HomeMy WebLinkAboutContracts & Agreements_74-2010_CCv0001.pdf } PUBLIC WORK; CONSTRUCTION CONTRACT
a This Public Work Construction contract ("Contract") is made and entered into this 24`1' day of
May, 2010, by and between the City of Redlands, a municipal corporation, organized and existing
under the laws of the State of California, (hereinafter "City") and South W
est Pump and
(hereinafter "Contractor"). City and Contractor are sometimes individually referred to herein Drilling
as a
"Party"and, together, as the"Parties."
In consideration of the mutual promises contained herein, City and Contractor agree as follows:
I. SCOPE OF WORK: Contractor shall furnish all materials and will perform all of the work for
the following: Construction of the certain designated public improvements project, complete,
as required by the Contract Documents ( as herein defined) and Specifications for City's
Mentone Acres 2, Well and Pump Rehabilitation Project(the "Work").
2. CONTRACT SUM: City shall pay Contractor the sum of Eighty Three Thousand Two
Hundred Two Dollars ($$3,252.00) as consideration for its performance of the Work in
accordance with the terms and conditions set forth in the Contract Documents. Pursuant to
Public Contract Code Section 22300, Contractor has the option to deposit securities with an
escrow agent as a substitute for retention of earnings required to be withheld by City pursuant
to an escrow agreement as set forth in Public Contract Code section 22300.
3. TIME FOR COMPLETION: The Work shall be completed within ninety(90) calendar days
from and after the date of the delivery to Contractor of the Notice to Proceed by City.
4. LIQUIDATED DAMAGES: Contractor's failure to complete the work within the time
allowed will result in damages being sustained by City. Such damages are, and will continue to
be, impracticable and extremely difficult to determine. Accordingly, Contractor shall pay to
City, or have withheld from monies due to Contractor, the sum of Five Hundred Dollars (S500)
for each consecutive calendar day in excess of the specified time for completion of the work.
Execution of the Contract shall constitute agreement by City and Contractor that Five Hundred
Dollars (S500) per day is the estimated damage to City caused by the failure of the Contractor
to complete the work within the allowed time. Such sum is liquidated damages and shall not be
construed as a penalty, and may be deducted from payments due the Contractor if such delay
occurs.
5. CONTRACT DOCUMENTS: Contract documents, under the Agreement, include all of the
documents set forth herein, to wit; Notice Inviting Bids, Instructions to Bidders, Proposal, Bid
Bond, Agreement, Performance Bond, Labor and Material Bond, Plans, General Conditions,
Special. Conditions, Special Provisions and Specifications, and any addenda thereto.
f'. ATTORNEY'S' FEES: In the event any legal action is commenced to enforce or interpret the
terms or conditions of the contract documents, the prevailing party in such action, in addition to
any costs and other relief, shall be entitled to recover its reasonable attorneys" fees.
7. RESOLUTION OF CONSTRUCTION CLAIMS: Claims by the Contractor in the amount
of $375,000 or less shall be made by Contractor and processed by the City pursuant to the
provisions of Part 3, Chapter 1, Article 1.5 of the Public Contracts Code (commencing with
Section 20104), All claims shall be in writing and include the documents necessary to
substantiate the claim. Nothing in subdivision (a) of Public Contracts Code Section 20104.2
shall extend the time limit or supersede the notice requirements provided in this case from
filing claims by Contractor.
8. ELIGIBILITY OF CONTRACTOR/SUBCONTRACTOR: Contractor and all of its
subcontractors shall abide by California Public Contract Code Section 6109, and California
Labor Code sections 1777.1 and/or 1777.7, and certify that they are not debarred and are
eligible to work on this Project,
9. ASSIGNMENT OF AGREEMENT: No assignment by a Party hereto of any rights or
interests under this agreement shall be binding on another Party without the written consent of
the Party sought to be bound.
10. SUCCESSORS AND ASSIGNS: City and Contractor each binds itself and their respective
successors and assigns in respect to all covenants, agreements, and obligations contained in the
Contract Documents.
