Loading...
HomeMy WebLinkAboutContracts & Agreements_148-15_CCv0001.pdf PUBLIC WORK CONSTRUCTION CONTRACT This Public Work Construction contract ("Contract") is made and entered into this 21st day of July, 2015,by and between the City of Redlands, a municipal corporation, organized and existing under the laws of the State of California (hereinafter "City"), and Ames Construction, Inc. hereinafter ("Contractor"). City and Contractor are sometimes individually referred to herein as a "Party" and, together,as the`?arties." In consideration of the mutual promises contained herein, City and Contractor agree as follows: 1. SCOPE OF WORK: Contractor shall furnish all materials and will perform all of the work for the following: Haul Fill Dirt to Prospect Park Reservoir Project, Supply Sound Curtain and Clear prepare area to be used as entrance and exit roads, complete, as required by the Contract Documents (as herein defined) and Specifications for City's Prospect Park Reservoir Fill Dirt Hauling and Repurposing Project,QOL04082015KG(the"Work"). 2. CONTRACT SUM: City shall pay Contractor the sum of One Hundred Fifteen Thousand, One Hundred Dollars ($115,100.) as consideration for its performance of the Work in accordance with the terms and conditions set forth in the Contract Documents. Pursuant to Public Contract Code Section 22300, Contractor has the option to deposit securities with an escrow agent as a substitute for retention of earnings required to be withheld by City pursuant to an escrow agreement as set forth in Public Contract Code section 22300. 3. TIME FOR COMPLETION: The Work shall be completed within ninety days (90) calendar days from and after the date of the delivery to Contractor of the Notice to Proceed by City. 4. LIQUIDATED DAMAGES: Contractor's failure to complete the Work within the time allowed will result in damages being sustained by City. Such damages are, and will continue to be, impracticable and extremely difficult to determine. Accordingly, Contractor shall pay to City, or have withheld from monies due to Contractor, the sum of Five Hundred Dollars ($500.) for each consecutive calendar day in excess of the specified time for completion of the work. Execution of this Contract shall constitute agreement by City and Contractor that Five Hundred Dollars ($500.)per day is the estimated damage to City caused by the failure of the Contractor to complete the work within the allowed time. Such sum is liquidated damages and shall not be construed as a penalty, and may be deducted from payments due the Contractor if such delay occurs. 5. CONTRACT DOCUMENTS: This Contract incorporates by reference the following: Notice Inviting Bids, Instructions to Bidders, Contractor's Proposal, Bid Bond, Agreement Performance, Labor and Material Bond, Plans, General Conditions, Special Provisions and Specifications, and any addenda thereto(collectively the"Contract Documents"). 6. ATTORNEYS' FEES: In the event any legal action is commenced to enforce or interpret the terms or conditions of the Contract Documents, the prevailing Party in such action, in addition to any costs and other relief, shall be entitled to recover its reasonable attorneys' fees, including fees for use of in-house counsel by a Party. 7. RESOLUTION OF CONSTRUCTION CLAIMS: Any claims by Contractor in the amount of Three Hundred Seventy Five Thousand Dollars ($375,000) or less shall be made by Contractor I:\ca\djm\Agreements\AmesConstrnetion,Inc.7.9.15.doc and processed by the City pursuant to the provisions of Part 3, Chapter 1, Article 1.5 of the Public Contracts Code (commencing with Section 20104). All claims shall be in writing and include the documents necessary to substantiate the claim. Nothing in Public Contracts Code Section 20104.2 shall extend the time limit or supersede the notice requirements provided for the filing of claims by Contractor. 