Loading...
HomeMy WebLinkAboutContracts & Agreements_222-2021PUBLIC WORK CONSTRUCTION CONTRACT This Public Work Construction contract ("Contract") is made and entered into this 7th day of December, 2021, by and between the City of Redlands, a municipal corporation, organized and existing under the laws of the State of California (hereinafter "City"), and Southwest Pipeline and Trenchless Corp., a California corporation (hereinafter "Contractor"). City and Contractor are sometimes individually referred to herein as a "Party" and, together, as the "Parties." In consideration of the mutual promises contained herein, City and Contractor agree as follows 1 SCOPE OF WORK. Contractor shall furnish all materials and will perform all of the work for the following: 2021 CIP Sewer Pipeline Replacement Project, complete all items as required by the Contract Documents (as herein defined) and Specifications for City's 2021 CIF Sewer Pipeline Replacement Project, Project No 521021 (the "Work") 2. CONTRACT SUM. City shall pay Contractor the sum of three hundred nine thousand eight hundred fifty two dollars ($309,852) as consideration for its performance of the Work in accordance with the terms and conditions set forth in the Contract Documents. Pursuant to Public Contract Code Section 22300, Contractor has the option to deposit securities with an escrow agent as a substitute for retention of earnings required to be withheld by City pursuant to an escrow agreement as set forth in Public Contract Code section 22300 3 TIME FOR COMPLETION The Work shall be completed within seventy (70) calendar days from and after the date of City's issuance of a Notice to Proceed to Contractor 4 LIQUIDATED DAMAGES. Contractor's failure to complete the Work within the time allowed will result in damages being sustained by City Such damages are, and will continue to be, impracticable and extremely difficult to determine. Accordingly, Contractor shall pay to City, or have withheld from monies due to Contractor, the sum of five hundred dollars ($500) for each consecutive calendar day in excess of the specified time for completion of the Work. Execution of this Contract shall constitute agreement by City and Contractor that five hundred dollars ($500) per day is the estimated damage to City caused by the failure of the Contractor to complete the work within the allowed time. Such sum is liquidated damages and shall not be construed as a penalty, and may be deducted from payments due the Contractor if such delay occurs. 5 CONTRACT DOCUMENTS This Contract incorporates by reference the following: Notice Inviting Bids, Instructions to Bidders, Contractor's Proposal, Bid Bond, Agreement, Performance Bond, Labor and Material Bond, Plans, General Conditions, Special Provisions and Specifications, and any addenda thereto (collectively, the "Contract Documents"). 6 ATTORNEYS' FEES. In the event any action is commenced to enforce or interpret the terms or conditions of this Contract, or the Contract Documents, the prevailing Party in such action, in addition to any costs and other relief, shall be entitled to recover its reasonable attorneys' fees, including fees for use of in-house counsel by a Party 7 RESOLUTION OF CONSTRUCTION CLAIMS Claims by Contractor in the amount of three hundred seventy five thousand dollars ($375,000) or less shall be made by Contractor and processed by the City pursuant to the provisions of Part 3, Chapter 1, Article 1.5 of the Public Contract Code (commencing with Section 20104). All claims shall be in writing and include the documents necessary to substantiate the claim. Nothing in subdivision (a) of Public Contract Code L.\ca\djm\Agrcernents\southwest Pipeline.PW 3 1.PY21-0049.doc.jn Section 20104.2 shall extend the time limit or supersede the notice requirements provided in this case from filing claims by Contractor 8. ELIGIBILITY OF CONTRACTOR/SUBCONTRACTOR. Contractor and all of its subcontractors shall abide by California Public Contract Code, Section 6109, and California Labor Code Sections 1777 1 and/or 1777 7, and certify that they are not debarred and are eligible to work on this project. 