IL SEVERABILITY: Any provision or part of the contract documents held to be void or
unenforceable under any law or regulation shall be deemed stricken, and all remaining
provisions shall continue to be valid and binding upon City and Contractor.
IN WITNESS WHEREOF, the Parties hereto have executed this Agreement the day and year first
written above,
' City of Redlands
(SEAL) (Owner)
By.eO O-C�644Y,1�
Mayor, City of Redlands, County of
ATTEST: San Bernardino, California
City Clerk; &vyoedlands
County of San Bernardino, California (SEAL)
pu4L Rtmptunojt
Z
2:uthorized
Agent
Title
�Signat�ureof Authorized Agent(if necessary)
Title
a
Contractor's License No.
WORKER'S COMPENSATION INSURANCE CERTIFICATION
Description of Contract: City of Redlands
Municipal Utilities& Engineering Department
Mentone Acres 2, Well and Pump Rehabilitation
Project
Labor Code Section 3700,provides, in part that:
"Every employer except the State, shall secure the payment of compensation in one or more of
the following ways:
(a) By being insured against liability to pay compensation in one or more insurer
duly authorized to write compensation insurance in this State.
(b) By securing from the Director of Industrial Relations a certificate of consent to
self-insure, either as an individual employer, or as one employer in a group of
employers which may be given upon furnishing proof satisfactory to the
Director of Industrial Relations of ability to self-insure and to pay any
compensation that may become due to his or her employees.
I am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be
insured against liability for worker's compensation or to undertake self-insurance in accordance with
the provisions of that Code, and I will comply with such provisions before commencing the
performance of the work of this contract. (Labor Code section 1861)
Dated this c2A day of nT�--2010.
—SoLrk WeA ow-ft
(Contractor)
Signature
(Official Title)
(SEAL)
(Labor Code Section 1861 provides that the above certificate must be signed and filed by the Contractor with
the Owner prior to perforining the work of the contract.)
Bond =x. 2303300
Premium; $916 . 00
PERFOIKATA ;C E BO
N hereeas' ...e. Ctity t b)::=d of me City ,,t I odi'land:s, Stat o! C ali e`miai. and
,south West Pump
._...._._. hereinafter ۤcsignaTed as "Principal") has ,e enteredint()
an c?i?i`C'ti'.ment whereby Prmcipal agrees to install Arid complete certain designated public iniprove mernts,
which said agivenient, dated ......�a� . �1�W ...... 2010, and idmitif ed as entone Acres 2,
Well and Pump Rehabilitation Project is hereby referred to anti made a part hereof; and
N'1'hereas, said. Principal is required under the terms of said agreement to Furnish a bond for the
performance of said prciject,
Now, therefore, said Principal and, Insurance Company.._of the Wes* surety. anew held.
_..... ___.. ...__.._,
firmly bound unto the City ofRedlan s(here inaftcrcall C"its I in the pend! ;gun,ofEi ghty Three
Thousand Two Hundred Fifty Two j 83 252 . 00***� �, --
__....._... __—T �.-1 _.__._..._. _L)e�i_ars{ '` ��# a
_� _�} ,a �ful iris..ae>,� of the
.t zits §xssl��ti; iii. tine l ay`niew of wh1h isuni L't t and truly to be nude. we bind our`+e.#its, our heirs.
sume;-,s(w €,1etal ors and <3drni 2v.mat:ors, ointly-and several ly. firnily by,these pinesents.
