HomeMy WebLinkAboutContracts & Agreements_206-2015_CCv0001.pdf PUBLIC WORK CONSTRUCTION CONTRACT
This Public Work Construction contract ("Contract") is made and entered into this 3' day of
November, 2015, by and between the City of Redlands, a municipal corporation, organized and
existing under the Iaws of the State of California (hereinafter "City"), and Macadee Electrical
Construction, Inc. hereinafter("Contractor"). City and Contractor are sometimes individually referred
to herein as a"Party"and, together,as the"Parties."
In consideration of the mutual promises contained herein, City and Contractor agree as follows:
1. SCOPE OF WORK: Contractor shall filrnish all materials and will perform all of the work for
the following: Installation of new traffic signal cabinet for University Street and Citrus Street,
complete, as required by the Contract Documents (as herein defined) and Specifications for City's
Traffic Signal Cabinet at University Street and Citrus Street(the "Work").
2. CONTRACT SUM: City shall pay Contractor the sum of Sixty Six Thousand Nine Hundred
Sixty Nine Dollars ($66,969)as consideration for its performance of the Work in accordance with
the terms and conditions set forth in the Contract Documents. Pursuant to Public Contract Code
Section 22300, Contractor has the option to deposit securities with an escrow agent as a substitute
for retention of earnings required to be withheld by City pursuant to an escrow agreement as set
forth in Public Contract Code section 22300.
3. TIME FOR COMPLETION: The Work shall be completed within Ninety days (90) calendar
days from and after the date of the delivery to Contractor of the Notice to Proceed by City.
4. LIQUIDATED DAMAGES: Contractor's failure to complete the Work within the time allowed
will result in damages being sustained by City. Such damages are, and will continue to be,
impracticable and extremely difficult to determine. Accordingly, Contractor shall pay to City, or
have withheld from monies due to Contractor, the sum of Five Hundred Dollars ($500) for each
consecutive calendar day in excess of the specified time for completion of the work.
Execution of this Contract shall constitute agreement by City and Contractor that Five Hundred
Dollars ($500) per day is the estimated damage to City caused by the failure of the Contractor to
complete the work within the allowed time. Such stun is liquidated damages and shall not be
construed as a penalty, and may be deducted from payments due the Contractor if such delay
occurs.
5. CONTRACT DOCUMENTS: This Contract incorporates by reference the following: Notice
Inviting Bids, Instructions to Bidders, Contractor's Proposal, Bid Bond, Agreement Performance,
Labor and Material Bond, Plans, General Conditions, Special Provisions and Specifications, and
any addenda thereto(collectively the"Contract Documents').
6. ATTORNEYS' FEES: In the event any legal action is commenced to enforce or interpret the
terms or conditions of the Contract Documents, the prevailing Party in such action, in addition to
any costs and other relief, shall be entitled to recover its reasonable attorneys' fees, including fees
for use of in-house counsel by a Party.
7. RESOLUTION OF CONSTRUCTION CLAIMS: Any claims by Contractor in the amount of
Three Hundred Seventy Five Thousand Dollars ($375,000) or less shall be made by Contractor
lAcaldjmVlgreements\Macadcc Electrical Const. Public Works Contract 11.3.15.doc
and processed by the City pursuant to the provisions of Part 3,Chapter 1, Article 1.5 of the Public
Contracts Code (commencing with Section 20104). All claims shall be in writing and include the
documents necessary to substantiate the claim. Nothing in Public Contracts Code Section 20104.2
shall extend the time limit or supersede the notice requirements provided for the filing of claims by
Contractor.
S. ELIGIBILITY OF CONTRACTOR/SUBCONTRACTOR: Contractor and aII of its
subcontractors shall abide by Public Contract Code Section 6109 and Labor Code sections 1777.1
and/or 1777.7, and certify that they are not debarred and are eligible to perform the Work.
9. ASSIGNMENT OF AGREEMENT: No assignment by Contractor of any rights or interests
under this Contract shall be binding on the City without the prior written consent of the City.
10. SUCCESSORS AND ASSIGNS: City and Contractor each binds itself and their respective
successors and assigns in respect to all covenants, agreements, and obligations contained in the
Contract Documents.
11. SEVERABILITY: Any provision or part of the Contract Documents held to be void or
unenforceable under any law or regulation shall be deemed stricken, and all remaining provisions
shall continue to be valid and binding upon City and Contractor.