8. ELIGIBILITY OF CONTRACTOR/SUBCONTRACTOR: Contractor and all of its subcontractors shall abide by Public Contract Code Section 6109 and Labor Code sections 1777.1 and/or 1777.7,and certify that they are not debarred and are eligible to perform the Work. 9. ASSIGNMENT OF AGREEMENT: No assignment by Contractor of any rights or interests under this Contract shall be binding on the City without the prior written consent of the City. 10. SUCCESSORS AND ASSIGNS: City and Contractor each binds itself and their respective successors and assigns in respect to all covenants, agreements, and obligations contained in the Contract Documents. 11. SEVERABILITY: Any provision or part of the Contract Documents held to be void or unenforceable under any law or regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon City and Contractor. I:\ca\dim\Agreements\AmesConstruction, Inc.7.9.I5_doc IN WITNESS WHEREOF, the Parties hereto have executed this Contract the day and year first written above. City of Redlands (SEAL) By r Paul Foster, Mayor ATTEST: Sam Irwin, ity berk (SEAL) L) Ames Construe 'on, Inc. Name of Contractor - z i� By: Signature of Authorized Agent (Gerard F. Miller) Senior Vice President Title Signature of Authorized Agent(if necessary) Title 490481 Contractor's License No. I:\ca\djm\Agreements\AmesConstruction, Inc.7.9.15.doc A WORKER'S COMPENSATION INSURANCE CERTIFICATION Description of Contract: Prospect Park Reservoir Fill Dirt Hauling&Repurposing Project Every employer, except the State, shall secure the payment of compensation in one or more of the following ways: a. By being insured against liability to pay compensation by one or more insurers duly authorized to write compensation insurance in this State. b. By securing from the Director of Industrial Relations, a certificate of consent to self-insure, either as an individual employer, or as one employer in a group of employers, which may be given upon furnishing proof satisfactory to the Director of Industrial Relations of ability to self-insure and to pay any compensation that may become due to his or her employees. CHECK ONE X I am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against liability for Workers' Compensation or to undertake self-insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work and activities required or permitted under this Agreement. (Labor Code §1861). I affirm that at all times, in performing the work and activities required or permitted under this Agreement, I shall not employ any person in any manner such that I become subject to the workers' compensation laws of California. However, at any time, if I employ any person such that I become subject to the workers' compensation laws of California, immediately I shall provide the City with a certificate of consent to self-insure, or a certification of workers' compensation insurance. I certify under penalty of perjury under the laws of the State of California that the information and representations made in this certificate are true and correct. Dated this_L"Ll�day of ` � ,201/3 Ames Cons ctio , nc. n o (Signature) Senior Vice President (Official Title) (SEAL) (Labor Code Section 1861 provides that the above certificate must be signed and filed by the Contractor with the Owner prior to performing the work of the contract.) I:\ca\djm\Agreements\AmesConsuvetion,Inc.7.9.15.doc 'k FAITHFUL PERFORMANCE BOND Bond No.106307123 Whereas, the City of Redlands ("City"), State of California, and Ames Construction, Inc. (hereinafter designated as "Principal') have entered into an agreement dated July 21, 2415 ("Agreement") whereby Principal agrees to install and complete certain public improvements (the "Work"), which said Agreement is identified as Prospect Park Reservoir Fill Dirt Hauling and Repurposing Project and is hereby referred to and made a part hereof; and Whereas, said Principal is required under the terms of the Agreement to furnish a bond for the faithful performance of the Agreement, now, therefore, we, the Principal and , as Surety, are held and firmly bound unto the City in the penal sum of One Hundred Fiftecn Thousand One Hundred And No/1ooDollars ($115,100.00 ) lawful money of the United States, for the payment of which sura we bind ourselves, and our heirs, successors, executors and administrators,jointly and severally, firmly by these presents. *Travelers Casualty and Surety Company of America The condition of this obligation is such that if the above