Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Contracts & Agreements_146-2026
PUBLIC WORT{ CONSTRUCTION CONTRACT This Public Work Construction contract ("Contract") is made and entered into this 21s' day of July, 2026, by and between the City of Redlands, a municipal corporation, organized and existing under the laws of the State of California (hereinafter "City"), and B-81 Paving Inc (hereinafter "Contractor"). City and Contractor are sometimes individually referred to herein as a "Party" and, together, as the "Parties." In consideration of the mutual promises contained herein, City and Contractor agree as follows: 1. SCOPE OF WORK: Contractor shall furnish all materials and will perform all of the work for the following: On -Call Pavement Repair Services for Water Utilities, complete all items as required by the Contract Documents (as herein defined) and Specifications for City's On -Call Pavement Repair Services for Water Utilities (the "Work"). 2. CONTRACT SUM: City shall pay Contractor the sum not -to -exceed Three Hundred Thousand dollars ($300,000.00) for fiscal year 2026/27; and the sum not to exceed Three Hundred Thousand dollars ($300,000.00) for fiscal year 2027/28; totaling an amount not to exceed Six Hundred Thousand dollars ($600,000.00) as consideration for its performance of the Work in accordance with the terms and conditions set forth in the Contract Documents. Pursuant to Public Contract Code Section 22300, Contractor has the option to deposit securities with an escrow agent as a substitute for retention of earnings required to be withheld by City pursuant to an escrow agreement as set forth in Public Contract Code section 22300. 3. TIME FOR COMPLETION: The Work shall be completed within seven hundred (700) calendar days from and after the date of City's issuance of a Notice to Proceed to Contractor. 4. LIQUIDATED DAMAGES: Contractor's failure to complete the Work within the time allowed will result in damages being sustained by City. Such damages are, and will continue to be, impracticable and extremely difficult to determine. Accordingly, Contractor shall pay to City, or have withheld from monies due to Contractor, the sum of Five Hundred dollars ($500.00) for each consecutive calendar day in excess of the specified time for completion of the Work. Execution of this Contract shall constitute agreement by City and Contractor that Five Hundred dollars ($500.00) per day is the estimated damage to City caused by the failure of Contractor to complete the work within the allowed time. Such sum is liquidated damages and shall not be construed as a penalty, and may be deducted from payments due Contractor if such delay occurs. 5. CONTRACT DOCUMENTS: This Contract incorporates by reference the following: Notice Inviting Bids, Instructions to Bidders, Contractor's Proposal, Bid Bond, Agreement, Performance Bond, Labor and Material Bond, Plans, General Conditions, Special Provisions and Specifications, and any addenda thereto (collectively, the "Contract Documents"). 6. ATTORNEYS' FEES: In the event any action is commenced to enforce or interpret the terms or conditions of this Contract, or the Contract Documents, the prevailing Party in such action, in addition to any costs and other relief, shall be entitled to recover its reasonable attorneys' fees, including fees for use of in-house coimsel by a Party. 7. RESOLUTION OF CONSTRUCTION CLAIMS: Claims by Contractor in the amount of Three Hundred Seventy -Five Thousand dollars ($375,000.00) or less shall be made by Contractor and processed by the City pursuant to the provisions of Part 3, Chapter 1, Article 1.5 of the Public 1 Mcmo\AgreementAAgmement w B-81 Paving.bm.07.08.2026.FY2728-08.doe Contract Code (commencing with Section 20104). All claims shall be in writing and include the documents necessary to substantiate the claim. Nothing in subdivision (a) of Public Contract Code Section 20104.2 shall extend the time limit or supersede the notice requirements provided in this case from filing claims by Contractor. 8. ELIGIBILITY OF CONTRACTOR/SUBCONTRACTOR: Contractor and all of its subcontractors shall abide by California Public Contract Code, Section 6109, and California Labor Code Sections 1777.1 and/or 1777.7, and certify that they are not debarred and are eligible to work on this project. 9. ASSIGNMENT OF AGREEMENT: No assignment by a Party of any rights or interests under this Contract shall be binding on another Party without the written consent of the Party sought to be bound. 