidence to be the person(,*)whose name(X) iso'am
subscribed to the within instrument and acknowledged to me that he;**jeA4eV executed the same in
hiskye(ftek authorized capacity(ia*, and that by his/JovMkaix signature(s)on the instrument the
person{*), or the entity upon behalf of which the person(*)acted, executed the instrument,
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing
paragraph is true and correct.
WITNESS my hand and official seal. or PETER AUSTIN NEFF
C4 Cow*17"389
pw.Mf 010M
ORANGE COUNTY
SignatureCoe:
mw
(Seal)
NtYMRF,ist
20--'A i
�AM POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS that American fety Casualty Insurance Company has made, constituted and appointed. and by these
presents does make.,constitute arta amok
YUng T. Mullic k
is true and lawful attorney-irt-[aid,lot it and its name,ptace, and stead to emcute on behatf of the said Company,as surety. bonds.undertaking and
contracts of sunetyship to be given to
ALL OBLIGEES
provided that n bond or undertaking or c nr*act'of suredvahisr executed under this autlxynty styatl exceed in amount the sum of
Two ftundrectSix iy"fhousand t3srec Hundred Furry D ollar�($260,34000)
This Power of Attorney is granted ano is signed and sealed by faearinde under and by the authority of tate following Resduttun adopted by the hoard of
Directors of the Company of the a day of August,2DOG..
RESOLVED,that the Prealdent in conjunction with the Secretary of any Assistant Secretary may appoint a ittorneysgn-fad or agents with sumanty as
defined or' mited in the instrument evidencing the appointrrient is each ate,For and on'behalf of the Company.to execrate and deliver and aft the
seat of the Company to bands,undertakings.recognizances,and suratyship;obl%Wlcim of all kinds7 and said officers may remove any notch ey-in-
fact at agent and revoke any power of attorney previously granted to such persons.
RESOLVED FURTHER,that any bond,undertaking,recogriczance,or sur shad be valid and la fins upon the company when
(r}when signed by the PreWsrd or any M Preieident=and attested and seated (If a seal is required) by any Secretary or Assistant Secretary or tdli
when signed by the President or airy tdent or SAacretary or Assitilant Secretary,andcounter-signed and sealed t"ri a seat is rewired)by a darty
authorized attomeyan-fact or agent:or(ilio when duty executed and sealed(if a seal is required)by one or mote attorney- -fact or agents pursuantto
and within the limits of the authority eviidenced by the power of attorney issued by the Company to such person or persons-
RESOLVED FURTHER.that the signature of any authorized officer and the:seat of the Company may be affixed by facsimile to any power of rtttorney
lir c4mtffication thereof authotizitg the execration and delivery of any bond,undertaking,recognizance.or other suretyship obligations of the Company;
and such signature and seat when so used shalt have the same fore*and effeatts as though manually affbred_
IN WtTNESS t MEREOF,American Safety Casualty Insurance Company has caused its otliraai seat to be hereunto affbred,and theca presents to be
signed by Its President and attested by its Secretary this b'"day of August,2009
Arntrul Jain t " ., t xt Joseph 17. Jr
STATE OF GEORGIA ) �
COUNTY OF COBB � � ipe iiiia
On titin&slay of August,2009,before min personally come Joeceph D7 lo,Jr.,to me known.who,being by rile duly swom,dad depose and say that
he is the President of Arriorican Safety Casualty Insurance Camp",the corporation described in and which executed the above instru :than he
knows the seat of the said Gorporatiorr:that the' affixed to the said instrument is such corporate seal,that is was so affixed by order of the Board of
Directors of said corFore ion and that ha signed his name thereto by like order
w e
fAMI BAILEY
NotaryPu"ic,batt Ccn.,GA
MY syon Expires Aug, 13,2012 Ja y atlray; clary PulNlt
1,the unassigned.Secretary of Amerkain S*e4y Casualty Instu me Company, an 01dahoina corporation,EIC "EREeY CERTIFY,that the foregoing
and attached Powair of Attorney remains in hA force and has not been revoked;and firthitirrnoire that the Resolution of the Board of Directors,sant forth
ini the said Pewter of Attorney,is now in force