9 ASSIGNMENT OF AGREEMENT No assignment by a Party of any rights or interests under this Contract shall be binding on another Party without the written consent of the Party sought to be bound. 10. SUCCESSORS AND ASSIGNS City and Contractor each binds itself and their respective successors and assigns in respect to all covenants, agreements, and obligations contained in the Contract Documents. 11 SEVERABILITY Any provision or part of the Contract Documents held to be void or unenforceable under any law or regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon City and Contractor 2 L.\ca\djm\Agreements \Southwest Pipeline.PW-3 1.PY21-0049.doc.jn IN WITNESS WHEREOF, the Parties hereto have executed this Contract the day and year first written above (SEAL) ATTEST e Donaldson, city Clerk CIT OF REDLANDS By Paul T Barich, Mayor Southwes Pipeline and Trenchless Corp Name of C i ntractor By (SEAL) re of Authorized Agent President Title Signature of Authorized Agent (if necessary) Title Contractor's License No 3 L \ca\djm\Agreements\Southwest Pipeline.PW 3 1 FY21 0049.doc.jn WORKER'S COMPENSATION INSURANCE CERTIFICATION ' Description of Contract City of Redlands Municipal Utilities & Engineering Department 2021 CIP SEWER PIPELINE REPLACEMENT PROJECT, Project No 521021 Every employer, except the State, shall secure the payment of compensation in one or more of the following ways a By being insured against liability to pay compensation by one or more insurers duly authorized to write compensation insurance in this State b By securing from the Director of Industrial Relations, a certificate of consent to self - insure, either as an individual employer, or as one employer in a group of employers, which may be given upon furnishing proof satisfactory to the Director of Industrial Relations of ability to self -insure and to pay any compensation that may become due to his or her employees CHECK ONE xx I am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against liability for Workers' Compensation or to undertake self-insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work and activities required or permitted under this Agreement (Labor Code §1861) I affirm that at all times, in performing the work and activities required or permitted under this Agreement, I shall not employ any person in any manner such that I become subject to the workers' compensation laws of California However, at any time, if I employ any person such that I become subject to the workers' compensation laws of California, immediately I shall provide the City with a certificate of consent to self -insure, or a certification of workers' compensation insurance I certify under penalty of perjury under the laws of the Sta - e California that the information and representations made in this certificate are true and co - t Dated this 24 day of November , 2021 Southwes ipeline and Trenchless Corp (Con i L (Signature) (Official Title) Presid: t (SEAL) (Labor Code Section 1861 provides that the above certificate must be signed and filed by the Contractor with the Owner pnor to performing the work of the contract ) 4 L \ca\djm\Agreements\Southwest Pipeline.PW 3 1 FY21 0049.doc.in Bond Number 024256104 Premium. $3,882.00 FAITHFUL PERFORMANCE BOND Southwest Pipeline Whereas, the City of Redlands ("City"), State of California, and and Trenchless Corp (hereinafter designated as "Principal") have entered into an agreement dated December 7 2021 ("Agreement") whereby Principal agrees to install andcomplete certain public improvements (the "Work"), which said Agreement is identified as 2021 CIP Sewer Pipeline Replacement Project No 59109.1 and is hereby referred to and made a part hereof; and Whereas, said Principal is required under the terms of the Agreement to furnish a bond for the faithful performance of the Work, now, therefore, we, the Principal and, Liberty Mutual Insurance