The condition of this obligation is such that it the:, aboe bounded Principal, his or hers he;ins, executors,
adn nistraitor,. sLIccLs s£)tx tw assi=gn , M in all things stand to and abide by, and well, and ?'.`' ly keep and
pe form the covenants. conditions and provisions in the said a r"ee#trie nt and any alteration thereof made as
therehi provided. or his or dwir part, to be kept and pe'.rfbnn d at the time arid in the mativer therein
specified, and in atll respects according to their trtie„ intent and nieaii3rt`g. and shatt defend, 3lldetrrini�y and
'ia >amalless the City, its elected officials. officers, agents and employees, as therein''Stipulaited. then this
C? ;t1i3 11x31£
become null and ,oid, other: t ea it shall be and remain in tell tbrce and effect,
As a pan of tris.,`` e �;, s t-on `secured hereby and Y2 itttcn the fiicL ag3 m _� twattftherefore. there Shaft
be included costs and reaso iable expenses and tees, including reasonable attC)rne s fees incurred by the
C R in s.=cess ally- e:i ki-cing stii:h €:bl gat ML A! to be taxed as costes and includtad in any judgment
rendered.
tic sumtv hereby stipulates and agrees that ria) � ,- , ah � >
u„ ct<a:i t. L 1c�n7tiliirS ts, tt: t >at2t}i t: a t t?it3Ti to ? it.
tem.of i;.iL c>;?rC'.£.s1'i C`n't or To One work to be t'`it. Art'i: e_d dhert:uIiLt.er orthe .`
e si"tt_ stis,saticsa accompanying
same ar,e";li in any"'ise Me , Rs t 3.i_'„3iIOns On this 'rt)nd. and ,t does 1wreby wake notice of mg rmh
chazl se, e'.."� ns„ion s erne, alteration or n(jd tiOn to tof gernns 3 the a re;e mnera or to the work l E
r I{ f)a" it) the
spec]i izcat icnls.
In wKn ss whereof, this it-istrurnent has been duty executed by the Principal and Surety above, ttanytcdi on
T.........3,..0_.....................w_. __.._.............._.__'7I,i09l
__5,.ag! __We_st Pump & Drilli Ince Insurance Company of the i st
(Str tv)
C��OSi�?21 nure I �.. (S4c,"Yi'ttir'e
) Diane M Nielsen
10.509 Vista Sorrento Pkwy ;x31.0
eiti:Ls :.S.a1+-_--D4'e,. 3- _CA _9 2.1..2-1 ..._..
i s_,t �c�t.e,� t< i;_g,�s't._ or
;gray)
STATE OF CALIFORNIA
COUNTY OF RIVERSIDE
ON ---IQ30111� - , BEFORE ME, LINDA ROCHA, Notary Public
PERSONALLY APPEARED:_ Diane M. Nielsen_____
Who proved to me on the basis of satisfactory evidence to be the person (s) whose name (s) is/are
subscribed to the within instrument & acknowledged to me that he/she/they executed the same in
his/her/their authorized capacity (ies), and that by his/her/their signatures (s) on the instrument the
person (s), or the entity upon behalf of which the person (s) acted, executed the instrument.
I certify under penalty of perjury under the laws of the State of California that the foregoing
paragraph is true and correct.
LINDA ROCHA
commission # 1777932
WITNESS my hand and official seat.
Notary Public -California
Riverside County
Mycorr1r,E095�-�23,2011
Signatur
i,, da Rocha, Notary
ALL PURPOSE ACKNOWLEDGMENT
STATE OF CALIFORNIA
COUNTY OF RIVERSIDE
ON—3 to�'- a 2010, BEFORE ME, C. WAASDORP, Notary Public
PERSONALLY APPEARD: CURTIS MCCALLA
Who proved to me on the basis of satisfactory evidence to be the person whose name is
subscribed to the within instrument and acknowledged to me that he executed the same in his
authorized capacity, and that his signatures on the instrument the person, or the entity upon
behalf of which the person acted, executed the instrument,
1 certify under penalty of perjury under the laws of the State of California that the foregoing
paragraph is true and correct,
WITNESS mrd an4/offici seal. ------------------------------------------------
C.W AMA NOWN
Signature: COW#1834M
NOT PUBM®CALFORNIA9
RNERSIDE CoLqm
C. Waasclorp, Notaryt a i
ALL PURPOSE ACKNOWLEDGMENT
Bond # : 2303300
Premium: lncluded in Performan(
Bond