Signed and sealed in the City of Atlantal,in the State of Georgo Dated this O9,day of
s
1" Ambu lain
ORIGNALS OF THIS POWER OF ATTORNEY ARE PRINTED WITH RED NUMERICAL NUMBERS
DUPLICATES SHALL HAVE THE SAME FORCE AND EFFECT AS AN ORIGINAL ONLY WHEN ISSUED IN CONJUCTION WITH THE ORIGWAL
BOND NO,20-SUR-210761
BOND PREMIUM INCLUDED IN PERFORMANCE BOND
BOND EXECUTED IN DUPLICATE
LABOR AND MATERIAL BOND
Whereas., the City Council of the City of Redlands, State of California, and KAD Paving Company(hereinafter
desigtaated as-Principal")have entered into an agreement whereby Principal agrees to install and cornplcte certain
designated public improvements, which said ai're-, errient,dated _ 'tl 1. and identified as
2009-2010 Pedestrian Ramp andSidewalk Infill Prg:ject:,Project No.24330043027 is hereby referred to and made
a part hereof,and
Whereas,under the terms of'said agreement.Principal is required before entering upon the p r`,orsaaance ofthe word,to
tilt'a good and sufficient payment basad with the City of Redlands to secure the claims to which reference is made in
Title 1 (commencing with Section 30821)of Part 4 of Division 3 of the Civil Code:of the Mate ofCalifornia,
AMERICAN SAFETY CASUALTY INSURANCE COMPANY
Now, therefore, said Principal and the undersigned as corporate surety,,are held firraaly bound unto tire City of
Redlands and all contractors,subcontractors,laborers,material rival men and other persons employed in the performance of
the aforesaid agreement mid referred- to in the aforesaid Code of Civil Procedure in the surra of
T-wD Ff f n Ct SIS x*�StCaU +�FtRE HUNDRED FORTY Seltart'( st tae3 tr.tr ®)for rraaterials furnished or labor°tlaezccrrr ei#
any hind,or for amounts due under the Unemployment Insurance:pct with respect to such avork or labor, that said
surety will pray the saran in an arnourat not exceeding the atrttaunthereinabove set forth,and also in case suit is brought
upon this band, will tray; in addition to the face artaount thereof,costs and reasonable expenses and fees, includir
reasonable attorney's tees,incurred by the City of Redlands in successfully enforcin-such obligation,to be awarded
and fixed by the court,and to be taxed as costs and to be included in the judgment therein rendered,
3t is hereby expressly stipulated and agreed that this bond shall insure to the benefit of°any and all persons,companies
and corporations entitled to file claims under Title 15(con-arrencing with Section 3082)ofPart 4 of Division 3 of the
Civil Code,so as to give a right of'action to them or their assigns in any wait brought upon this bond
Should the condition of this board be fully perforined,then this obligation shall become null and void,othenvise it shall
be and remain in full fierce and effect.
The surety hereby`stipulates and agrees that no change,extension;o chase,altercation or addition to the terms of said
agreernCru or the specifications accompanying the:same shall in any marmer affect its obligations on this bond,and it
does hereby waive notice of arty such change,extension of time,alteration or addition.
In witness whereof, this instrument has been duty executed by the Principal and surety above named, on
;MARCH 9TH
(SEAL) (SEAL)
firs�'S'vC C Mtn vY t7F3 3 Is t7 E UIiVS S;RT
AMERICAN SAFETY CAS sI-TI SURf�^+C E C't7N N
)� - � .__
faantr C r.ar (Surety)
`t ,
�€
,rEraaraJre) Oi naturi)N'UNGT.MULLICK,,W-T3RN,EY-tN-FACT
Addressz390�Ai".'�BASAS BOULS VA D,SUITE 1085,C SLA€ASAS,CA 1302
(Seal andNotarial Acknowledgi-nent of`surety) T`elptaorae ..�i7r t-- .SSI rticao _,
-
ACKNOWLEDGMENT
State of California;
County of
On _. .e March rch 2011 before me; . Peter-Austin Neff Notag Puy lic
(insert name and title of the officer)
personally appeared a x unc T. My Ljllick
who proved to me on the basis of satisfactory evidence to be the person(:)whose name(s) is/MIA
subscribed to the within instrument and acknowledged to me that he/*teWxV executed the same in
his k authorized capacity ` , and that by hishmftak signature( ) on the instrument the
person(*), or the entity upon behalf of which the person(*)acted, executed the instrument.
1 certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing
paragraph is true and correct.