bounded Principal, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and provisions in the Agreement and any alteration thereof made as therein provided, on his or its part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall faithfully fulfill the one-year guarantee of all materials and workmanship, and shall defend, indemnify and save harmless the City and its elected officials, officers, agents and employees, as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefor, there shall be included costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligations, all to be taxed as costs and included in the judgment rendered. As a condition precedent to the satisfactory completion of the Agreement, the above obligation shall hold good for a period of one (1) year or longer if required by the Agreement after the acceptance of the work by the City, during which time if the Principal shall fail to make full, complete, and satisfactory repair and replacements and totally protect the City from loss or damage made evident during this period from the date of completion of the Work, and resulting from or caused by defective materials or faulty workmanship, the above obligation in penal sum thereof shall remain in full force and effect. The obligations of Surety hereunder shall continue so long as any obligation of the Principal remains. Whenever the Principal shall be, and is declared by the City to be, in default under the Agreement, the City having performed the City obligations thereunder, the Surety shall promptly remedy the default, or shall promptly, at the City's option: 1. Complete the Agreement in accordance with its terms and conditions; or 2. Obtain a bid or bids for completing the Agreement in accordance with its terrus and conditions, and upon determination by Surety of the lowest responsive and responsible bidder, arrange for a contract between such bidder and the City, and make available as work progresses sufficient funds to pay the cost of completion of the Work less the balance of the Agreement price, but not exceeding, including other I;\cald}m\Agrcct»cutslAmesConstructiwt,Inc.7.9.15.doc costs and damages for which Surety may be liable hereunder, the amount set forth above. The term "balance of the Agreement price," as used in this paragraph, shall mean the total amount payable to the Principal by the City under the Agreement and any modifications thereto, less the amount previously properly paid by the City to the Principal. Surety expressly agrees that the City may reject any contractor or subcontractor which may be proposed by Surety in fulfillment of its obligations in the event of default by the Principal. Surety shall not utilize the Principal in completing the Agreement nor shall Surety accept a bid from the Principal for completion of the Work if the City, when declaring the Principal in default, notifies Surety of the City's objection to the Principal's further participation in the completion of the Work. No right of action shall accrue on the bond to or for the use of any person or corporation other than the City named herein or the successors or assigns of the City. Any suit under this bond must be instituted within the applicable statute of limitations period. The said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terns of the Agreement or to the work to be performed thereunder or the Specifications accompanying the same shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Agreement or to the work or to the specifications. No final settlement between the City and the Principal shall abridge the right of any beneficiary hereunder whose claim may be unsatisfied. The Principal and Surety agree that if the City is required to engage the services of any attorney in connection with the enforcement of this bond, each shall pay the City's reasonable attorneys' fees incurred, with or without suit, in addition to the above sum. In witness whereof, this instrument has been duly executed by the Principal and Surety above named, on July 21 52015 . (SEAL) (SEAL) Ames Construction,Inc. Travelers Casualty and Surety Company of America 0:9) aic� � ,� By rety Michael J.Kellen, (Signature) J ck