LkBOR AND NIA'FERIAL BOND
Vv`hereas, i Cliv Council ofhe Citys,t Redilaads, Suite lcil,'Cahi'ornia, and South Wes t Pum
and Drilling, Tnc. _(hereinafter de,',i,plated as -Pri'llcipal-) ha�,e
entered into an a�),reernent whereby Principal agrees, to install and complete cer-min designated public
e
in1proveirients, which said agreement, dated -11a `010, and idntified as
Nlentone Acres 2, Well and Puny Rehabilitation Project is hereby referred to and made a part
hereof-, and
Whereas, under the terms of said agreement, Principal is required befiare entering upon the performance
of the work, to file a good and sufficient payment bond with the City of Redlands to secure the claims to
which reference is made in Title 15 (commencing with Section 3082) of Part 4 of Division 3 of the Civil
Ccde of the State of California,
Now, therefore, said Principal and the undersigned as corporate surety, a,e held firmtv bound unto the
Cily Of Redlands and all contractors, subcontractors, ]aborers, material -,-,ten and other persons employed
in the performance of the aire said agreement and referred to in the aforesaid Code of Civil Procedure 'in
the sum of—*-*`-* ' Dollars (S 8 3-1-25-2 . Wor materials "urnished or labor
on,
thereof any kind, or for aniounts due under the Unerriploly-nent, Insurance Act -with respect to such
work or labor, that said surety will pay the sarrie in an amount not exceeding tile arnount hereinabove set
6orih, and also in case salt is brought uvon this bond, will pay, in addition to the tacit amount thereof,
costs and reasonable expenses and fees, including reasonable attorney s fees, inciirred by the City of
Redlands in successftfllv enforcinJI, such oblioation, to be a"arded and fixe l bv the court, ail d to be taxed
"s Coll;
ts and to be included in tiltJudginein therein rendered,
it is hereby expressly stipulated and agreed that this and shall insure to the benefit of any and all
perst-,-,ns, conipanics and corporations entitled to file clainis under Title 15 (commencing with Section
1082) of Pan -4 ofDi%ision 3 of[he Civd Code, so as to Llive a rialit of action to thern or theirassigns in
an- su4 brou-In upont this bond,
Should the condit'on of thins bond be foliv ncrforn-,ed, then this obligation shall become null and void,
u"ham.r;Vise it :at be and reniain in fu.#. force and
ettect.
The suretv, herebv stipilknez and a(-,rces that no chianae, extLrision of tinie, aiteration or addi6on to the
ications, accompativ snail manner .i tit its
,el'Ms "'t said aclecinctit or the specitl Ying The San. , d in any ,
t)b1i,oat;ons on, this bond. and a does hereby wi.ve notice of any such change, extension of time, alteration
o-addition.
In ,w itness Ahereof. this instrument has been duly executed by the Principal and surety above,natr�ed, on
y 3 0 -1010.
(S 6Al-)
South West Pump & Drillic. Insurance Companv of fh '` ";t
7—Mi i i F 3 c—10 f (S ret
(S til M Nielsen
10509 Vista Sorrento #310
San Deo , CA
4t,'M�11,0� u re 1 clephone8 5a 5 1 J. -7ndf N k ti I i al Ac k n oo�1 e d tZ
----��310
�i ......
"Bond Amount : Eighty Three Thousand Two Hundred Fifty Two Dollars & 00/ 100
STATE OF CALIFORNIA
I
COUNTY OF RIVERSIDE
ON r��' , BEFORE ME, LINDA ROCHA, Notary Public
PERSONALLY APPEARED:_ Diane M. Nielsen
Who proved to me on the basis of satisfactory evidence to be the person (s) whose name(s) is/are
subscribed to the within instrument & acknowledged to me that he/she/they executed the same in
his/her/their authorized capacity (ies), and that by his/her/their signatures (s) on the instrument the
person (s), or the entity upon behalf of which the person (s) acted,executed the instrument.
I certify under penalty of perjury under the laws of the State of California that the foregoing
paragraph is true and correct.