I:kaldjmlAgreeincntslMacadee Electrical Const. Public Works Contract 11.3.15.doe 2
IN WITNESS WHEREOF, the Parties hereto have executed this Contract the day and year first
written above.
City of Redlands
(SEAL) 1 1{1 1
By. r
Paul W. Foster, Mayor
ATTEST:
— z�A
Sam Irwin, rt Clerk
(SEAL)
(lam-fir►ti M�
Macadee Electrical Const ction, Inc.
By:
=nature of Authorized Agent
Title
Signature of Authorized Agent(if necessary)
Title
(7-e73�2� C
Contractor's License No.
3
C\ca\djm\Agreements\Macadee Electrical Const. Public Works Contract 11.3.t 5.doc
WORKER'S COMPENSATION INSURANCE CERTIFICATION
Description of Contract:
Every employer, except the State, shall secure the payment of compensation in one or more of the
following ways:
a. By being insured against liability to pay compensation by one
or more insurers duly authorized to write compensation insurance in this State.
b. By securing from the Director of Industrial Relations, a
certificate of consent to self-insure, either as an individual employer, or as one
employer in a group of employers, which may be given upon furnishing proof
satisfactory to the Director of Industrial Relations of ability to self-insure and to pay
any compensation that may become due to his or her employees.
CHECK ONE
I am aware of the provisions of Section 3700 of the Labor Code which requires every
employer to be insured against liability for Workers' Compensation or to undertake self-insurance
in accordance with the provisions of that Code, and I will comply with such provisions before
commencing the performance of the work and activities required or permitted under this
Agreement. (Labor Code §1861).
'' I affirm that at all times, in performing the work and activities required or permitted under
this Agreement, I shall not employ any person in any manner such that I become subject to the
workers' compensation laws of California. However, at any time, if I employ any person such that I
become subject to the workers' compensation laws of California, immediately I shall provide the
City with a certificate of consent to self-insure, or a certification of workers' compensation
insurance.
I certify under penalty of perjury under the laws of the State of California that the information and
representations made in this certificate are true and correct.
Dated this qth day of 06bur,2015. r�
M aGA�CC C �rc>��coil (�nS�C�IC�
(Contractor)
ignature)
/!
(Official Title)
(SEAL)
(Labor Code Section 1861 provides that the above certificate must be signed and filed by the Contractor with the
Owner prior to performing the work of the contract.)
a
l:\ca\djm\Agreements\Macadee Electrical Const. Public Works Contract 1 1.3.15.doc
Executed in Duplicate Bond Number CSB0008121
Premium. $1,674,00
Premium is for contract term and is subject to
FAITHFUL PERFORNIANCE BOND adjustment based an final contract price
Whereas, the City of Redlands ("ClW), State of Cafifomia, and Macadee Electrical
Construction, Inc (hereinafter designated as "Principal") hR%C entered into an agreement dated
Nin,ember 3, 2015 ("Agreement") whereby Principal agrees to install and complete certain public
ImProvernenLs (the "Work"), which said Agreement is identified as Installation of new Traffic
Signal Cabinet and Conduit and is hereby referred to and made a pan hereof; and
Whereas, said Principal is required under the terms of the Agreement to l'orrush a bond for
the faithful perfortnance or the Agreement, no%%, thereFore, we, the Principal and
as Surety. are held and firmly bound unto the City, in the penal sura of Sixty Six Thousand Nine
Hundred Stxty Nine Dollars (S66,969,00) lar%fol monsy of the United States, for tire payment of'
which sum we bind ourselves, and our heirs, successors, executors and administrators,jointly and
severally, firinly by theseresents
k—Contractors Bonding anTInsurance Company'
The condition of this obligation is such that if the aboe bounded PrI ncl pal, his or its heirs,
executors, adininistrators. successors or assigns., shall in all thina
g5 stand to acid abide by, and well
and truly keep and perform the covenanis, conditions and provisions in the Apreenient and any,
alteration thereof made as therein proN ided, on leis or its part, to be kept and perfornied at the time
and in the manner therein specified, and in all respects according to their true intent and meaning,
and shall faithfully fulfill the one-year guarantee of all materials and workmanship, and shall
defend, indemnify and sa%o harmless the City and Its elected officials, officers, agents and
employees,as therein stipulated, then this obligaition shall berome null and said: othen%ise it shall
be and remain in Fiji] force and effect,
As a part of the Obligation secured hereby and in addition iis the face amount specified
therefor, there shall be included costs and teasonable expenscs and fees, including reasonable
attorneys' fees, incurred by the City in successfully enforcing such obligations, all to be taxed as