Company , as Surety, are held and firmly bound unto the City 1n the penal sum of Three Hundred Nine Thousand Eight Hundred Fifty Two and 00/100 dollars ($ 309,852.00 ) lawful money of the United States, for the payment of which sum we bind ourselves, and our heirs, successors, executors and administrators, jointly and severally, firmly by these presents. The condition of this obligation is such that if the above bounded Principal, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and provisions in the Agreement and any alteration thereof made as therein provided, on his or its part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall faithfully fulfill the one-year guarantee of all materials and workmanship, and shall defend, indemnify and save harmless the City and its elected officials, officers, agents and employees, as therein stipulated, then this obligation shall become null and void, otherwise it shall be and remain in full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefor, there shall be included costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligations, all to be taxed as costs and included in the judgment rendered. As a condition precedent to the satisfactory completion of the Work, the above obligation shall hold good for a period of one (1) year or longer if required by the Agreement after the acceptance of the work by the City, during which time if the Principal shall fail to make full, complete, and satisfactory repair and replacements and totally protect the City from loss or damage made evident during this period from the date of completion of the Work, and resulting from or caused by defective materials or faulty workmanship, the above obligation in penal sum thereof shall remain in full force and effect. The obligations of Surety hereunder shall continue so long as any obligation of the Principal remains Whenever the Principal shall be, and is declared by the City to be, in default under the Agreement, the City having performed the City obligations thereunder, the Surety shall promptly remedy the default, or shall promptly, at the City's option. 1 Complete the Work in accordance with its terms and conditions, or 2. Obtain a bid or bids for completing the Work in accordance with its terms and conditions, and upon determination by Surety of the lowest responsive and responsible bidder, arrange for a contract between such bidder and the City, and make available as work progresses sufficient funds to pay the cost of completion of the Work less the balance of the Agreement price, but not exceeding, including other costs and damages for which Surety may be liable hereunder, the amount set forth above. The term "balance of the Agreement price," as used in this paragraph, shall mean the total amount payable to the Principal by the City under the Agreement and any modifications thereto, less the amount previously properly paid by the City to the Principal. Surety expressly agrees that the City may reject any contractor or subcontractor which may be proposed by CD 6 Surety in fulfillment of its obligations in the event of default by the Principal Surety shall not utilize the Principal in completing the Work nor shall Surety accept a bid from the Prmcipal for completion of the Work if the City, when declaring the Principal in default, notifies Surety of the City's objection to the Principal's further participation in the completion of the Work No right of action shall accrue on the bond to or for the use of any person or corporation other than the City named herein or the successors or assigns of the City Any suit under this bond must be instituted within the applicable statute of limitations period The said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or to the work to be performed thereunder or the Specifications accompanying the same shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Agreement or to the work or to the specifications No final settlement between the City and the Principal shall abridge the