DA
WITNESS my hand and official seal. Lit,
g �� CommissPOCHA
ion ;777,3,
RJVq-S!oA, County
Signature(-' PaR
icha, Notary
AI.L PURPOSE ACKNOWLEDGMENT
TCW GROUP No. 0004214
Power of Attorney
Insurance Company of the West
Explorer Insurance Company Independence Casualty and Surety Company
KNOW ALL MEN BY THESE PRESENTS. That Insurance Company of the West,a Corporation duly organized under the laws of the State of California, Explorer
Insurance Company,a Corporation duly organized under the laws of the State of California,and Independence Casualty and Surety Companya Corporation duly organized
under the laws of the State of Texas,(collectively referred to as the"Companies"),do hereby appoint ,
PAUL W.LEWIS,ANN WILLARD.DIANE M.NIEI.SEN
Ctheir true and lawful Attomey(s)-in-Fact with authority to date,execute,sign,seal,and deliver on behalf of the Companies,fidelity and surety bonds,undertakings,and other
similar contracts of'suretyship,and any related documents.
CIn witness whereof,the Companies have caused these presents to be executed by its duly authorized officers this 2nd day of January,2008.
G\
z��ooeroxurFo�a tu`c r�8
�owrxaro� d`'UR�,y §
INSURANCE COMPANY OF THE WEST
EXPLORER INSURANCE COMPANY
a ! s.�f INDEPENDENCE CASUALTY AND SURE'T'Y COMPANY
Jeffrey D.Sweeney,Assistant Secretary_ J.Douglas Browne,Senior Vice President
State of California }ss.
County of San Diego
On May 21,2009,before me,JoAnn Pache,Notary Public,personally appeared J_Douglas Browne and Jeffrey D.Sweeney,who proved to me on the basis of satisfactory
evidence to be the person(s)whose name(s)is/are subscribed to the w thin instrument,and acknowledged to me that they executed the same in their authorized capacities,and
that by their signatures on the instrument,the entity upon behalf of which the persons acted,executed the instrument
I certify under PENALTY OF PERJURY under the laws of the State of Califomia that the foregoing paragraph is true and correct.
Witness my hand and official seal.
WA FW
my
JoAnn Pache,Notary Public
I
RESOLUTIONS
This Power of Attomey is granted and is signed,sealed and notarized with facsimile signatures and seals under authority of the following resol ttions adopted bthe respective
Boards of Directors of each of the Companies: y
"RESOLVED: That the President,an Executive or Senior Vice President of the Company,together with the Secretary or any Assistant Secretary,are
hereby authorized to execute Powers of Attorney appointing the person(s)named as Attorney(s)-in-Fact to date,execute,sign,seal,and deliver on
behalf of the Company,fidelity and surety bonds,undertakings,and other similar contracts of suretyship,and any related documents.
RESOLVED FURTHER: That the signatures of the officers making the appointment,and the signature of any officer certifying the validity and
current status of the appointment,may be facsimile representations of those signatures;and the signature and seal of any notary,and the seal of the
Company,may be facsimile representations of those signatures and seals,and such facsimile representations shall have the same force and effect as if
manually affixed. The facsimile representations referred to herein may be affixed by stamping,printing,typing,or photocopying"
CERTIFICATE
1,the undersigned,Assistant Secretary of Insurance Company of the West,Explorer Insurance Company,and Independence Casualty and Surety Company,do hereby certify
that the foregoing Power of Attorney is in full force and effect,and has not been revoked,and that the above resolutions were duly adopted by the respective Boards of
Directors of the Companies,and are now in full force.
IN WITNESS WHEREOF,I have set my hand this 30 t h day of _ May _ 2010
Jeffrey D.Sweeney,Assistant Secretary
To verify the authenticity of this Power of Attorney you may call 1-800-877-1111 and ask for the Surety Division_ Please refer to the Power of Attomey Number,the above
named individual(s)and details of the bond to which the power is attached For information or filing claims,please contact Surety Claims,ICW Group. 11455 Et Camino
Real,San Diego,CA 92130-2045 or call(858)350-24(3
STATE OF CALIFORNIA
COUNTY OF RIVERSIDE
ON , "0r__ Q- 2010, BEFORE ME, C. WAASDORP, NotaryPublic
PERSONALLY APPEARD: CURTIS MCCALLA
Who proved to me on the basis of satisfactory evidence to be the person whose name is
subscribed to the within instrument and acknowledged to me that he executed the same in his
authorized capacity, and that his signatures on the instrument the person, or the entity upon
behalf of which the person acted, executed the instrument.