costs and included in the judgment rendered
As a condtfion precedent to the satisfactory completion of the Agreement, the abo%c
obligation shall hold good for a period of one (1) year or longer if required by the Agreement afler
the acceptance of the work- by the City, dunng %%hich uric if tire Principal Shall fall to m full,
complete, and satisfactory repair and replacements and totally protect the City from loss or damage
made evident during this period rrom the dale of completion of the Watk, and resulting from or
caused by derectu%e materials or faulty Nsorkrrianship, the aboxe obligation in penal sum thereof
shall remain in full force and effect Tire obligations of Surety hereunder shall continue so long as
an) obligation of the Principal remains
Whenever the Principal shall be, and is declared by the City to be, in default under the
Agreement, the City basing,;perfortned the City obligations thereunder, the Surety shall prorupily
remedythe default,or shall promptly, at the City's option
I Complete the Agreement in accordance with its temis and conch ions,or
2 Obtain a bid or bids for completing the Agreement in accordance with its temis and
conditions, and upon detemunation by Surety of the lowest responsive and
responsible bidder, arrange for a contrast between such bidder and tire Cit). and
FRECEIVED
OCT 2 1 2015
QUALITY OF LIFE r.)FP—,,
. t
make available as \work progresses sufticrent funds to pay the cost of-completion of
the Work less the balance of the Agreement price, but not exceeding. including other
costs and danta,,es for %%hick Surra\ ma\ be liable hereunder. the amount set forth
above. The term "balance of the Agreement price.' as used in this paragraph, shall
mean the total amount payable to the Principal by the City under the Agreement and
any modifications thereto. less the amount pre%lously properIN paid by the (it} to
the Principal.
Surety expressly agrees that the City may refect any contractor or subcontractor which may
he proposed by SUrety In fulfillment of its obligations in the e\ent of default by the Principal.
Surety shall not utilize the Principal in completing the Agreement nor shall Surety accept a
bid from the Principal for completion of' the Work, it' the City, \\hen declaring the Principal in
default, notifies Surety of the ()t\'s objection to the Principal's further participation in the
completion of the Work
No right of action shall accrue on the bond to or for the use of any person or corporation
other than the City named herein or the successors or assigns of'the Clty. Ali\ suit under this bond
must be instituted \within the applicable statute of limitations period.
I he said Surety. for \alue received, hereby stipulates and agrees that no change, extension
of time, alteration or addition to the terms of the Agreement or to the work to be performed
thereunder or the Specifications accompanying the same shall in any \way affect its obligations on
this bond, and it does hereby \\ai\e notice of any such change, extension of time, alteration or
addition to the terms of the Agreement or to the work or to the specifications.
No final settlement bet\veen the (ity and the Principal shall abridge the right of any
beneficiary hereunder \\hose claim may be unsatisfied.
The Principal and Surety agree that if the City is required to engay the ser\ices of' any
attorney in connection with the enforcement of this Bond. each shall pay the City's reasonable
attorneys' fees incurred, \with or without suit, in addition to the above sum.
In \vitness \\hereof, this instrument has been duly executed by the Principal and Surety
above named, on October 13 201
1SFAL) (SI-Ai.)
Macadee Electrical Construction Contractors Bonding and Insurance Company
ntractorl (Surety)
_ BY, � Ni,,a
iSgnaturcl (Signature) _—_—
Laurie B. Druck, Attorney-in-Fact
Address 111 Pacifica, Suite 350
Irvine,CA 92618___ . . .
(Seal and Notarial Acknovdedgment of t elephone( 949 )341-9110
Sura\I
r,
1 :.t,Ilm.\en-cm;nig\ta.alce I I..un.�l l .ntl Puhh. \vaA,r nur.t.t 1 I t I�J.,
CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the
document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
State of California
/) ss.
County of San Bernardino
On October 13, 2015 before me, Cynthia J. Young, Notary Public
Name and Title of Officer(e.g.,"Jane Doe,Notary Public")
personally appeared Laurie B. Druck
Name(s)of Signer(s)
who proved to me on the basis of satisfactory evidence
to be the person whose name is subscribed to the
within instrument and acknowledged to me that she
executed the same in her authorized capacity,
0Y'ti '''" O'jr"' and that by her signature on the instrument the
Commission # 1�,a?4G2
Notary Public i;f,�rf is person, or the entity upon behalf of which the person
��; �u� Bernardino count;; y acted, executed the instrument.
k f Gomm spires„ul 15 2016
I certify under PENALTY OF PERJURY under the laws of
the State of California that the foregoing paragraph is
true and correct.