WITNESS my hand and official seal. � ��'���� PETER AUSTIN NEFF 11`x,#1
ORANGE COUNTY 01Y
My Cwft E*m MAY
'202
Signature (Seal
ItitfTtifi##tR
ry,l-aalt'-.,l lla-,1'a 1.
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS that Amerirart Safety Casualty Insurance Company has made, consfiluted and appointed, and by these
presents does make,cotssttttite and art mints
` 'ung T. Mullis:
its tare and lawful a torney-m-fact,hx it and Its name,place,and stead to execute on behalf of the said Company,as surety,bonds,undertaking and
contracts of suretyship to be given to
ALL 08L)GEES
provided that n bond or undedaktnp or contract of suretvahlo executed under this authority shall exceed in amount the sum of
I Wo ftuntlra:d Sixry'7Thoussastti Three Ilundlred Forly Dollars("260,40,W)
This Power of Attorney is granted and is"nod and sealed by taaaemalea under and by the authority of the following Kesoiution adopted by the Board of
Directors of the Company of the a day of August,20M.
RESOLVED,that the President In conjunction with the Secretary or any Assistant Secretary may appoint -in-fact or agents with authority as
defined or limited in the instrument evidencing lane appointment in each case, for and on behalf of the Company,to execute and clativer and affix tate
seal of the Company to banills,undertakings_recognizances,and suretyship otattolom of all kinds;and sad officers may remover any such 7ltorney-In-
fact or agent and revoke any power of attorney previomly granted to such perm.
RESOLVED FURTHER,that any bond,undertaking,racognizance,or suretyship obligation shall be valid and binding upon dw company when.
(1)when signed by the President or any Moo-Preeldent and attested and sealed (if a seal Is required)by any Secretary or Assistant Secretary or(JI)
when sgnsd by the President or any Vee-President or Secretary or Assistant Secretary,and counter-signed and sealed(r(a seal is required)by a duly
a attorney-in-fact or went;or�-vij when duly executed and sealed(d s saal Is required)by one or more attorney-tri-fact or ager#a pursuant to
and within the lantats of the authority evidenced by the poorer of attorney issued by the Company to such person or personas:
RESOLVED FURTHER.that the signature of any authorized officer and the seal of the Company may be affixed by facsimile to any pourer of attorney
or cattification,the sof authorizing the execution and delivery of any bond,undertaking,recognizance,or rawer suretyship obligations of the Company,
and such mature and seal when so tlssed shall have the:saine force and effects as though manually affiate d,
IN WITNESS WHEREOF,American Safety Casualty Insurance Company has caused Its official swil to be hereunto affixed,and these prosents to be
signed by its President and attested by Its Secretary this e day of August.2W9
Arntaul Jain .. # � Jt11 ph� r.
STAVE OF GEORGIA
}
COUNTY OF COSS
On Oak;ai'clay of August,2009,before me personally carne J ®.Sooilo,Jr,to me known,who,being by me duly sworn,did depose and say that
he Is the President of American Safety Casualty Insurance Company,the corporation described in and which executed the above instrument:that he
krews the seal of the said corporation,that the a"alffnted to the said instrurrtire is such corporate seal:that is was ser affixed by order of the Board sof
Directors of said corporattion and that he signed Na name thereto by like.older.
JAMI BAILEY
Notary Public,hall Co.,GA i. , ai#ey, otary Paro3lc
My Commission Expires Aug,13,2012
1,the undersigned,Secretary of American Safely Casualty lrarurance Company, an Gklahorn corporation,00 HEREBY CERTIFY,that the foregoing
and attached Power of Attorney remains in fiat!force and has not been revoked;and furthermore that the Resolution of the Board of Directors,sat forth
in the said mower of`Attorney,is now ri farce.
Signed and sealed in the City of Atlanta,in the Slate of C !gia + Dated thisO,9 day of
rZc ;
t r
, d
za: A.mbuj Jaen
j=lf,e69"
ORIGINALS OF THIS POWER OF ATTORNEY ARE PRINTED WITH REIN NUMERICAL NUMBERS
DUPLICATES SHALL HAVE THE SAME FORCE AND EFFECT AS AN ORIGINAL ONLY WHEN ISSUED IN CONJUCTION WITH THE ORIGINAL
4 4
t W
A}-
o !' 1200 060446*
At
A A..A. a 9111"42W
[ftnoh
R x s
MUM
KAD Paving Company
12113
l0th ,'k w
:.:.W i. 9230 r'
lotguRot State Corn AnsafloninsFund s.
r t
Of I it I
OCCUR
...