right of any beneficiary hereunder whose claim may be unsatisfied The Principal and Surety agree that if the City is required to engage the services of any attorney in connection with the enforcement of this bond, each shall pay the City's reasonable attorneys' fees incurred, with or without suit, m addition to the above sum In witness whereof, this instrument has been duly executed by the Principal and Surety above named, on December 7 , 2021 Southwest ,'ipelme and Trenchless CorSEAL) (Contract. (SEAL) Liberty M al lnsurance Company BY (Signature) (Signature) N Address 790 The City Dnve South uiroz, Attorney-m-Fact Orange, CA 92868 (Seal and Notarial Acknowledgment of Telephone (714 ) 634-5720 Surety) CD 7 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 �l. ':.....�. .. ..\. ...� ...:. _.._... .��.;-,.. .. .."..rl �. .��,,..\.. .��r. :��:.. ..�. .:vim... .�, -. .� .� .�........�\ ..\ ....... .. ..� .�. .... A notary public or other officer completing this certificate verifies only the identity of the Individual who signed the document to which this certificate Is attached, and not the truthfulness, accuracy, or validity of that document. State of Califomia County of Los Angeles On 12. 7 - 2 / before me, Date Robert Bolger, Notary Public Here Insert Name and Title of the Officer personally appeared Justin Duchaineau Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capaoity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the Instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature Sig re of Notary Public ROBERT BOLGER Notary Public California Los Angeles County Commission # 2236371 My Comm. Expires Mar 30 2022 Place Notary Seal Above OPTIONAL Though thls section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: L� Corporate Officer — Title(s): Li Partner — 0 Limited ❑ General ❑ Individual ❑ Attorney in Fact 0 Trustee 0 Guardian or Conservator 0 Other Signer Is Representing: Signer's Name: 0 Corporate Officer — Tltle(s): ❑ Partner — 0 Limited 0 General 0 Individual 0 Attorney In Fact 0 Trustee ❑ Guardian or Conservator 0 Other Signer Is Representing: e 02014 National Notary Association www.NationalNotary.org 1-800-US NOTARY (1-800-876-6827) Item #5907 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT Civil Code § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy or validity of that document State of California County of Los Angeles On `" " - 2' I , before me, Natalie K Trofimoff, Notary Public, personally appeared ss Noemi Quiroz , who proved to me on the basis of satisfactory evidence to be the person-s} whose name{s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/t#e+r authorized capacity{ies}, and that by his/her/their signature{-} on the instrument the person{-}, or the entity upon behalf of which the person(s) acted, executed the instrument I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct WITNESS my hand and official seal NATALIE K TG077r COi= i `• 2.7 129 ,OS ANGELES CL 1Y kly Comm Ex ir,C,T22 Signature. (Seal) Natalie K Trofimoff, Notar P blic Thls Rawer Of AttorfieylfrnItt;the.aOts of those named hereln,-and thoy-have•noluttiorityte'btridthe-C.oittnany.excent In the Mariner and to.theeidentherein Stated: Not, valld-for mortgage,-note;toan, letter of.oredit,- bank deppeit.currency rate, interest rate or reelduth value guarantees For bond.andler Power of Attorney (pON yerifioation utitrieeiplease .call 610,832-B241:ter einall-NOStik@libertyrnettiaLcorn, Uberty Mutual. SURETY Liberty kutitg.insurance Company The Ohio CagiMIty IhsoMnte:COMpany WeSt ArtieriBBB- 'OSLO:Odd CoMpany POWER OF ATTORNEY KNOWNALL PERSONS BY THESE P.R1S$NITS: thatItie.Ohlo.Caenalty InenranOetenvertYtee oOtpOtation delrgenitedOnderthe lakkr ef the -State ef.Newl-fatepshire,:thStLitierty Mutual Inattrance:.CoresanyiSs terbetationstulyOrganttett•iteder. the taWs Of the $tate'ef:Nake aditieetta,itid.WeSt-Mtaffeart. lflsuranc Company is'SSOrporationdaty.organIzed-bndet the lews af the Stateof indianaAtierein-golleotivetvgaltedthetertipanies1;:psisuent to.an&by-suthertty herein set fortkdoes herebynamei.conslitina andappoint;Noemi Quiroz The.tity 0? Los Angeles . state�f . CA Stleritepin-ei6Withfuligbiver Srittautheriiy hereby conferred taSigri,:eiOdute and adkrieMerfgalhefolieWing surety bond:: PitifolOat Neale: southwest Pipeline and Treno.htess corp.