Cedarleaf II, (Signature) Secretary/Chief Financial Officer Attorney-in-Fact Address: One Tower Square Hartford,CT 06183 (Seal and Notarial Acknowledgment of Telephone( 860 )277-0111 Surety) 1:\ca\djm\Agreements\AmesConstruction, Inc.7.9.15.doc CORPORATE ACKNOWLEDGMENT State of Minnesota ) I 1 County of b )ss) On this day of \J �, before me appeared Michael J.Kellen to me personally known, who, being by me duly sworn, did say that he/she is the Secretary/Chief Financial Officer of Ames Construction, Inc. , a corporation, that the seal affixed to the foregoing instrument is the corporate seal of said corporation, and that said instrument was executed in behalf of said corporation by authority of its Board of Directors, and that said Michael J.Kellen acknowledged said instrument to be the free act and deed of said corporation. Notary Public 'cc IAA- unty,�v 1 ��� AMIE J.KRAUS My commission expires % (� NQTAW PUBLIC•MINNESOTA My C,gnmission Eh"Jan.31,2020 A AAA SURETY ACKNOWLEDGMENT State of Minnesota ) )ss County of Hennepin ) On this 21st day of July 2015 , before me appeared Jack Cedarleaf II to me personally know, who being by me duly sworn, did say that(s)he is the Attorney-in-Fact of Travelers Casualty and Surety Company of America , a corporation,that the seal affixed to the foregoing instrument is the corporate seal of said corporation and that said instrument was executed in behalf of said corporation by authority of its Board of Directors; and that said Jack Cedarleaf II acknowledged said instrument to be the free act and deed of said corporation. - } 7"1LIN ULVEN 4- Notary Notary Public Ramsey County,Minnesota My Commission Expires My commission expires 131/2020 Jznuary 31,2020 WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE REI)BORDER POTATER OF ATTORNEY FarmingtonTRAVELERS Casualty Company St.Paul Mercury Insurance Company Fidelity and Guaranty Insurance Company Travelers Casualty and Surety Company Fidelity and Guaranty Insurance Underwriters,Inc. Travelers Casualty and Surety Company,of America St.Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company St,Paul Guardian Insurance Company` Attorney-In Fact No. 229381 Certificate No. 006331402 Tt.rdOW ALL MEN BY THE,SE PRESENTS: That Farmington Casualty Company, St Paul Fire and Marine Insurance Company-, St. Paul Guardian Insurance Company,SL Paul Mercury Insurance Company.Travelers Casualty and Surety Company,"Travelers Casualty and Surety Company of Americas,and CJnited States Fidelity and Guaranty Company are corporations duly organized under:the latus of the State of Connecticut,that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the.State of krona,and that Fidelity and Guaranty Insurance Underwriters,tire.,is a corporation duly organized under the laws of the State(if Wisconsin(herein collectively called the"Companies"),aand that the Companies do hereby make,constitute and appoint John E.Tatter,Linde K, French.R. W.Frank.Craip,Peranirk,Rachel Thomas,NicoJc S illin�s,.li slntta I�.Lcaltia, l�ri<arn J. OcArtich,Sandra M. 1)cnre, Jororne T.C)uimet, D.R. Doughcrtyti,Jack Cedarleal`ll, Kurt C.Lutndblad, Melinda C.Blodgett,R. C. Howman,R,Scott E _gginitnii,Ted R.Jcnrgenstln. Emily Keiser,and Lin Ulveai Minneapolis Minnesota of thc�ity ol'_- ,State of ,their tine and lawful Attorney(s)=ia§-Poet, each in their separate capacity at ni re than one is naanaed above,to sign,execute,seal and acknowledge tiny and all bonds,recogtnzances,conditional undertakings and other writings oli igaatoryt in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons,guaranteeing the performance of contracts and executing o�guaranteeing bonds and undertakings required;or permitted in any actions or proceedings allowed by law. IIS WITNESS 6$fTtFREOF,the Companies have caused this instrument to be signed and their corporate seals to be hereto affixed,this 8th 20,15 (lily of Y Farmington Casualty Company St.Paul Mercury Insurance Company Fidelity and Guaranty Insurance Company 'Travelers Casualty and Surety Company Fidelity and Guaranty Insurance Underwriters,Inca Travelers Casualty and Surety Company of America St.Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company St.Paul Guardian Insurance Company SwSG.?14", Y qMO� *pp 3�d9fdA nT i . a�caaA�e�n 4m �iGpR9 {,gp x �caaaaRgyCT� 8'a���ae9R.e3�.�`: yr �r �^I,:. �� ec �9ia X957 r�" �° sctiLr�s SEAL 3 curt. o c J t8a State of Connecticut By _ City of Hartford ss. Robert t Raney,.eniur Vice President kith May 2{71 5 On this the day of before me personally appeared Robert L Rancy,who acknowledged himself to be the Senior Vice President of Farmington CasualtyCompany, Fidelity and Guaranty Insurance Company,Fidelity and Guaranty Insurance Underwr teras,Inc.,St.Paul Fire and Marine Insurance Company-,St.Patel Guardian Insurance Company,St.Paul Mercury Insurance Company,Travelers Casualty and Surety Company,Travelers Casualty and Surety Company of America,and United Slates Fidelity and Guaranty Company,and that he_its such,being authorized so to do,executed the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. Cs.TErr TanWitness Whereof,I hereunto set my haricl and official lead, TAN '%� __Y\AA�k My Commission expires the 30dn day 7f June,30 l t, l y Marie C.Tetre atilt.Notary Public t� ft 88440-8-12 Printed in U.S.A. WARNING;THIS POWER OF ATTORNEY tS 1NVAt_ID WITHOUT THE RED BORDER LABOR AND MATERIAL BOND Bond No.106307123 Whereas, the City Council of the City of Redlands, State of California, and Ames Construction, Inc. hereinafter designated as "Principal") have entered into an agreement (the "Agreement") whereby Principal agrees to install and complete certain designated public improvements (the "Work"), which said agreement, dated July 21, 2015, and identified as Prospect Park Reservoir Fill Dirt Hauling & Repurposing Project is hereby referred to and made a part hereof; and Whereas, under the terms of the Agreement, Principal is required before commending the performance of the Work, to file a good and sufficient Labor and Material bond with the City of Redlands to secure the claims to which reference is made in Title 3 (commencing with Section 9550) of Part 6 of Division 4 of the Civil Code of the State of California. Now, therefore, said Principal and the undersigned as corporate surety, are held firmly bound unto the City and all contractors, subcontractors, laborers, material men and other persons employed in the performance of the Agreement and referred to in the aforesaid Code of Civil Procedure in the sum of** Dollars ($115,100.00 ) for materials furnished or labor thereon of any kind, or for amounts due under the Unemployment Insurance Act with respect to such work or labor, that said surety will pay the same in an amount not exceeding the amount hereinabove set forth, and also in case suit is brought upon this bond, will pay, in addition to the face amount thereof, costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligation,to be awarded and fixed by the court,and to be taxed as costs and to be included in the judgment therein rendered. **One Hundred Fifteen Thousand One Hundred And No/100 It is hereby expressly stipulated and agreed that this bond shall insure to the benefit of any and all persons, companies and corporations entitled to file claims under Title 3 (commencing with Section 9550) of Part 6 of Division 4 of the Civil Code, so as to give a right of action to thein or their assigns in any suit brought upon this bond. Should the condition of this bond be fully perfonned, then this obligation shall become null and void, otherwise it shall be and remain in full force and effect. The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or the specifications accompanying the same shall in any manner affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition. In witness whereof,this instrument has been duly executed by the Principal and surety above named, on July 21 , 2015 . (SEAL) (SEAL) Ames Construction,Inc. Travelers Casualty and Surety Company of America (Contractor (Surety BY: - (Signature) Michael J.Kellen, (Sign re)Jack Cedarleaf II,Attorney-in- ct Secretary/Chief Financial Officer Address: One Tower Square Hartford,CT 06183 (Seal and Notarial Acknowledgment of Telephone(860 ) 277-0111 Surety) 1:\ca\djm\Agreements\AmesConstruction, Ine.7.9.15.doc CORPORATE ACKNOWLEDGMENT State of Minnesota ) ; I County of J' )ss) I1 On this day of , before me appeared Michael J. Kellen to me personally known, who, being by 'e duly sworn, did say that he/she is the Secretary/Chief Financial Officer of Ames Construction, Inc. , a corporation,that the seal affixed to the foregoing instrument is the corporate seal of said corporation, and that said instrument was executed in behalf of said corporation by authority of its Board of Directors, and that said Michael J. Kellen acknowledged said instrument to be the free act and de d of said corporation. 