WIT _SS my hand and official seal.
c rLC
atur Notary Publill
OPTIONAL
Though the information below is not required by law,it may prove valuable to persons relying on the document and could prevent fraudulent
removal and reattachment of this form to another document.
Description of Attached Document
Title or Type of Document:
Document Date: Number of Pages:
Signer(s) Other Than Named Above:
Capacity(ies) Claimed by Signer(s)
Signer's Name:
O Individual Top of thumb here
O Corporate Officer
Title
O Partner -- O Limited O General
O Attorney-in-Fact
O Trustee
O Guardian or Conservator
Other:
Signer is Representing:
m
R L i ckic POWER OF ATTORNEY
"aRU contim"Y PJLI Insurance Company
9025 N.Lindbergh Dr.p Peoria,IL 61615 Contractors Bonding and Insurance Company
Pho=(800)645-2402 1 Fax:(309)689-2036
Know All Men by These Presents:
That this Power of Attorney is not valid or in effect unless attached to the bond which it authorizes executed, but may be detached by the
approving officer if desired,
That this Power of Attorney may be effective and given to either or both of RLI Insurance Company and Contractors Bonding and
Insurance Company,required for the applicable bond.
That RLI Insurance Company and/or Contractors Bonding and Insurance Company, each Illinois corporations (as applicable), each
authorized and licensed to do business in all states and the District of Columbia do hereby make,constitute and appoint:
Jay P,Freeman,Pamela McCaghia J.Young, Laurie B.Druck, jointl y
y,CyDth— or severall
Y
in the City of San Bernardino State of California as Attorney in Fact, with full power and authority hereby
conferred upon him/her to sign, execute, acknowledge and deliver for and on its behalf as Surety, in general, any and all bonds,
undertakings,and recognizances in an amount not to exceed Ten Million Dollars
$10,000,000.00 )for any single obligation.
The acknowledgment and execution of such bond by the said Attorney in Fact shall be as binding upon this Company as if such bond had
been executed and acknowledged by the regularly elected officers of this Company.
R-LI insurance Company and Contractors Bonding and Insurance Company, as applicable, have each further certified that the
following is a true and exact copy of the Resolution adopted by the Board of Directors of each such corporation,and now in force,to-wit:
"All bonds, policies, undertakings, Powers of Attorney or other obligations of the Corporation shall be executed in the
corporate name of the Corporation by the President,Secretary,any Assistant Secretary,Treasurer,or any Vice President,or by
such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant
Secretary, or the Treasurer may appoint Attorneys in Fact or Agents who shall have authority to issue bonds, policies or
undertakings in the name of the Corporation. The corporate seat is not necessary for the validity of any bonds, policies,
undertakings,Powers of Attorney or other obligations of the Corporation. The signature of any such officer and the corporate
i seal may be printed by facsimile or other electronic image."
IN WITNESS WIIEREOF,RLI Insurance Company and/or Contractors Bonding and Insurance Company,as applicable,have
caused these presents to be executed by its respective Vice President with its corporate seal affixed this 25th day of Auggst,2015.
I H" RLI Insurance Company
AN NC
0
Contractors Bonding and Insurance Company
POR C's P O'N
fi
S E A L
SEAL .
Barton W.Davis Vice President
State of Illinois
SS 6-N 0
County of Peoria 111-011�
CERTIFICATE
On this 25th day ofAugust 2015 -1 1, the undersigned officer of RLI Insurance Company, and/or
before are, a Notary Public, personally appeared Barton W. Davis Contractors Bonding and Insurance Company, each Illinois
who being by Inc duly sworn,acknowledged that he signed the above Power corporations, do hereby certify that the attached Power of Attorney is
of Attorney as the aforesaid officer of the RLI Insurance Company and/or in full force and effect and is irrevocable; and farthermore, that the
Contractors Bonding and Insurance Company, and acknowledged said Resolution of the Company as set forth in the Power of Attorney, is
instrument to be the voluntary act and deed of said corporation. now in force. In testimony whereof,I have hereunto set my hand and
the seal of the RLI Insurance CoIjky and/or Co t t
Bonding and Insurance C day of
R.Ll Insurance Company
JacquNotary Public Contractorsing and Ins raiicte,Company
kz�
FF10AL SEAL"
Barton W.Davis Vice President
PUBLIC JACOUE'LINE M.BOCKLER
COMSSON EXPIRES C11W8
=Mmn 0475152020212 A0059115
Executed in Duplicate Bond Number: CSB0008121
Premium included in charge for
Performance Bond
LABOR AND MATERIAL. BOND
herca\. file Cit\ Council of the Cit\ of Redlands, State of California, and Macadec Flectrical
Construction, Inc (hereinafter designated as "principal") ha\c entered Into an agreement (the "Agreement")
\\hereby Principal agrees to Install and complete certain designated public nnpro\emcnts (the "\\ork").