10. SUCCESSORS AND ASSIGNS: City and Contractor each binds itself and their respective successors and assigns in respect to all covenants, agreements, and obligations contained in the Contract Documents. 11. SEVERABILITY: Any provision or part of the Contract Documents held to be void or unenforceable under any law or regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon City and Contractor. 2 IAcmo\Agreements\Agreement w B-81 Paving.bm.07.08.2026.PY2728-08.doe IN WITNESS WHEREOF, the Parties hereto have executed this Contract the day and year first written above. CITY OF REDLANDS (SEAL) Mario Saucedo, Mayor ATTEST: S)?'� LAg� 4jWhne Donaldson, City Clerk (SEAL) B-S 1 PgyLm Inc. Name of Contractor By. Signature of Authorized Agent Title Signature of Authorized Agent (if necessary) Title �G-L�0-7U Contractor's License No. 3 I: Icmo\AgreementslAgreement w B-8I Paving.bm.07.08.2026.FY2728-08.doc WORKER'S COMPENSATION INSURANCE CERTIFICATION Description of Contract: City of Redlands Municipal Utilities and Engineering Department On -Call Pavement Repair Services for Water Utilities Every employer, except the State, shall secure the payment of compensation in one or more of the following ways: a. By being insured against liability to pay compensation by one or more insurers duly authorized to write compensation insurance in this State. b. By securing from the Director of Industrial Relations, a certificate of consent to self - insure, either as an individual employer, or as one employer in a group of employers, which may be given upon furnishing proof satisfactory to the Director of Industrial Relations of ability to self -insure and to pay any compensation that may become due to his or her employees. CHECK ONE am aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against liability for Workers' Compensation or to undertake self-insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work and activities required or permitted under this Agreement. (Labor Code §1861). I affirm that at all times, in performing the work and activities required or permitted under this Agreement, I shall not employ any person in any manner such that I become subject to the workers' compensation laws of California. However, at any time, if I employ any person such that I become subject to the workers' compensation laws of California, immediately I shall provide the City with a certificate of consent to self -insure, or a certification of workers' compensation insurance. I certify under penalty of perjury under the laws of the State of California that the information and representations made in this certificate are true and correct. Dated this 1 U (SEAL) day of , 2026. B-81 Paving. Inc. (Contra, or) (Signature) p (Official Title) (Labor Code Section 1861 provides that the above certificate must be signed and filed by the Contractor with the Owner prior to performing the work of the contract.) 4 I:Icmo\A.greements\Agreement w B-81 Paving.bm.07.08.2026.FY2728-08.doc "Issued in two original counterparts FAITHFUL PERFORMANCE BOND Bond no: 024-274-905 Premium: $18,000.00 Whereas, the City of Redlands ("City"), State of California, and B-81 Paving, Inc. (hereinafter designated as "Principal") have entered into an agreement dated July 21, 2026 ("Agreement"), whereby Principal agrees to install and complete certain public improvements (the "Work"), which said Agreement is identified as On -Call Pavement Repair Services for Water Utilities and is hereby referred to and made a part hereof; and Whereas, said Principal is required under the terms of the Agreement to furnish a bond for the faithful performance of the Work, now, therefore, we, the Principal and, The Ohio Casualty Insurance Company, as Surety, are held and firmly bound unto the City in the penal sum of Six Hundred Thousand dollars ($600,000.00) lawful money of the United States, for the payment of which sure we bind ourselves, and our heirs, successors, executors and administrators, jointly and severally, firmly by these presents. The condition of this obligation is such that if the above bounded :Principal, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and provisions in the Agreement and any alteration thereof made as therein provided, on his or its part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall faithfully fulfill the one-year guarantee of all materials and workmanship, and shall defend, indemnify and save harmless the City and its elected officials, officers, agents