1 {\l & _ • AMIE J.KRAUS Notary Public -CC ' —ZoJu`nt Oji NOTARY PuBUC-MINNESOrA MyiE>=Jea.31,2020 My commission expires I s SURETY ACKNOWLEDGMENT State of Minnesota ) )ss County of Hennepin ) On this 21st day of July 2015 , before me appeared Jack Cedarleaf II to me personally know, who being by me duly sworn, did say that(s)he is the Attorney-in-Fact of Travelers Casualty and Surety Company of America , a corporation,that the seal affixed to the foregoing instrument is the corporate seal of said corporation and that said instrument was executed in behalf of said corporation by authority of its Board of Directors; and that said Jack Cedarleaf II acknowledged said instrument to be the free act and deed of said corporation. �dL;,�a•, rti,nniwvnnnvw+nnnnn�,�nnno _�—�^ �.�r .----- . ._ LIN ULVEN Notary Public Ramsey County,Minnesota OTARY PUBLIC-MINNEOTA Vy Commission Expires My commission expires 1/31/2020 January 31, 2020 WARNING THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER Agbk POWER ATTORNEY FarmingtonTRAVELERS Casualty Company St,Paul Mercury Insurance Company Fidelity and Guaranty Insurance Company Travelers Casualty and Surety Company Fidelity°and Guaranty Insurance Underwriters,Inc. Travelers Casualty and Surety Company of America St.Paul Fire and,Marine Insurance Company United States Fidelity and Guaranty Company St.Paul Guardian Insurance CompanyWttor cr®Itn Fact iso, certificate No.2293 I 006331401 KNOW AAI, IW=EN BY THESE PRESENTS: That Farmington Casualty Company, ,St.Paul Fire and Marine.Insurance Company. St, Paul Guardian insurance Corxnpaiany,St, Paul Mercury Insurance Company, Travelers Casualty and Surely'Company,Travelers Casualty and Surety Company of America,and United States Fidelity and Guaranty Company are corporations duty organized under the laws of the State of Connecticut,that Fidelity and;Guaranty Insurance Company is a corporation duly organized under the laws of the.State of Iowa,and that Fidelity and Goaaanty Insurance Underwriters,talc.,is a corporation duly organized under the laws of the State cf Wisconsin{herein collectively called the"Companies").and that the.Companies do hereby make.constitute and appoint john E.'moor,Linda K.French,R. W,Frank.Craig Remick,Rachel Thomas,Nicolc Stilling-,Joshua R. Loftis,Brian J. Oestr;ic.h,Sandra M. Doze, Jerome T,t uirnct,13. R. Dougherty;Jack Cedarlcat ll,Burt C L undhiad,Melinda C. Bloductl,R.C. Bowman,R.Scott Eg-intoe,`ed R.Jorgensen, L.ntily Keisor,and Rin Ulven Minrica alis Minnesota 04 the City of 1 �;.State of ,their true and lawful A,ttor-ncy(ti)-in-Faact., each in their separate capacity if more than one is named above,to sign,exectme,seal and acknowledge any and all bonds,recognizances,conditional undertakings and Cather writings obligatory in the nature thereof on behalf of the:Companies in then-business of guaranteeing the fidelity of persons,guaranteeing tdie performance of contracts and cxmiri ng or guaranteeing bonds and undertakings required or permitted in my actions or proceedings allowed by law. _ IN WI'T'NESS WHEREOF,the.Companies have carried this instrmtsent to be sil-ned and their corporate seals to be hereto affixed,this 9 S th day of Cv1aa}r 2015 Farmington Casualty Company St.Paul Mercury Insurance Company Fidelity and Guaranty Insurance Company Travelers Casualty=and;Surety Company Fidelity and Guaranty Insurance Underwriters,Inc. 'Travelers Casualty and Surety Company aa#'almerira St.Paul Fire and Marine:Insurance Company United States Fidelity and Guaranty Company St.Paul Guardian Insurance Company 'usu�,q ®T�aaRA"j'. X70 �,, a -_ ra�atraao, raa�ir�s�,t " SE61L�as. �J o' y C4iEN. n Ghat. j� 1996 :,�, a a f �"�': �,t # :#'� rr r^,�,wA c° ��5 ♦�����f... 