Loading...
HomeMy WebLinkAboutContracts & Agreements_167-2024PUBLIC WORK CONSTRUCTION CONTRACT This Public Work Construction contract ("Contract") is made and entered into this 17t day of September, 2024, by and between the City of Redlands, a municipal corporation, organized and existing under the laws of the State of California (hereinafter "City"), and C.R. Contracting LLC, an Oregon limited liability company (hereinafter "Contractor"). City and Contractor are sometimes individually referred to herein as a "Party" and, together, as the "Parties." In consideration of the mutual promises contained herein, City and Contractor agree as follows: 1. SCOPE OF WORK: Contractor shall furnish all materials and will perform all of the work for the following: Runway and Apron Pavement Treatment Project, complete all items as required by the Contract Documents (as herein defined) and Specifications for City's Runway and Apron Pavement Treatment Project, Project No. FCS662023JN (the "Work"). 2. CONTRACT SUM: City shall pay Contractor the sum of Six Hundred Sixteen Thousand Four Hundred Ninety -Nine Dollars ($616,499) as consideration for its performance of the Work in accordance with the terms and conditions set forth in the Contract Documents. Pursuant to Public Contract Code Section 22300, Contractor has the option to deposit securities with an escrow agent as a substitute for retention of earnings required to be withheld by City pursuant to an escrow agreement as set forth in Public Contract Code section 22300. 3. TIME FOR COMPLETION: The Work shall be completed within sixty (60) working day(s) as defined in Section 1-2 of the Standard Specifications for Public Works Construction "Greenbook" from and after the date of City's issuance of a Notice to Proceed to Contractor. 4. LIQUIDATED DAMAGES: Contractor's failure to complete the Work within the time allowed will result in damages being sustained by City. Such damages are, and will continue to be, impracticable and extremely difficult to determine. Accordingly, Contractor shall pay to City, or have withheld from monies due to Contractor, the sum of five hundred dollars ($500) for each working day as defined in Section 1-2 of the Standard Specifications for Public Works Construction "Greenbook" in excess of the specified time for completion of the Work. Execution of this Contract shall constitute agreement by City and Contractor that five hundred dollars ($500) per day is the estimated damage to City caused by the failure of Contractor to complete the work within the allowed time. Such sum is liquidated damages and shall not be construed as a penalty, and may be deducted from payments due Contractor if such delay occurs. 5. CONTRACT DOCUMENTS: This Contract incorporates by reference the following: Notice Inviting Bids, Instructions to Bidders, Contractor's Proposal, Bid Bond, Agreement, Performance Bond, Labor and Material Bond, Plans, General Conditions, Special Provisions and Specifications, and any addenda thereto (collectively, the "Contract Documents"). 6. ATTORNEYS' FEES: In the event any action is commenced to enforce or interpret the terms or conditions of this Contract, or the Contract Documents, the prevailing Party in such action, in addition to any costs and other relief, shall be entitled to recover its reasonable attorneys' fees, including fees for use of in-house counsel by a Party. 1 I:\emo\Agreements\C.R. Contracting LLC Public Works Agreement FY24-0017.docx-ms 7. RESOLUTION OF CONSTRUCTION CLAIMS: Claims by Contractor in the amount of Three Hundred Seventy -Five Thousand Dollars ($375,000) or less shall be made by Contractor and processed by the City pursuant to the provisions of Part 3, Chapter 1, Article 1.5 of the Public Contract Code (commencing with Section 20104). All claims shall be in writing and include the documents necessary to substantiate the claim. Nothing in subdivision (a) of Public Contract Code Section 20104.2 shall extend the time limit or supersede the notice requirements provided in this case from filing claims by Contractor. 8. ELIGIBILITY OF CONTRACTOR/SUBCONTRACTOR: Contractor and all of its subcontractors shall abide by California Public Contract Code, Section 6109, and California Labor Code Sections 1777.1 and/or 1777.7, and certify that they are not debarred and are eligible to work on this project. 9. ASSIGNMENT OF AGREEMENT: No assignment by a Party of any rights or interests under this Contract shall be binding on another Party without the written consent of the Party sought to be bound. 