and employees, as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefor, there shall be included costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligations, all to be taxed as costs and included in the judgment rendered. As a condition precedent to the satisfactory completion of the Work, the above obligation shall hold good for a period of one (1) year or longer if required by the Agreement after the acceptance of the work by the City, during which time if the Principal shall fail to make full, complete, and satisfactory repair and replacements and totally protect the City from loss or damage made evident during this period from the date of completion of the Work, and resulting from or caused by defective materials or faulty workmanship, the above obligation in penal sum thereof shall remain in full force and effect. The obligations of Surety hereunder shall continue so long as any obligation of the Principal remains. Whenever the Principal shall be; and is declared by the City to be, in default tinder the Agreement, the City having performed the City obligations thereunder, the Surety shall promptly remedy the default, or shall promptly, at the City's option: Complete the Work in accordance with its terms and conditions; or 2. Obtain a bid or bids for completing the Work in accordance with its terms and conditions, and upon determination by Surety of the lowest responsive and responsible bidder, arrange for a contract between such bidder and the City, and make available as work progresses sufficient :funds to pay the cost of completion of the Work less the balance of the Agreement price, but not exceeding, including other costs and damages for which Surety may be liable hereunder, the 1Acm0\Agm=vnf!AAgreement w 5-81 Paving.bm.07.08.2026.PY2728-08.doc amount set forth above. The term "balance of the Agreement price," as used in this paragraph, shall mean the total amount payable to the Principal by the City under the Agreement and any modifications thereto, less the amount previously properly paid by the City to the Principal. Surety expressly agrees that the City may reject any contractor or subcontractor which may be proposed by Surety in fulfillment of .its obligations in the event of default by the Principal. Surety shall. not utilize the Principal in completing the Work nor shall Surety accept a bid from the Principal for completion of the Work if the City, when declaring the Principal in default, notifies Surety of the City's objection to the Principal's further participation in the completion of the Work. No right of action shall accrue on the bond to or for the use of any person or corporation other than the City named herein or the successors or assigns of the City. Any suit under this bond must be instituted within the applicable statute of limitations period. The said Surety, :for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or to the work to be performed thereunder or the Specifications accompanying the same shall in any way affect its obligations on this bond, and. it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Agreement or to the work or to the specifications. No final settlement between the City and the Principal shall abridge the right of any beneficiary hereunder whose claim may be unsatisfied. The Principal and Surety agree that if the City is required to engage the services of any attorney in connection with the enforcement of this bond, each. shall pay the City's reasonable attorneys' fees incurred, with or without suit, in addition to the above sum. In witness whereof, this instrument has been duly executed by the Principal and Surety above named, on July 14 , 2026. (SEAL) (SEAL) $-81 Pavin , Inc. The Ohio Cgosmaki Insurance Company (Contractor) (Surety) ZL BY: A-Zn lslgnaturerdalberto 6edolla, President lgnature) Jeff Aase, Attorney -in -Fact Address: 790 The City Drive South, Suite 200 CA 92868 (Seal and Notarial Acknowledgment of Telephone(415) 691-5385 Surety) 6 1:FcmolAgreemcrk& Agrcement w B-81 Paving.bm.07.08.2026. FY2728-0S.doc ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity_of that document. State of California County of San Bernardino On July 14, 2026 before me, N. Cruz-Echauregui, Notary Public (insert name and title of the officer) personally appeared Jeff Aase who proved to me on the basis of satisfactory evidence to be the persopksl-w—hose na is subscribed to the within instrument and acknowledged to me that(h , ,they executed the same in i eir authorized