„ obligee .qty of Redlands serety Bond Number . .. .024266104 . . Rod Amount SOR EgOnOt IN•WITNESSWHEREOF ititSpoier trAiici,rno:ha's-ixibri.etiSSStitied by ad dtdlioti2dd bffeef eteffi ciel CothtiehieSSed: the tetperitsteals. thSeenfpiehieShaVsbeeitallixed: thereto this dayof March, 201., The Qh1O•,Caeeelty.lhecgRPOe.CoirVany iiberty MPt,OPI;inaPr4nce Company Wee merloneurance•Compeny. • 'David itif:Osrey,ASititaritse&retory. .8TATp.E. i:).PN§,Y1f,Y.A1%.11A 85 .00LINTY MONTGOMPIY On thie:120! . day...61, Mareli,.20.21,, befOhtl. the:net:Soppily SOOSStanetrilltil: Careyiiwhe.eektididetedhlmeeltte be theMetatant Secretary aLili.briy:MUtpOilMnranee.C.Onipahy, The. OtilSqegtmity P0111P0; 11.t.iN‘l@gAnigritall.10410r1.PC-9mOlir and ttIat. ti•ei,a.s..ssch„.being-.atithori4e.ct•So:to tie, ekeehteteforegoinglnannent-fOrthe'ptunoseethefein..Contained by signin0.00-behalf Ofthe derporatiens by himself -Asa ,001yebtherized efficer. INWITNESS W HEREOF; IlieVe bereubtoeunsoilbed:rev fie ale and affiied triV:iinterfatMetat Kilid•ofPrneele,PonnevIvenie, ciifthe daVand:venffirStaboile.Written, CaniiTionwealth ofreartsylventa- Notary Seal YereS3:144iStellk.NOtatIPubIld - Adia/A) igzr.:Viii.) hiforitgontery County ii0.. • • - '1'qrfaso-Pastejle,..RIOtary.publiO, MY tOrnmtaalorrOXpites.MOrch 26,..21i6 CortindSeidni number 1'12604.4 . . . **AIY.'13. • .Whitentier', Penneyhiania:Aesociation:Of Notaries TN'S Foierd AtfOrpo -Imada;end..eisdedtc4dreyrsgnt to and by atilhoritY et ine letloytitne tiy.400, and Adtherizatibria.et Liberty Ritual tnearattOa.COMpany, .1 he OntOiCastialtyfristirance COnigany, and.*4tAlnericati hisbreace gotnneny.whiChreaeldtiena enIneiv.lrf fOrce•and affeCtrnading as follows: ARTICLE:IV 7-OFFICERS.-.S4tiOn.12..P.Oerof.AttotneY.My-officeferethdr official:orthe-CorboratiOn ab(horized:fer that. tiurpeSSin:Wiltit hyttte: Chainnakorthe'Preeklerit 1 and subject lo et0.jifiii.tatip.-g.the.cheirroaSsr.th9..Pf9s.idcOt-Oyi)f.Ps.01.?P;'*411•PPP9irttPVM..qttprOsys-11;feqt,P.reey he..nPcaeaY.tqac.t.-1!1'.bef)alf effhelPiOrpOrattento rneicei.execste, seal,lioknoVvIedne end deliveries serety any all'iinderlakiveibonds, redotifillentes.and Statity.oblkjatione. Subh:atterifeiye.in;faCt,:stiblectkithe lirnitatitine-settadli it their reSpeCtlye.boyi.ete::Of attorney shall hayaluttpdwerto bind tfie;.0.f0Orattati by their etonaterp.and.exestitien.er any.-Stiehinstruniankend.to;attech,thorete the seal of the:Corporation, When so egeouted, euettinstrurnefita-andPbeea.blnOttio.gelf. al4necl:hy:the POStdetil.and ettestad.te-by.ttte Secretary,Any. power or authorityauthonly granled te atty,:representethre.or attorney, '1114dt:tinder the; droVieldrfthiSattidle'nlaY be iStioked athtiYinteby-thaderit -the .Clial(OW,the:PreSidenter. bSillie.dfflr:Brotfit4tt grtntitig ekti. pet* cirtethority. ARTICLE XIIt --:Exeptttion Of Contracte:,‘'.6EcTIO 5-..,guretytands.and:Undeitekinge, -Any otter afthetompenyeqthorigd:fOrthR(p4rpoe0 lnvdt1pa by the:ehatiman or the.president, rid.aubjent toenclilltinitatione as the Mahal ari or (he pre$:100fit may prescribe,. shalt atibbintSeth afterrieiSilrgeeti as may be inecea.eatylo eat in-behalfof the corhoany to Stake r ette(-Ste, seal, acknowledge and deliver as surety any and alt UndeileItogs bonds reconizanoes arid:ether. ebretyoblfg Oen.s §001 ettenieWin4.00Sybjedt id thefilitittetipOSSet. fettle:their respective powers of attorney shelf have-fulf,power to bind the:,COrnpanyby.thalreignature and:qeen(len ofany such Instruments anOAd..attach,theratoiho seal of the COrnpanyWhen so 6.