\\hich said agreement, hated No%ember 3, 2015, and identified as Traffic Sivrial Cabinet is heretic referred to
and made a part hereof, and
Wherea\, under the teens of the Agreement, Principal Is required before commending the
perli►rmancc of the M ork. to file a good and sullicient Labor and Material bond \\ith the City of'Redlands to
secure the claims to \\hich reference is made in Title 3 (commencing \\ith section 91 5(1) of Part 6 of
Di\ision 4 of the Ci\II ('odc of the Statc o1 California.
Noi%. therefore, said Principal and the undersigned as corporate surct\, are held firmly bound unto
the City and all contractors, subcontractors, laborers, material men and other persons employed u► the
performance of the Agreement and referred to in the aforesaid Code of ('i\it Procedure in the sum of,
Sixt\ Six Thousand Nine hundred Si\ty Nine Dollars (500.909.00) for materials furnished or labor thereon
of any kind, or for amounts due under the Unemployment Insurance Act mth respect to such \\ork or labor.
that said surety \\III pay the same In an amount not exceeding the amount hercinabo\c set firth, and also in
case suit is brought upon this bond, vvIll pad, in addition to the face amount thereof, costs and reasonable
expenses and fees, including reasonable attorneys' fees. Incurred by the Cuy In successfully enforcing, such
obligation. to be a\\ardcd and fixed bN the court, and to be taxed as costs and to be included in the judgment
therein rendered.
It is hercb\ expressly stipulated and agreed that this bond shall insure to the benefit of an\ and all
persons, companies and corporations entitled to file claims under Title 3 (commencing with Section 9550) of'
Part b of Di\ision a o1' file Ci\fI Code. so as to gl\e a right of action to them or their assigns in any surf
brought upon this bond.
Should the condition of this bond be fill(\ performed, then this obligation shall become null and
wid, otherwise it shall be and remain in lull force and effect.
'I he surety hereb\ stipulates and agrees that no change, extension of time, alteration or addition to
the terms of the Agreement or the specifications accompanying the same shall In an\ manner affect its
obligations on this bond. and it does hereby \\ai\e notice of ani such change, extension of time. alteration or
addition.
In \\uness \\hereof. this instnuncnt has been duly executed by the Principal and surety abo\e named.
o►► October 13 2015
(SEAL) (SEAL)
Macade Electrical Construction Contractors Bonding and Insurance Company__
(Contra r) (surety)
(Sign (Signature) Laurie B. Druck,Attorney-in-Fact
Address
111 Pacifica, Suite 350
Twine, CA 92618-
(Sea]
2618(Seal and Notarial Ackno\\ledgment of Telephone( 949) 341-9110
Surct\)
I r.t.11tH:\utccrnrnt.\Lt..t.lc�I Inutr.tl t ,yr.t P"Id" N-k,t owr. ! I I i I c J-
CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the
document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
State of California \
County of San Bernardino
I SS.
On October 13, 2015 before me, Cynthia J. Young, Notary Public
Name and Title of Officer(e.g.,"Jane Doe,Notary Public")
personally appeared Laurie B. Druck
Name(s)of Signer(s)
who proved to me on the basis of satisfactory evidence
to be the person whose name is subscribed to the
within instrument and acknowledged to me that she
CrNihH A J. YouNG executed the same in her authorized capacity,
con, ,fission ;: 1 s2aa2 and that by her signature on the instrument the
ag = -'t7kr^ d Notary Public - Califcrnia z
San Bernardino Count person, or the entity upon behalf of which the person
° y acted, executed the instrument.
"- My Cr,o�rn. F<Vres Jul 15, 2016
I certify under PENALTY OF PERJURY under the laws of
the State of California that the foregoing paragraph is
true and correct.