10. SUCCESSORS AND ASSIGNS: City and Contractor each binds itself and their respective successors and assigns in respect to all covenants, agreements, and obligations contained in the Contract Documents. 11. SEVERABILITY: Any provision or part of the Contract Documents held to be void or unenforceable under any law or regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon City and Contractor. 2 I:lcmolAgreerents\C.R. Contracting LLC Public Works Agreement FY24-0017.docx-ms IN WITNESS WHEREOF, the Parties hereto have executed this Contract the day and year first written above. (SEAL) ATTEST: ,4,4e—itgYZal Donaldson, City Clerk CITY OF By: Eddie Tejeda, Mayor C.R. Contracting LLC Name of Contractor (SEAL) BY: ee Z7Ccdi4�.� Signature of Authorized Agent Russell Davis, President Title Signature of Authorized Agent (if necessary) President Title CSLB:1119858 Contractor's License No. 3 1:\cmo\Agreements\C.R. Contracting LLC public Works Agreement FY24-0017.docx-ms WORKER'S COMPENSATION INSURANCE CERTIFICATION Description of Contract: City of Redlands Facilities and Community Services Department Runway and Apron Pavement Treatment Project FCS662023JN Every employer, except the State, shall secure the payment of compensation in one or more of the following ways: a. By being insured against liability to pay compensation by one or more insurers duly authorized to write compensation insurance in this State. • b. By securing from the Director of Industrial Relations, a certificate of consent to self- insure, either as an individual employer, or as one employer in a group of employers, which may be given upon furnishing proof satisfactory to the Director of Industrial Relations of ability to self -insure and to pay any compensation that may become due to his or her employees. CHECK ONE V I am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against liability for Workers' Compensation or to undertake self-insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work and activities required or permitted under this Agreement. (Labor Code § 1861). I affirm that at all times, in performing the work and activities required or permitted under this Agreement, I shall not employ any person in any manner such that I become subject to the workers' compensation laws of California. However, at any time, if I employ any person such that I become subject to the workers' compensation laws of California, immediately I shall provide the City with a certificate of consent to self -insure, or a certification of workers' compensation insurance. I certify under penalty of perjury under the laws of the State of California that the information and representations made in this certificate are true and correct. Dated this 16 day of September , 2024. C.R. Contracting LLC Azd Co (Signature) Russell Davis, President (Official Title) (SEAL) (Labor Code Section 1861 provides that the above certificate must be signed and filed by the Contractor with the Owner prior to performing the work of the contract.) 4 I;Icmo\Agreements\C,R. Contracting LLC Public works Agreement FY24 -00 17,docx-ms Bond No. ES00019220 FAITHFUL PERFORMANCE BOND Whereas, the City of Redlands ("City"), State of California, and C.R. Contracting LLC (hereinafter designated as "Principal") have entered into an agreement dated September 17, 2024 ("Agreement") whereby Principal agrees to install and complete certain public improvements (the "Work"), which said Agreement is identified as Runway and Apron Pavement Treatment Project, Project No. FCS662023JN and is hereby referred to and made a part hereof; and Whereas, said Principal is required under the terms of the Agreement to furnish a bond for the faithful performance of the Work, now, therefore, we, the Principal and, Everest National Insurance Company , as Surety, are held and firmly bound unto the City in the penal sum of Six Hundred Sixteen Thousand Four Hundred Ninety -Nine Dollars ($616,499) lawful money of the United States, for the payment of which sum we bind ourselves, and our heirs, successors, executors and administrators, jointly and severally, firmly by these presents. The condition of this obligation is such that if the above bounded Principal, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and provisions in the Agreement and any alteration thereof made as therein provided, on his or its part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall faithfully fulfill the one-year guarantee of all materials and workmanship, and shall defend, indemnify and save harmless