I certify under penalty of perjury under the laws of the State of California that the foregoing
paragraph is true and correct.
WITNESS rhd a offi al seal. `---- 9
COMM.0834
Signature: 4aNOtARYPt1 couw rMW`OWFORMA
G Waasdorp, Nota
ALL PURPOSE ACKNOWLEDGMENT
May 30, 2010
Insured: South West Pump & Drilling, Inc.
Policy. 22 UEV JC 6817—Hartford Underwriters Insurance Company
i
This endorsement changes the policy. Please read it carefully.
ADDITIONAL INSURED -AUTOMATIC STATUS PER CONTRACT
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
The following persons or organizations are an additional insured when you have agreed in a written
contract or agreement, that such person or organization be added as an additional insured on your
policy,provided the loss occurs subsequent to the execution of the contract or agreement. The
additional insured status applies only for that period of time required by the contract or agreement.
HG 00 0106 05
PRIMARY
Coverage provided by this policy shall be primary insurance but only as respects any claim, loss or
liability arising out of the operations of the named insured and any insurance maintained by the
additional insureds shall be non-contributing.
WAIVER OF SUBROGATION
It is agreed that the companies reflected on Certificate waive any right of subrogation against the
additional insureds which might arise by reason of any payment under the policy.
Name of person or organization SCHEDULE
City of Redlands
LTS Internet Shipping: Shipment Receipt
Page I of I
Shipment Receipt
Transaction Date: 02 Jur,2010
Tracking Number: 1ZF903VJ513934,37402
1......................................11-1-111-1--11111111-1............................................................................ .............. ........
Address Inforriliarion
Ship To: Ship From:
Return Address:
City of Redlands South West Pump&Drilling,inc South Wast Pump&Drilling Jhc,
David McClellan Chris Waasclorp Chris Waasclorp
35 Caped Street 53-361 Highway 111 53-381 Highway 111
Suite 15A COACHELLA CA 92236 COACHELLA CA 92236
Muni Utilities&Eng Dept Telephone:760-398-3977 005 Telephone:760-398-3977 x105
it REDLANDS CA 92373-4746
Telephone 909-798-7504 x1
........... ............. ......................................... ............
............ ............................................ .......... .......................... ...... ............ .................................................................................... ....................
Package information
Weight Dimensions Packaging
Declared Value Reference Numbers
Letter UPS Letter
.................. ............ .................. ......................... .................... ...........................
............ ........
UPS Shipping Service and Shipping Options
Service:
UPS Next Day Air Saver
Guaranteed By:':
3:00 P.M.Thursday,61312010
Shipping Fees Subtotal:
15-19 USD
Transportation 1-.4.00 USD
Fuel Surcharge
1.19 USD
........... ................ --------------- ............... ...............