capaci� ie�}, that by h� isJerlth-eir signature seen the instrument the p rson(�, the entity upon behalf of which the p179'off(ST acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signatu (Seal) N. CRUZ-ECHAUREGUI a Notary Public - California San Bernardino County + Commission p 2556240 My Comm. Expires Jun 18, 2030 Liberty POWER OF ATTORNEY 1Y16uiUN Liberty Mutual Insurance Company Certificate No: 8214023-024130 SURETY The Ohio Casualty Insurance Company West American Insurance Company KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies`), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Jeff Aase, Justin Buenaventura_ Fvlvia Caneva. Kevin Jahn Comstock, Colby Craig, .Iefni R. Davis, Amber DelCiognale, Oscar Zachary Gallegos,Rachel G. Holbrook, Craig all of the city of Los Angcics state of CA each individually if there be more than one named, its true and lawful attorney -in -fact to make, execute, seal, acknowledge and deliver, for and on Its behalf as surety and as Its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their on proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 12tb day of May , 2025 . Liberty Mutual Insurance Company Py 1Nsbgq PVxY INsp tNsu� The Ohio Casualty Insurance Company jJ3ooavoggr�ycm yJ3ooNPeagr�'PQy� PNoavopgro2cm West American Insurance Company � �912�(go 0 7919 � g 9991 0 d'Z�ggCNY3` a0' yO y�YNNMPS�p�aYaO Y rNDIANP aC' `aA/T y. Fed dqt a key sd4l x xax� By: Nathan.] 7annede. Assistant Serretary teof PENNSYLVANIA ss mty of MONTGOMERY this 12th day of May 2025 before me personally appeared Nathan J. Zongede, who acknowledged himself lobe the Assistant Secretary of Liberty Mutual npany, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the sin contained by signing on behalf of the corporations by himself as a duly authorized officer. I have hereunto subscribed my name and affixed my notarial seal at Plymouth Meeting, Pennsylvania, on the day and year first above written. yP €yaS sypsrya^.}�'r CommonwaaM of Pannsylvanla-Nclary Beal YC,P iereso Peslella, Notary Public i{'-� �f , QV Manlganery My rmmmkslon exp March 28, 202a By: tya Commission number 1128094 Teresa PasteNotary lla, Nota Public �6Member. Pennaylvanle AssoclMlan of Notaries 4 This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Aulhorizations of The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: ARTICLE IV- OFFICERS: Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President' may prescribe, shall appoint such attorneys -In -fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact, subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney -in -fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. ARTICLE XIII- Execution of Contracts: Section 5. Surety Bands and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such attomeys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation - The President of the Company, acting pursuant to the Bylaws of the Company, authorizes Nathan J. Zangerle, Assistant Secretary to appoint such attorneys -in -fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Authorization - By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. 1, Renee C. Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, hue and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this I4th day of July 2026 P� 1NSUgq 004tv'411. d tNSUk\P�pPOggfpdCq 3 0o ms 1991 0�w.BYs� Nn1ANl'aja�yRenee C. Llewellyn, Assistant Secretary M ,r F LMS-12873 LMIC OCIC WAIC Multi Co 02124 'Issued in two original counterparts Bond no: 024-274-905 Premium: Included in performance bond LABOR AND MATERIAL BOND Whereas, the City Council of the City of Redlands, State of California, and B-81 Paving, Inc. (hereinafter designated as "Principal") have entered into an agreement (the "Agreement") whereby Principal agrees to install and complete certain designated public improvements (the "Work"), which said agreement, dated July 2.1, 2026, and identified as Ong -Call Pavement Repair Services for Water Utilities is hereby referred to and made a part hereof; and Whereas, under the terms of the Agreement, Principal is required before commencing the performance of the Work, to file a good and sufficient Labor and Material bond with the City of Redlands to secure the claims to which reference is made in Title 3 (commencing with Section 9550) of Part 6 of Division 4 of the Civil Code of the State of California. Now, therefore, said Principal and the undersigned as corporate surety, are held finely bound unto the City and all