the City and its elected officials, officers, agents and employees, as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefor, there shall be included costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligations, all to be taxed as costs and included in the judgment rendered. As a condition precedent to the satisfactory completion of the Work, the above obligation shall hold good for a period of one (1) year or longer if required by the Agreement after the acceptance of the work by the City, during which time if the Principal shall fail to make full, complete, and satisfactory repair and replacements and totally protect the City from loss or damage made evident during this period from the date of completion of the Work, and resulting from or caused by defective materials or faulty workmanship, the above obligation in penal sum thereof shall remain in full force and effect. The obligations of Surety hereunder shall continue so long as any obligation of the Principal remains. Whenever the Principal shall be, and is declared by the City to be, in default under the Agreement, the City having performed the City obligations thereunder, the Surety shall promptly remedy the default, or shall promptly, at the City's option: 1. Complete the Work in accordance with its terms and conditions; or 2. Obtain a bid or bids for completing the Work in accordance with its terms and conditions, and upon determination by Surety of the lowest responsive and responsible bidder, arrange for a contract between such bidder and the City, and make available as work progresses 5 L\cmo\Agreements\C.R. Contracting LLC Public Works Agreement FY24-0017.docx-ms sufficient funds to pay the cost of completion of the Work less the balance of the Agreement price, but not exceeding, including other costs and damages for which Surety may be liable hereunder, the amount set forth above. The term "balance of the Agreement price," as used in this paragraph, shall mean the total amount payable to the Principal by the City under the Agreement and any modifications thereto, less the amount previously properly paid by the City to the Principal. Surety expressly agrees that the City may reject any contractor or subcontractor which may be proposed by Surety in fulfillment of its obligations in the event of default by the Principal. Surety shall not utilize the Principal in completing the Work nor shall Surety accept a bid from the Principal for completion of the Work if the City, when declaring the Principal in default, notifies Surety of the City's objection to the Principal's further participation in the completion of the Work. No right of action shall accrue on the bond to or for the use of any person or corporation other than the City named herein or the successors or assigns of the City. Any suit under this bond must be instituted within the applicable statute of limitations period. The said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or to the work to be performed thereunder or the Specifications accompanying the same shall in any way affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Agreement or to the work or to the specifications. No final settlement between the City and the Principal shall abridge the right of any beneficiary hereunder whose claim may be unsatisfied. The Principal and Surety agree that if the City is required to engage the services of any attorney in connection with the enforcement of this bond, each shall pay the City' s reasonable attorneys' fees incurred, with or without suit, in addition to the above sum. In witness whereof, this instrument has been duly executed by the Principal and Surety above named, on September 18 , 2024. (SEAL) C.R. Contracting, LLC dba C.R. Contracting (Cc ractor) Z7Gi (i�L - (Signature) (SEAL) Everest National Insurance Company By," (Surety) (Signature) Brent Olson, Attorney -In -Fact Address: PO Box 2808 Portland, OR 97208 (Seal and Notarial Acknowledgment of Telephone ( 503)224-2500 Surety) 6 I:\cmo\Agreements\C.R. Contracting LLC Public Works Agreement FY24-0017.docx-ms everest POWER OF ATTORNEY EVEREST REINSURANCE COMPANY and EVEREST NATIONAL INSURANCE COMPANY KNOW ALL PERSONS BY THESE PRESENTS: That Everest Reinsurance Company and Everest National Insurance Company, corporations of the State of Delaware ("Company") having their principal offices located at Warren Corporate Center, 100 Everest Way, Warren, New Jersey, 07059, do hereby nominate, constitute, and appoint: Chloe Lyons, Gloria Bruning, Gail A. Price, Vicki Mather, Leticia