•A
`y 3
AUTOMOSILELIANUTY
AWA
4F. ISA30VISIt b !
:: OVMD.....F r .
IP
AUTOS:. a
MREOAUTOIS
•. MT08
ttt fit4
9HOULD ANY Or THE ABOVE DESMS"POLOE$Se CANCEUW WORE
City
of '" a W"
Cajon Street
diandsia, • ..
POLICY NUMBER: CBP3017155 COMMERCIAL GENERAL LIABILTY
CO 20 10 07 04
THIS ENDORSEMENT CHANGES THE POUCY, PLEASE READ IT CAREFULLY.
ADDITIONAL INSURED - OWNERS, LESSEES OR
CONTRACTORS - SCHEDULED PERSON OR
ORGANIZATION
This endorsement modifies insurance provided under the following-
COMMERCIAL GENERAL LIABILITY COVERAGE PART
SCHEDULE
Name of Additional Insured Person(s)
9r
O 0
raar�fzafi n(s): Location s)pfqqyere L
4_O"ratfons,
City of Redlands 1 2000-2010 Pedestrian Ramps and Sidewalk Infill
Proiect
Project#243300-43027
Information PN!it qto cornp!ete this Schedule,it not shown above,wilt be shown in the Declarations.
A. Section If — Who Is An Insured is amended to B. With respect to the insurance afforded to these
include as an additional insured the person(s) or additional insureds, the following additional exclu-
organization(s) shown in the Schedule, but only sions apply:
with respect to liability for "bodily Injury", 'property
damage or 'personal and advertising injury" This insurance does not apply to 'bodily injury" or
caused,in whole or in part,by: property damage'occurring after.
1. Your acts oromissions;or 1. All work, Including materials, parts or equip-
2. The acts or omissions of those acting on your ment furnished in connection with such work,
behalf, on the project(other than service, maintenance
or repairs) to be performed by or on behalf of
in the performance of your ongoing operations for the additional insured(s) at the location of the
the additional 1nsured(s) at the location(s) design covered operations has been completed-,or
nated above,
2. That portion of 'your work" out of which the
injury or damage arises has been put to its in-
tended used by any person or organization
other than another contractor or subcontractor
enGaged in performing operations for a pdnd-
pat as a part of the same project,
CG 20 10 07 04 ISO Properties, Inc.,2004 Page I of I
POLIO`NUMBED. CBP3017155 COMMERCIAL GENERAL LIABILITY
CG 20 37 07 04
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ADDITIONAL L INSURE1 — O'W'NERS, LESSEES R
CONTRACTORS COMPLETED OPERATIONS
This endorsement modifies insurance provided under the following-
COMMERCIAL
all ingll/M R I L GENERAL LIBILITY COVERAGE PART
SCH15 t1 E
Name of Additional Insured Person(s)
Or O a nization s f Location And Desciription of Completed O ratlon s
City of Redlands 2009-2010 pedestrian Ramps and;Sidewalk Infill
project
Project##24300-43027
Information required to complete this Schedule,if net shown above, will be shown in the DecIarations,
Section It — Who is An Insured is amended to
include as an additional insured theperson(s) or
organization(s)shown In the Schedule, but only with
reset to liability for.bodily injuryr or"property dam-
age' caused, in whole or in part, by 'your woW at
the location designated and described in the sched-
ule of this endorsement performed for that additional
insured and included in the "products-completed
operations hazard".
CG 20 37 07 04 0 ISO Properties, Inc,,2004 Page I of
CERTHOLDER COPY
090
P- , BOX 420807, SAN FRANCISCO,CA 94142-01947
CERTIFICATE OF WORKERS' COMPENSATION INSURANCE
ISSUE DATE. 03-102-2011 GROUP: 000236
POLICY NUMBER 0013694-2010
CERTIFICATE ICS- 97
CERTIFICATE EXPIRES. 06-12-2011
06-12-2010/05-12-2011
CITY OF REDLANDS SJ JOB:PRQ JECT #2+13300-43027
99 CAafON ST
REMANDS CA 92373-41146
This is to certify that we have issued a valid Workers' Compensation isriwance policy in a;form approved by the
California insurance Commissioner to the employer-named below for the policy period indicated
This policy Es not subject to cancellation by the Fund exc t upon 30 days advance written notice t0 the employer.