contractors, subcontractors, laborers, material men and other persons employed in the performance of the Agreement and referred to in the aforesaid Code of Civil Procedure in. the sum of Six Hundred Thousand dollars ($600,000.00) for materials furnished or labor thereon, of any kind, or for amounts due under the Unemployment Insurance Act with respect to such work or labor, that said surety will pay the same in an amount not exceeding the amount herei.nabove set forth, and also in case suit is brought upon this bond, will pay, in addition to the face amount thereof, costs and reasonable expenses and fees, including reasonable attorneys' fees, incurred by the City in successfully enforcing such obligation, to be awarded and fixed by the court, and to be taxed as costs and to be included in the judgment therein rendered. It is hereby expressly stipulated and agreed that this bond shall insure to the benefit of any and all persons, companies and corporations entitled to file claims under Title 3 (commencing with Section 9550) of Part 6 of Division 4 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond. Should the condition of this bond be fully performed, then this obligation shall become null and void, otherwise it shall be and remain in full force and effect - The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or the specifications accompanying the same shall in any manner affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition. In witness whereof, this instrument has been duly executed by the Principal and surety above named, on July 14 , 2026. (SEAL) (SEAL) B-81 Paving, Inc. The OhioGenvaltv Insurance Company Cara actor) (Surety) Jeff Aase, Attorney -in -Fact BY: (Signature)adalberto Bedolla, President (Signature) Addres 790 The City Drive South, Suite 200 (Seal and Notarial Acknowledgement of Orange, CA 92868 Surety) Telephone: ( 415 ) 691-5385 7 1:lcrrioSAareetnentslAgrcement w B-8 i Paving.bm.07.08.2026.FY2728-08.(€oc ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validityof that document ---------- _.__-..-..-.___ State of California County of San Bernardino On July 14, 026 before me, N. Cruz-Echauregui, Notary Public (insert name and title of the officer) personally appeared Jeff Aase who proved to me on the basis of satisfactory evidence to be the persop("hose narnetsj(Ware- subscribed to the within instrument and acknowledged to me that h�sh-etthey executed the same in hisl evV e authorized capacity(ies , and that by sl , elr signaturoko-an the instrument the on the entity upon behalf of which the personated, executed the instrument. certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is trUU and correct. WITNESS my hand and official seal, Signature (Seal) 90my N. CRUZ-ECHAUREGUI Notary Public - CaliforniaSan Bernardino County Commission # 1556140 Comm. Expires Jun 18, 2030 'ok Liberty7 POWER OF ATTORNEY MiXt112l1w Liberty Mutual Insurance Company Certificate Na: 8214023-024130 SURETY The Ohio Casualty Insurance Company West American Insurance Company KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, JeffAase, 1„.1i, n,........ e... s.a.aa r-Kevin Tnhn Comctnr.k. Colby Crain_ JnlPrev R. Davis. Anther UelCroenale. Oscar Zachmv Gallegos, Rachel G. Holbrook, Craig all of the city of Los Angeles state of CA each individually if there be more than one named, its true and lawful attorney -in -fact to make, execute, seal, acknowledge and deliver, for and on Its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, In pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 12th dayofMa)L__, 2025 Liberty Mutual Insumnce Company 1NSUq �tY INSU 1NSUR The Ohio Casually Insurance Company hp bUpPORgj 4� yJ �avbRgjR9,` pPbbapNRgjq'r'p West American Insurance Company �a oom cia `"o m r`a Font �4Y NgCNU`+a yONgM980.pD Y �NRIANP D� �Rj> ♦ had �Rl � hid s�M + 1-Y1d By. Nathan J. Zanoede, Assistant Secretary iu State of PENNSYLVANIA County of MONTGOMERY ss On this 12th day of May 2025 before me personally appeared Nathan J. Zangerie, who acknowledged himself to be the Assistant Secretary of Liberty Mutual m Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the y therein contained by signing on behalf of the corporations by himself as a duly authorized officer. IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at Plymouth Meeting, Pennsylvania, on the day and year first above written, Commonweelu Penneylwais-Notnryaeel `O y, p -Y\ C,n Teresa Pastello, Notary PUMio/) 4i Montgwnary County a) (3P My commission oxp'roa March 2a, 