Romano, Philip 0. Forker, Richard Kowalski, Joel Dietzman, Brent Olson, Christopher A. Rebum, J. Patrick Dooney, Justin Cumnock, Andrew Choruby, Casey Geske, Sterling Drew Roddan its true and lawful Attorney(s)-in-fact to make, execute, attest, seal and deliver for and on its behalf, as surety, and as its act and deed, where required, any and all bonds and undertakings in the nature thereof, for the penal sum of no one of which is in any event to exceed UNLIMITED, reserving for itself the full power of substitution and revocation. Such bonds and undertakings, when duly executed by the aforesaid Attorney(s)-in-fact shall be binding upon the Company as fully and to the same extent as if such bonds and undertakings were signed by the President and Secretary of the Company and sealed with its corporate seal. This Power of Attorney is granted and is signed by facsimile under and by the authority of the following Resolutions adopted by the Board of Directors of Company ("Board") on April 21, 2016: RESOLVED, that the President, any Executive Vice President, and any Senior Vice President are hereby appointed by the Board as authorized to make, execute, seal and deliver for and on behalf of the Company, any and all bonds, undertakings, contracts or obligations in surety or co -surety with others and that the Secretary or any Assistant Secretary of the Company be and that each of them hereby is authorized to attest to the execution of any such bonds, undertakings, contracts or obligations in surely or co -surety and attach thereto the corporate seal of the Company. RESOLVED, FURTHER, that the President, any Executive Vice President, and any Senior Vice President are hereby authorized to execute powers of attorney qualifying the attorney named in the given power of attorney to execute, on behalf of the Company, bonds and undertakings in surety or co -surety with others, and that the Secretary or any Assistant Secretary of the Company be, and that each of them is hereby authorized to attest the execution of any such power of attomey, and to attach thereto the corporate seal of the Company. RESOLVED, FURTHER, that the signature of such officers named in the preceding resolutions and the corporate seal of the Company may be affixed to such powers of attorney or to any certificate relating thereto by facsimile, and any such power of attorney or certificate bearing such facsimile signatures or facsimile seal shall be thereafter valid and binding upon the Company with respect to any bond, undertaking, contract or obligation in surety or co -surety with others to which it is attached. IN WITNESS WHEREOF, Everest Reinsurance Company and Everest National Insurance Company have caused their corporate seals to be affixed hereto, and these presents to be signed by their duly authorized officers this 10th day of October 2023. Everest Reinsurance Company and Everest National Insurance Company By: Anthony Romano, Senior Vice President On this 22"d of March 2023, before me personally came Anthony Romano, known to me, who, being duly sworn, did execute the above instrument; that he knows the seal of said Company; that the seal affixed to the aforesaid instrument is such corporate seal and was affixed thereto; and that he executed said instrument by like order. UNDA ROBINS Notary Public, State of New York No 01R06239736 Qualified in Queens County Term Expires April 25, 2027 Linda Robins, Notary Public 1, Sylvia Semerdjian, Assistant Secretary of Everest Reinsurance Company and Everest National Insurance Company do hereby certify that I have compared the foregoing copy of the Power of Attorney and affidavit, and the copy of the Section of the bylaws and resolutions of said Corporation as set forth in said Power of Attomey, with the ORIGINALS ON FILE IN THE HOME OFFICE OF SAID CORPORATION, and that the same are correct transcripts thereof, and of the whole of the said originals, and that the said Power of Attorney has not been revoked and is now in full force and effect. IN WITNESS WHEREOF, I have hereunto set my hand and affixed the seal of said Company, this l8th day of September202 4 By: Sylvia Semerdjian, Assistant Secretary GO Af, /\A n.t +e CALIFORNIA ALL—PURPOSE ACKNOWLEDGMENT i[1 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF Washington County of Clark On September 18, 2024 Date personally appeared before me, Brent Olson } i,"f 111'1 eia tt d i Insert Name of Notary exactly as it appears on the official seal , Notary Public, Name(s) of Signer(s) OFFICIAL STAMP JENNIFER N MOONEY NOTARY PUBLIC - WASHINGTON COMMISSION NO. 21033965 MY COMMISSION EXPIRES OCTOBER 12, 2025 Place Notary Seal Above who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Witness my hand and official seal. Signature d l' 1 � Signature of MAW Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Number of Pages: ❑ Individual ❑ Corporate Officer —Title(s): ❑ Partner ❑ Limited ❑ General ® Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: RIGHT THUMBPRINT OF SIGNER Top of thumb here Signer's Name: El Individual ❑ Corporate Officer —Title(s): ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: RIGHT THUMBPRINT OF SIGNER Top of thumb here LABOR AND MATERIAL BOND Bond No. ES00019220 Whereas, the City Council of the City of Redlands, State of California, and C.R. Contracting LLC (hereinafter designated as "Principal") have entered into an agreement (the "Agreement") whereby Principal agrees to install and complete certain designated public improvements (the "Work"), which said agreement, dated September 17, 2024, and identified as Runway and Apron Pavement Treatment Project, Project No. FCS662023JN is hereby referred to and made a part hereof; and Whereas, under the terms of the Agreement, Principal is required before commencing the performance of the Work, to file a good and sufficient Labor and Material bond with the City of Redlands to secure the claims to which reference is made in Title 3 (commencing with Section 9550) of Part 6 of Division 4 of the Civil Code of the State of California. Now, therefore, said Principal and the undersigned as corporate surety, are held firmly bound unto the City and all contractors, subcontractors, laborers, material men and other persons employed in the performance of the Agreement and referred to in the aforesaid Code of Civil Procedure in the sum of Six Hundred Sixteen Thousand Four Hundred Ninety -Nine Dollars ($616,499) for materials furnished or labor thereon of any kind, or for amounts due under the Unemployment Insurance Act with respect to such work or labor, that said surety will pay the same in an amount not exceeding the amount hereinabove set forth, and also in case suit is brought upon this bond, will pay, in addition to the face amount thereof, costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligation, to be awarded and fixed by the court, and to be taxed as costs and to be included in the judgment therein rendered. It is hereby expressly stipulated and agreed that this bond shall insure to the benefit of any and all persons, companies and corporations entitled to file claims under Title 3 (commencing with Section 9550) of Part 6 of Division 4 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond. Should the condition of this bond be fully performed, then this obligation shall become null and void, otherwise it shall be and remain in full force and effect. The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or the specifications accompanying the same shall in any manner affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition. In witness whereof, this instrument has been duly executed by the Principal and surety above named, on September 18 , 2024. (SEAL) (SEAL) C.R. Contracting, LLC dba C.R. Contracting Everest National Insurance Company Aed.44Zrtra,citggi _(Surety) (Signature) (Signature) Brent Olson Address: PO Box 2808 Attorney -In -Fact (Seal and Notarial Acknowledgement of Surety) Portland, OR 97208 Telephone: 7 I:\cmo\Agreements\C.R. Contracting LLC Public Works Agreement FY24-0017.docx-ms ( 503 )224-2500 everest POWER OF ATTORNEY EVEREST REINSURANCE COMPANY and EVEREST NATIONAL INSURANCE COMPANY KNOW ALL PERSONS BY THESE PRESENTS: That Everest Reinsurance Company and Everest National Insurance Company, corporations of the State of Delaware ("Company') having their principal offices located at Warren Corporate Center, 100 Everest Way, Warren, New Jersey, 07059, do hereby nominate, constitute, and appoint: Chloe Lyons, Gloria Bruning, Gail A. Price, Vicki Mather, Leticia Romano, Philip O. Forker, Richard Kowalski, Joel Dietzman, Brent Olson, Christopher A. Reburn, J. Patrick Dooney, Justin Cumnock, Andrew Choruby, Casey Geske, Sterling Drew Roddan its true and lawful Attorney(s)-in-fact to make, execute, attest, seal and deliver for and on its behalf, as surety, and as its act and deed, where required, any and all bonds and undertakings in the nature thereof, for the penal sum of no one of which is in any event to exceed UNLIMITED, reserving for itself the full power of substitution and revocation. Such bonds and