We wilt also give you 30 days advance notice should this policy be cancelled prior to its normal expiration.
This caFrtific2te of imsurutca is riot an ins ane policy and does not emend. extend or after the coverage afforded
by the policy listed herein. Notwithslandin any re%groment, term or condition of any contract or other document
with respect to which this certiflcata of �nsuranc® May be issued or to which it May pertain, the insurance
afforded by that policy described hereiri is subject to all the terms, exclusions, and conditions, of such policy.
i
Authorized Representative Prosident and CEO
EMPLOYER'S LIABILITY LIMIT INCLUDING OgPeMl! COSTS. $1,000,000 PER OCCURRENCE.
ENDORSEMENT #16OD WHEELER, DONALD P,S T - EXCLUDED.
ENDORSEMENT 02065 ENTITLED CERTIFICATE HOLDERS` NJYICE EFFECTIVE 05-24-2010 IS
ATTACHED TO AND FORMS A PART 0! THIS POLICY
EVPLOYEd
KAD PAVING COMPANY S
12173 10TH 'ST
YUCAIPA CA 92399
{B10,SJl
PRINTED : 03-02-2011
trt�v°,s-JiS tt�
ChLirch Street Well Rehahilitation On inoticaia of C'ouncilrnember Harrison,
seconded by Couneilnaentber lean, the City Council unatainIouSly aaztrecd that
rehabilitation of the Church Street- Well is excnapt from cilviroi niciatal
processing pursuant to C l; A Guidelines and approved as service aagrccmcnt
between the City of Redlands atltd Beit Drilling and Pump. Inc. to perforin the
rehabilitation work.
Air•trtart Wc:l1 1Cc:haafrilitaatico-tr - On motion of C'iruncilmember Harrison, seconded
b+v Councilmernber 11can, the City Council unan.mousty a-reed that
rehabilitation cat' the Airport No. 2 Well is exempt ti-orn euvironraacnt�al
processing, pursuant to C'UQA C iuidelines and approved a service agreement
between the City of Redlands and South West f'trnrp and Drilling Inc. to
perform the rehabilitation "ork.;
Sidewalk and Curb Improvement - On motion, cif' Councilnterrber Gardner,
seconded by Counc:ilmember f laarrison, the City Council unanimously agreed
that construction of the FY2009-2010 C BDG Sidewalk- and Curb Cut
Improvement Project is exempt from further environmental processing pursuant
to CT-.QA Guidelines. approved the Protect plans and specifications and awarded
as contract to KAD Paving Conrpaany to perfOrnt the work.
More Sidewalk Improyemetits - On motion of` Councilmernher C;ardner,
seconded by Councihnember Harrison, the City Council unanimously agreed
that constr'uctiora of the FY-2-010-2011 BM-1` Sidewalk and Curb Cut
Improvement Projca is exempt from further environmental processing pursuant
to ('FQA C iuidehnes. approved the Profeet plans and specifications and awarded
as contract to L'lanrco. Inc.to perform the work.
Mon: Sidewalk Improvements - On motion oaf` Cc>uncilmember Gardner,
seconded by Councilmember Harrison, the City Council unaninaouslyr agreed
that cora4trUCtion of the C BDG - Recovery Act - Cityavide Sidewalk and Curb
Cut Improvement Project, Phase 1l is exempt from further environnrentaal
processino pursuant to ('F-QA C;uidefines, approved tett~ Prca' ct plans arid
specifications and awarded as contract to KAD Paving Company to perforans the
work:
Water District Agreement - Oil motion of C ounclimember lean, seconded by
Canna ifrnember Hamson. tilt: City Council unanimously appr=oved a Stock
Purchase Option Agreement and a Shares Lease Agreement between the. City of
Redlands and the Sail Bernardino Valley Municipal Water District for the lease
with option to buy 10.000 shares ol'Beaar Valley Mutual Fater Company water
:;tock:
Fire Truck Purchase - Oil motion of C ouncilmer ber Harrison, seconded by
C.`ouncilmenibcr- Bean, the City C*ouncil unanimously aapprovcd a purchase
March 1,2011
Page 0