WIT ESS my hand and official seal.
i
ign a of Notary PC
OPTIONAL
Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent
removal and reattachment of this form to another document.
Description of Attached Document
Title or Type of Document:
Document Date: Number of Pages:
Signer(s) Other Than Named Above:
Capacity(ies) Claimed by Signer(s)
Signer's Name:
O Individual Top of thumb here
O Corporate Officer
Title
O Partner -- O Limited O General
O Attorney-in-Fact
O Trustee
O Guardian or Conservator
Other:
Signer is Representing:
-----m---
RL18 Ckic POWER OF ATTORNEY
"RLI 40ontpany RLI Insurance Company
9025 N.Lindbergh Dr,I Peoria,IL 61615 Contractors Bonding and Insurance Company
Phone:(800)645-2402[Fax:(M9)689-2036
Know All Men by These Presents:
That this Power of Attorney is not valid or in effect unless attached to the bond which it authorizes executed, but may be detached by the
approving officer if desired.
That this Power of Attorney may be effective and given to either or both of RLI Insurance Company and Contractors Bonding and
Insurance Company,required for the applicable bond.
That RLI Insurance Company and/or Contractors Bonding and Insurance Company, each Illinois corporations (as applicable), each
authorized and licensed to do business in all states and the District of Columbia do hereby make,constitute and appoint:
Jay P.Freeman,Pamela McCarthy,Cynthia J. Young,Laurie B.Druck,jointly or severally
in the City of San Bernardino I State of California _,as Attorney in Fact,with full power and authority hereby
conferred upon him/her to sign, execute, acknowledge and deliver for and on its behalf as Surety, in general, any and all bonds,
undertakings, and recognizances in an amount not to exceed Ten Million Dollars
( , $10,000,000-00 )for any single obligation.
The acknowledgment and execution of such bond by the said Attorney in Fact shall be as binding upon this Company as if such bond had
been executed and acknowledged by the regularly elected officers of this Company.
RILI Insurance Company and Contractors Bonding and Insurance Company, as applicable, have each further certified that the
following is a true and exact copy of the Resolution adopted by the Board of Directors of each such corporation,and now in force,to-wit:
"All bonds, policies, undertakings, Powers of Attorney or other obligations of the Corporation shall be executed in the
corporate name of the Corporation by the President,Secretary,any Assistant Secretary,Treasurer,or any Vice President,or by
such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant
Secretary, or the Treasurer may appoint Attorneys in Fact or Agents who shall have authority to issue bonds, policies or
undertakings in the name of the Corporation. The corporate sea] is not necessary for the validity of any bonds, policies,-
undertakings,
olicies,undertakings,Powers of Attorney or other obligations of the Corporation. The signature of any such officer and the corporate
seal may be printed by facsimile or other electronic image."
IN WITNESS WHEREOF, RLI Insurance Company and/or Contractors Bonding and Insurance Company,as applicable,have
caused these presents to be executed by its respective Vice President with its corporate seal affixed this_jtj day of Febiuary,2015.
GAN RLI Insurance Company
%
Contractors Bonding and Insurance Company
0
.0-
3 % S EAL L
faL :
Roy C.Di Vice President
State of Illinois
County of Peoria SS
CERTIFICATE
On this 4th day of February 2015 1, the undersigned officer of RLI Insurance Company, and/or
before me, a Notary Public, personally appeared Roy C. Die — who Contractors Bonding and Insurance Compary, e:xh Illinois
being by me duly sworn, acknowledged that he signed the above Power of corporations, do hereby certify that the attached Power of Attorney is
Attorney as the aforesaid officer of the RLI tnsurance Company and/or in full force and effect and is irrevocable, and furtherniore, that the
Contractors Bonding and Insurance Company, and acknowledged said Resolution of the Company as set forth it hix Po-w(,r of Attorricy, is
instrument to be the voluntary act and deed of said corporation, now in force. In testimony whereof,I bane hereunto sU my hand and
the seal of the RLI Insurance Com, y and/or 1C t t
day of WR7
mpanyis wthwu &W
oonkdnq and Insurance Co
0 1 ,
R-LI Insurance Company
Jacqu ire M.Bockle Notary Public Contractors Bonding and Insurance Company
"OFFICIAL SEAL"
oyC. l(j ' Vice President
111A11
RD
...LC
STAMOF JACQUELINE M.BOCKLER
lumns-ICOMMISSION EXPIRES 01114118
0476152020212 A0059115