202fl B Ie0 % c! r. Porn sionia Assa 1t26044 y 2w Pf,,A, Memeer. ven�sywama AssPuerwa of Nounas Teresa Pastella, Notary Public 4py P\ and executed pursuantto and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual Insurance Insurance Companywhich resolutions are now in full force and effect reading as follows: ARTICLE IV— OFFICERS: Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys -in -fact, as may be necessary to act In behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact, subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney -in -fact under the provisions of this aNicle may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. ARTICLE XIII— Execution of Contracts: Section 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose In writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shell appoint such attorneys-in-Lci, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature andexecution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation — The President of the Company, acting pursuant to the Bylaws of the Company, authorizes Nathan J, Zangerie, Assistant Secretary to appoint such attorneys -in -fad as may be necessary, to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surely obligations Authorization — By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a codified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and a act as though manually affixed. I, Renee C. Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, one and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 14th day of July , 2026 . _�rd��zY3y�,''`M 41N\fNG9O'•ISO9AWRU-01PRh jto x.'pYLC3O g Y919 Renee C. Llewellyn, Assistant Secretary D-o4bt-- LMS-12e73 LMIC OCIC WAIL Multi Co 02124 PART 4 BID # 20260604 CITYWIDE PAVEMENT REPAIR FOR WATER UTILITIES Bidder must bid on all items. Award will be made based on unit orice of bid item number 1 ITEM DESCRIPTION Unit of Measure Unit Price Sawetlt & Remove Temporary Asphalt, Grind & Overlay 0.10 Ft MlI1lmL11n, and Replace with per Square Foot $ 16 72 Conventional Asphalt in accordance with the City of , Redlands Surface Restoration & T'rench Backfill Detail Remove Existing Temporary Material and Place 4-inch Per 5qua�e Foot 51.99 Depth PCC (560-C-3250) on Compacted Base 3 Replace Pavement Striping in Kind Per linear Foot $ 15.00 (Pai nt/T'hermo )lastic) Replace Thermoplastic Pavement Markings (Le(lends, Each 185 . DO Arrows. etc.) Replace Traffic Loops Eacli S 1,620 .00 6 Replace Pavement Markers Each S 65 . 00 Contract will be awarded to lowest responsive and responsible bidder based on the unit price for Bid Item No. 1. This project is intended to provide full workdays of operation, at approximately 15 patches per week, Once list of repairs is provided to the Contractor, Contractor will have 30 Calendar days to complete the work. The annual contract amount is anticipated not to exceed three hundred thousand dollars ($300,000) for fiscal year 26/27 (June 1, 2026 —July 1, 2027) and three hundred thousand dollars ($300,000) for fiscal year 27/28 (June 1, 2027—July 1, 2028). CONTRACT TERM (Please Complete) The City may ® or may not ❑ exercise its option to renew this agreement as stipulated Linder the same price, terms and conditions for a period one [ two ❑x three ❑ additional year(s). Signature y1 l+L Title CEO / PRESIDENT Date 06/01/2026 Page 12 of 33 A� o® CERTIFICATE OF LIABILITY INSURANCE 0 07/09/2026 7/0 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER($), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WANED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER PAYCHEX INSURANCE AGENCY 225 Kenneth Drive Rochester, NY 14623 NAME CT Mastrella, Anthony G PHONE g77-266-6850 FAx EM: A/C No: EIL ADDRESS: as astrefla@paychex.com INSU RERS AFFORDING COVERAGE NAIC# INSURERA: NorGUARD Insurance Company 31470 INSURED B-81 Paving Inc 34426 Yucaipa Blvd # 343 _ INSURER a: INSURERC: Yucaipa, CA 92399-2474 INSURER D: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE Alan VVkM SUBR POLICY NUMBER MMDDMY POLICY LIMITS COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ O CLAIMS -MADE OCCUR PREMISES Ea occurrence $ 0 MED EXP (Any one person) $ 0 PERSONAL & ADV INJURY $ 0_ GEML AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE _ $ 0 PRODUCTS-COMP/DP AGO $ 0 POLICY jE0 LOC S OTHER: AUTOMOBILE LIABILITY COMBINED SINGLE UMIT Ea accident) $ BODILY INJURY (Per person) $ ANY AUTO OWNED SCHEDULED AUTOS ONLY AUTOS HIRED NON -OWNED _ AUTOS ONLY HAUTOS ONLY BODILY INJU RY(For