*.ecuted audit inetrufeents,ehalite.aetindiri§-as ifekiried byte president and"eiteeted.bytha'ssidratanj. Cettitteetd OiDeeignatien Thes.Proefdentef the-Contoany',-.ectinq paceuent to-the-Ryfativ.e.ofthe geoppy-, sethoitzeepoytti fvt..CaNy, reeiptarit Secretary to appoint SUO. attemeys-irt- ieet as nay be necessary to act -ou•behalf.Of the:tOnlbanY tetnakai Otecigeeepti.acknoW!edne.and deliver as surely any end el undertakings bonds;. recognixences and.other surely obligations; A000d*on-,-,By onomm;conseopfthetemnapy pleard.ablreotors,thotornpany oonsentohatfaostodear.roochonioalty reproduced 4i0nature.of.any.,esetstant secretary of the- deinfiany..WheieVer' ebbearino,d0bii adeiff.4ed -Copy of any Oliver Of attorney issued by'thatdmbany in.Ootitiectien-vvith euretyberkia,.-Shati ba..Valtel andbiridino.ubdithif Company with the aatne (604 rid .effect ealliengh manually affixed. I, -Renee the iinclerSignedi Aeetitenfteeretery;-stliWrtyllislosilnsurance COnipany T.he-Ohte Casualty insurance Ceft(pany .and.WastAmOrken-instirenCortornOphy detareby Cenifythatifile.0yVer:ofettet*iikeeuted bysaid Companies istnMl torbe atideffebt althea ntitibeertraVeked. litiTOTIM0NYWHEROF have herepotoset-my.handsn.S-s.ffi10e0 the.applatfeard.Companles this. 7th day of December 2021 By: Renee C. LleWellyn, Assistant Secretary Bond Number 024256104 Premium Included in Charge for Performance Bond. LABOR AND MATERIAL BOND Whereas, the City Council of the City of Redlands, State of California, and Southwest Pipeline and Trenchless Corp (hereinafter designated as "Principal") have entered into an agreement (the "Agreement") whereby Principal agrees to install and complete certain designated public improvements (the "Work"), which said 2021 CIP Sewer Pipeline Replacement Project No. 52 021 agreement, dated December 7, 20 211 and identified as is hereby referred to and made a part hereof, and Whereas, under the terms of the Agreement, Principal is required before commending the performance of the Work, to file a good and sufficient Labor and Matenal bond with the City of Redlands to secure the claims to which reference is made in Title 3 (commencing with Section 9550) of Part 6 of Division 4 of the Civil Code of the State of California Now, therefore, said Principal and the undersigned as corporate surety, are held firmly bound unto the City and all contractors, subcontractors, laborers, material men and other persons employed in the perHufordmared Nnce of the nme Thousand Eight Agreement and referred to m the aforesaid Code of Civil Procedure in the sum of Hundred Fifty Two and 001100 dollars ($309,852 00) for materials furnished or labor thereon of any kind, or for amounts due under the Unemployment Insurance Act with respect to such work or labor, that said surety will pay the same in an amount not exceedmg the amount heremabove set forth, and also m case suit is brought upon this bond, will pay, m addition to the face amount thereof, costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligation, to be awarded and fixed by the court, and to be taxed as costs and to be included in the judgment therem rendered It is hereby expressly stipulated and agreed that this bond shall insure to the benefit of any and all persons, compames and corporations entitled to file claims under Title 3 (commencmg with Section 9550) of Part 6 of Division 4 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond Should the condition of this bond be fully performed, then this obligation shall become null and void, otherwise it shall be and remain m full force and effect The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or the specifications accompanying the same shall in any manner affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition. In witness whereof, this instrument has been duly executed by the Principal and surety above named, on December 7, 2021 (SEAJ,) (SEAL) lit y BY SouthwetPipehne and Trenchless Corp Libert Contractor) (Signature) (Seal and Notarial Acknowledgement of Surety) utual Insurance Company (Signature)Noe Quiroz, Attorney-m-Fact Address 790 The City Dnve South Suite 200 Orange, CA 92868 Telephone (714 ) 634-5720 CD 8