Payment informarliont
Bill Shipping Charges to:
Shipper's Account F903VIV5
Total Charged:
15.19 USD
------------- --------- -----------........ .......... -----------
Note:Year invoice may vary from the do,played reference rates
1'For delivery and guarantee information see the To speak to a call 11-800-PICK-UPS for domestic se-ces
services. and 1-800-782-7892 for mternatjoral
Responsibility for Loss or Damage
Unless a greater ane is recorded in the declared vaf.e field as appropriate For the UPS snWing system,used,the shipper agrees brah the released VaUs�f each package--overed by this receipt s no
greateirthsol$100 y ecainng.hghp,
,aloe and Paying an add Sona`charge US vd-s-ct accept for hansp,cfalom and shtimers recicesfing service�hrougn the intemet are poohleted Im b d
S50.0041 The maXmjM� ty o sh�prcnlg packages
otah per package ass.modoy UPS shall net exceed S50,001),regardless Ofvafue in excess of the mar mum�,almanot ma nine
Mort a raf�e m`mrre than
hs after dehrely of rhe package
.aived The entry of a C 0 D amount�s not a I-ecaratort of value s aftel a reasOnglde time for delivery has efaieved fitirtydays fo,mtentatiOnai Sh*rhsrdsi Sharbedeemed
Itirdy days for ioternationai shircents) or in the�dirtc vf FaVkile to make dahriey, -:ice MOM d r,
de for carriage porpos-,AlAi cherks or other negptsacre instrumen#s Tendered in bary rent el C.0 0
contained�n the UPS Tyarqff and the Jos 7emla arid Cnodpons or
UPS shat; ot be raine for any special inicrontai,or conseq-,dia!damages.Ail aeiphre-�ts are subtest the terms 8MI conciftores cc, 11 be-,cetrredl by UPS at sh,preet,risk.
Sairvcdi,It.od',can be bond at aono,ro co,
0 0 .3
https: UPS,coml Ui S/ereate.Actio nOrig 1 nPai r=pri nt----LJ IS Receipt&,POP(j P LEVEL=— 61')1?010
INrz
w
z
Well Rehabilitation - On motion of Mayor Pro Tem Bean, seconded by
Councilmember Gallagher, the City C.`ouncil unanimously determined the
approval of an agreement for the rehabilitation of klentone Acres Well No. 2 is
categorically exempt from further environmental review in accordance with the
California E=nvironmental Quality Act and awarded a construction contract with
South Fest Pump and Drilling, Inc. to rehabilitate the well.
Pipeline Replacement Project - On motion of Mayor Pro Tem Bean, seconded
by Councilmember Gallagher, the City Council unanimously determined the
approval of an agreement and construction of the Brookside Avenue Sewer
Pipeline Replacement Project is categorically exempt from further
environmental review in accordance with the California Environmental Quality
Act, approved plans and specifications for the project and awarded a
construction contract for the work to MCC Equipment Rentals, Inc.
Pavement Repair Project - On motion of Mayor Pro Tern Bean, seconded by
Councilmember Gallagher, the City Council unanimously determined the
approval of an agreement and construction of the Nevada Street Sewer Trench
Repair Project is categorically exempt from further environmental review in
accordance with the California Environmental Quality Act, approved plans and
specifications for the project and awarded a construction contract for the work to
TE Roberts, Inc.
NEW BEISINESS:
Resolution leo. 6941 — Desert Protection -- Marisa Calderon, of the California
Wilderness Coalition, provided a presentation on the California Desert
Protection Act of 2010, a bill to designate certain federally owned lands in
Southern California as National Monuments and Off Highway Vehicle
Recreation ,areas for the purpose of creating. a framework to address renewable
energy development, recreation on these lands and ecotourism in the area.
Several speakers, representing P ' ,� diverse groups. provided public comments in
support of the hill. Mayor Pro Tem Bean expressed concern that no one was
Present to speak against the bill. He pointed out that a proper decision should
consider both sides of an argument. On motion of Councilmember Aguilar,
seconded by Councilrnember Harrison, the City Council unanimously approved
Resolution No. 1 endorsing and supporting the designation of wilderness,
wild and scenic rivers, national monuments and National Park and Preserve
wilderness additions within the (:alifornia Desert Conservation Area.
Budget. Advisory C:;omrnittee - On motion of` ;Mayor Gilbreath, seconded by
Mayor Pro Tem Bean, the Cite Council voted to approve the appointment of
Mayor Pro Tem Bean and Council Member Gallas#her to an Ad-hoc Fiscal Year
20I0-2011 I Budget Advisory Committee whose purpose is to advise the CitV`
council, the City Manager and staff regarding that budget. The committee's
duration is to be limited and it is not subject to the Brown ,=pct. Councilmember
April 20, 2010
Page 3
I