accident) $ PROPERTY DAMAGE Per accident $ UMBRELLALIAB OCCUR EACH OCCURRENCE $ AGGREGATE $ EXCESSUAB CLAIMS -MADE CEO RETEWION$ $ A WORKERSCOMPENSATION AND EMPLOYERS LIABILITY YIN ❑Y ANWROPRIETORMARTNER/EXECUTIVE OFFICERIMEMHEREXCLUDEO? (Mandatary in NH) NIA BEWC615687 08130/2025 08/30/2028 X STATUE ERH E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE -EA EMPLOYEE $ 110001000 E.L. DISEASE -POLICY LIMIT $ 1,000,000 If yes, describe under DESCRIPTION OF OPERATIONS below DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (ACORD 101, Additional Remarks Schedule, maybe attached If more space Is mqulmd) Contractor License #: 1026076 Employees: Full Time: 1; Part Time: 1 Governing Class Description: STREET OR ROAD CONSTRUCTION -PAVING Exclusions: Adalberto Bedolla; CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE CITY OF REDLANDS THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. 35 CAJON STREET STE 15 A Redlands, CA 92373 tAUTHORIZED REPRESENTATIVE ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25 (2016/03) _ The ACORD name and logo are registered marks of ACORD B-81 Paving Inc 34428 Yucaipa Blvd # 343 Yucaipa, CA 92399-2474 hR•�T�7'r7-r�7 I� CERTIFICATE OF LIABILITY INSURANCE DATE(MMIDDIYYYY) 07/10/2026 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER McRae Associates Insurance Services 1265 N. Manassero St Suite 303 Anaheim, CA 92807 CONTACT e NAME' M14)779 PHONE E.. (714)779.6999 ac Na; 714)779.6903 6999 E-MAIL DOREss: maricela mcraeinsurence.insure INSURERS AFFORDING COVERAGE NAIC# INSURER A: CHAMPLAIN SPECIALTY INSURANCE COMPANY 16834 INSURED B81 PAVING, INC 34428 YUCAIPA BLVD #343 YUCAIPA, CA 92399 INSURER B: NATIONAL FIRE AND MARINE INSURANCE 20079 INSURER C: INSURERD: INSURER E: INSURER F: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAYBE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. *LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. LIMITS SHOWN ARE INCLUSIVE OF AMOUNTS REQUESTED BY THE CERTIFICATE HOLDER AND MAY NOT REFLECT POLICY LIMIT AMOUNTS IN EXCESS OF THOSE REQUESTED. *Not Applicable in WY INSR LTR TYPEOFINSURANCE ApOL SUER WDPOLICY NUMBER POLICYEFF MM/DD/Y YY POLICY EXP M /DD/YYYY LIMITS A X COMMERCIAL GENERAL LIABILITY CLAIMS -MADE ®OCCUR Y Y CSAR-CGL-0008421.01 08/19/2025 08/19/2026 EACH OCCURRENCE $ 1,000,000 PREMSES Eaoccurrenca $ 100 000 $ 5 000 MED EXP Any one person) — PERSONAL A ADV INJURY $ 1000000 AGGREGATE LIMIT APPLIES PER; POLICY I -XI jEO D LOC GENERAL AGGREGATE $ 2000000 GEN'L PRODUCTS-COMP/OP AGO $ 2 000 000 $ OTHER: I B AUTOMOBILE LIABILITY ANY AUTO OWNED SCHEDULED AUTOS ONLY x AUTOS HIRED NON -OWNED AUTOS ONLY i( AUTOS ONLY Y Y 72APS130389 01/1012026 0111012027 EOMaBII,'NdMIN GLE LLIMIT_rx $ 1 000000 X BODILY INJURY (Per person) $ BODILY INJURY (Per eccldent) $ PROPERTY DAMAGE Per accident $ $ A UMBRELLA LIAB X OCCUR Y Y CSAR-CEL-0008423-01 08/1912026 0811912026 EACHOCCURRENCE $ $2,000,000 X AGGREGATE $ $2,000,000 EXCESS LIAB CLAIMS -MADE DED RETENTION$ 0 $ WORKERS COMPENSATION AND EMPLOYERS' LIABILITY Y f N ANY PROPRIETORIPARTNER/EXECUTIVE OFFICERIMEMBER EXCLUDED? (Mandatory In NH) Ryes, describe under DE SCRIPTION OF OPERATIONS below NIA - PER OTH- STATUTE ER E.L. EACH ACCIDENT $ E.L. DISEASE EA EMPLOYE $ E.L. DISEASE POLICY LIMIT $ DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached If more space is required) Re: On -Call Pavement Repair Services for Water Utilities City of Redlands ,along with their officers, officials, agents, employees and volunteers are named as additional insured with respects to the above -mentioned policies per attached endorsement(s). coverage is primary & non-contributory as required by written contract, per attached endorsement forms, waiver of subrogation applies, if required by written contract. continued on ACORD 101 Additional Remarks Schedule City of Redlands Municipal Utilities and Engineering Department 35 Cajon St, Ste 15 A Redlands, CA 92373 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED ACORD 25 (2025112) CORPORATION. All rights reserved. I ne Aa Vhru name ana logo are registered marks of ACORD Printed by MAG on 07/1012026 at 09:39AM AGENCY CUSTOMER ID: LOC #: ACO & ADDITIONAL REMARKS SCHEDULE Page? of AGENCY NAMED INSURED - McRae Associates Insurance Services BB1 PAVING, INC POLICY NUMBER NIA CARRIER NAIC CODE Multiple Carriers EFFECTIVE DATE: ADDITIONAL REMARKS - THIS ADDITIONAL REMARKS FORM IS A. SCHEDULE TO ACORD FORM, FORM NUMBER: 25 FORM TITLE: Certificate of Liability Insurance - (continued