'f f Starts of Connecticut By: City of Htarttord ss`. RobcrtL.Rancy,<enior Vice President S th May 2fl 15 On this the. clay of before me personally appeared Robert L.Raney,who aeknas4iiledgcci himself to be the Senior`vice President of Farmington Casualty Company, Fidelity and Guaranty Insurance Company,Fidelity and Guaranty Insurance Underwriters,Inc.,.rt.Paul. Fire and Marine Insurance Company,St,Find Guardian Insurance Company,St.Paul Mercury Insurance Company,'fravelers Casualty and Surety Company,Travelers Casualty and Surety Company of Ante'icaa,and United States Fidelity and Guaranty Company,and that he.as such,being authorized so to der,eXeC led the foregoing instrument for the purpose;therein contained by signing on behalf of dee corporations by himself as a duly authorized officer, In Witness Whereof,I hereunto,set my hand and official seal; w,l My Commission expires the 30th day of June,-2016. vtaa�r C.Teareauh,NotaD Public 58440-8-12 Printed in U.S.A. WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER Client#:51 AMESCONI DATE(MMIDDIYYYY) ACORDTM CERTIFICATE OF LIABILITY INSURANCE 6/22/2015 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT:If the certificate holder is an ADDITIONAL INSURED,the policy(les)must be endorsed.If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: MN-COMMERCIAL LINESPHDNE 612 349-2400 FAX 612 349 2490 AIC No Ext: AIC No COBB STRECKER DUNPHY 8r ZIMMERMANN E-MAIL ADDRESS: 150 S FIFTH ST STE 2800 INSURER(S)AFFORDING COVERAGE NA1C# MINNEAPOLIS,MN 55402 INSURER A TRAVELERS INDEMNITY OF AMERICA INSURED INSURER 0:TRAVELERS PROPERTY CASUALTY COI Ames Construction Inc INSURER C: 2000 Ames Dr INSURER D: Burnsville,MN 55306 INSURER E INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSLTR TYPE OF INSURANCE INSRADDW O POLICY NUMBER POLICY EFF MMIDIDIIYYYY LIMITS LTR A X COMMERCIAL GENERAL LIABILITY VTC2HCO7408B632 0510112015 05/011201 EACH�OCCCURRENCE s2,000,000 CLAIMS-MADE a OCCUR PRET fISES Ee occuErr°noe 0001000 000 X CONTRACTUAL LIAB PER MED EXP(Any one person) S5,000 X POLICY FORM AND XCU PERSONAL SADV INJURY s2,000,000 GEN'LAGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE 54,000,000 POLICY�JECT a LOC PRODUCTS-COMPIOPAGG 54,000,000 OTHER: S B AUTOMOBILE LIABILITY VTC2JCAP5834B489 5/01/2015 05/01/201 COMBINED SINGLE LIMIT 2 000 000 Ea accident r r X ANY AUTO BODILY INJURY(Per person) S ALL OWNED SCHEDULED AUTOS AUTOS BODILY INJURY(Peraccidenl) S X HIRED AUTOS Ix NON-OWNED PROPERTY DAMAGE S AUTOS Per accident S UMBRELLA LIAB HOCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE S DED I I RETENTIONS S B WORKERS COMPENSATION VTC2JUB6726B789 5/01/2015 05/0112016 X IPFR OTH- STATUTF AND EMPLOYERS'LFABIL1TY B ANY PROPRIETOR/PARTNERIEXECUTIVEFN VTRJUB8364B757 5/01/2015 05/01/201 E.L.EACH ACCIDENT $1000000 OFFICERIMEMBER EXCLUDED? N N I A (Mandatory in NH) STOP GAP LIABILITY ONLY IN STATES E.L.DISEASE-EA EMPLOYEE S1,000,000 yes,describe under DESCRIPTION OF OPERATIONS below OF: ND OH WA WY E.L.DISEASE-POLICY LIMIT $1,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached If more space Is required) DIRT DONATION AT PROSPECT PARK ADDITIONAL INSURED ONLY IF REQUIRED BY WRITTEN CONTRACT WITH RESPECT TO GENERAL LIABILITY AND AUTOMOBILE LIABILITY APPLIES ON A PRIMARY BASIS AND THE INSURANCE OF THE ADDITIONAL INSURED SHALL BE NON-CONTRIBUTORY: CITY OF REDLANDS (See Attached Descriptions) CERTIFICATE HOLDER CANCELLATION CITY OF REDLANDS SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 35 CAJON ST,STE 222 ACCORDANCE WITH THE POLICY PROVISIONS. PO BOX 3005 REDLANDS,CA 92373 AUTHORIZED REPRESENTATIVE I ©1988- 0' 4 ACORD CORPORATION.All rights reserved. ACORD 25(2014101) 1 of 2 The ACORD name and logo are registered marks of ACORD #S718972IM703306 KLH DESCRIPTIONS (Continued from Page 1) The following supersedes the cancellation wording: Should any of the above described policies be cancelled before the expiration date,30 Days written notice (10 Days for Non-Payment)will be delivered to the certificate holder. SAGITTA 25.3(2014101) 2 of 2 #S7189721M703306