undertakings, when duly executed by the aforesaid Attorney(s)-in-fact shall be binding upon the Company as fully and to the same extent as if such bonds and undertakings were signed by the President and Secretary of the Company and sealed with its corporate seal. This Power of Attorney is granted and is signed by facsimile under and by the authority of the following Resolutions adopted by the Board of Directors of Company ("Board") on April 21, 2018: RESOLVED, that the President, any Executive Vice President, and any Senior Vice President are hereby appointed by the Board as authorized to make, execute, seal and deliver for and on behalf of the Company, any and all bonds, undertakings, contracts or obligations in surety or co -surety with others and that the Secretary or any Assistant Secretary of the Company be and that each of them hereby is authorized to attest to the execution of any such bonds, undertakings, contracts or obligations in surety or co -surety and attach thereto the corporate seal of the Company. RESOLVED, FURTHER, that the President, any Executive Vice President, and any Senior Vice President are hereby authorized to execute powers of attorney qualifying the attomey named in the given power of attorney to execute, on behalf of the Company, bonds and undertakings in surety or co -surely with others, and that the Secretary or any Assistant Secretary of the Company be, and that each of them is hereby authorized to attest the execution of any such power of attorney, and to attach thereto the corporate seal of the Company. RESOLVED, FURTHER, that the signature of such officers named in the preceding resolutions and the corporate seal of the Company may be affixed to such powers of attorney or to any certificate relating thereto by facsimile, and any such power of attorney or certificate bearing such facsimile signatures or facsimile seal shall be thereafter valid and binding upon the Company with respect to any bond, undertaking, contract or obligation in surety or co -surety with others to which it is attached. IN WITNESS WHEREOF, Everest Reinsurance Company and Everest National Insurance Company have caused their corporate seals to be affixed hereto, and these presents to be signed by their duly authorized officers this 10th day of October 2023. Everest Reinsurance Company and Everest National Insurance Company By: Anthony Romano, Senior Vice President On this 22"a of March 2023, before me personally came Anthony Romano, known to me, who, being duly sworn, did execute the above instrument; that he knows the seal of said Company; that the seal affixed to the aforesaid instrument is such corporate seal and was affixed thereto; and that he executed said instrument by like order. LINDA ROBINS Notary Public, State of New York No 01R06239736 Qualified in Queens County Term Expires April 25, 2027 Linda Robins, Notary Public 1, Sylvia Semerdjian, Assistant Secretary of Everest Reinsurance Company and Everest National Insurance Company do hereby certify that I have compared the foregoing copy of the Power of Attorney and affidavit, and the copy of the Section of the bylaws and resolutions of said Corporation as set forth in said Power of Attorney, with the ORIGINALS ON FILE IN THE HOME OFFICE OF SAID CORPORATION, and that the same are correct transcripts thereof, and of the whole of the said originals, and that the said Power of Attorney has not been revoked and is now in full force and effect. IN WITNESS WHEREOF, I have hereunto set my hand and affixed the seal of said Company, this 18th day of September 202 4 . By: Sylvia Semerdjian, Assistant Secretary CC" nn Ila /1I AC CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF Washington County of Clark On September 18, 2024 before me, Date personally appeared Brent Olson } )-0,11)1 i F. 1 0 c�,; t t Insert Name or Notary exactly as it appears on the oft bial seal , Notary Public, Name(s) of Signer(s) OFFICIAL STAMP JENNIFER N MOONEY NOTARY PUBLIC - WASHINGTON COMMISSION NO. 21033965 MY COMMISSION EXPIRES OCTOBER 12, 2025 Place Notary Seal Above who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Witness my hand and official seal. Signature n/A,'GL Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Number of Pages: ❑ Individual ❑ Corporate Officer—Title(s): ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: RIGHT THUMBPRINT OF SIGNER Top of thumb here Signer's Name: ❑ Individual ❑ Corporate Officer —Title(s): ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: RIGHT THUMBPRINT OF SIGNER Top of thumb here