from Description of Operations) " Should any of the above described policies be cancelled before the expiration date there of, a 30 day written notice will be Issued. © 2008 ACORD CORPORATION. All rights reserved.: The ACORD name and logo are registered marks of ACORD : Printed by MAG on July 70, 2026 at 09:39AM U- or or repair. THIS ENDORSEMENT CHANGES/MODIFIES THE POLICY. PLEASE READ IT CAREFULLY. PRIMARY AND NON-CONTRIBUTING INSURANCE This endorsement changes/modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE FORM To the extent that this insurance is afforded to any additional insured under this policy, SECTION IV — COMMERCIAL GENERAL LIABILITY CONDITIONS, 4. Other Insurance, is deleted in Its entirety and replaced with the following condition: 4. Otherinsurance If all of the other insurance permits contribution by equal shares, we will follow this method unless the insured is required by written contract signed by both parties, to provide Insurance that is primary and non- contributory, and the "insured contract" is executed prior to any loss. Where required by a written contract signed by both parties, this insurance will be primary and non-contributing only when and to the extent as required by that contract. However, under the contributory approach each insurer contributes equal amounts until it has paid its applicable limit of insurance or none of the loss remains, whichever comes first. If any of the other insurance does not permit contribution by equal shares, we will contribute by limits. Under this method, each insurer's share is based on the ratio of its applicable limit of insurance to the total applicable limits of insurance of all insurers. ALL OTHER TERMS AND CONDITIONS OF THE POLICY REMAIN UNCHANGED. This endorsement is attached to and forms a part of the Policy as listed in the Declarations Page or Declarations Extension Schedule, effective on the inception date of the Policy unless otherwise stated herein. (The following information is required only when this endorsement is issued subsequent to preparation of the Policy.) Endorsement effective date: Policy No.: csAR-cGL-0008421-01 Endorsement No.: Named Insured: Bet Paving, Inc. Authorized Representative CIS CGL 4026 12 16 I Print Date: 4O12025 Policy Number.GSAR-CGlA000421.01 COMMERCIAL GENERAL LIABILITY CG 24 04 05 09 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Person Or Organization: As required by written contract signed by both parties and the Insured contract is executed prior to any loss. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV — Conditions: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for Injury or damage arising out of your ongoing operations or "your work" done under a contract with that person or organization and included in the "products - completed operations hazard". This waiver applies only to the person or organization shown in the Schedule above. CG 24 04 05 09 ©insurance Services Office, Inc., 2008 Page 1 of 1 13 THIS ENDORSEMENT CHANGES/MODIFIES THE POLICY. PLEASE READ IT CAREFULLY. AMENDMENT OF LIMITS - DESIGNATED CONSTRUCTION PROJECT(S) GENERAL AGGREGATE LIMIT This endorsement changes/modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM (If no entry appears herein, information required to complete this endorsement. will be shown in the Declarations as applicable to this endorsement.) required by written contract signed by both parties and the insured contract Is tcuted prior to any loss. A. For all sums which the insured becomes legally obligated to pay as damages caused by "occurrences" under COVERAGE A BODILY INJURY AND PROPERTY DAMAGE LIABILITY (SECTION 1 — COVERAGES), which can be attributed only to ongoing operations at a single designated construction project shown in the Schedule above: 1. A separate Designated Construction Project General Aggregate Limit applies to each designated construction project, and that limit Is equal to the amount shown in the Declarations of this policy. 2. Subject to the Total Policy Aggregate Limit, the Designated Construction Project General Aggregate Limit Is the most we will pay for the sum of all damages under COVERAGE A, except damages because of "bodily Injury" or "property damage" Included In the "products completed operations hazard," regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits." 3. Any payments made under COVERAGE A for damages shall reduce the Designated Construction Project General Aggregate Limit for that designated construction project. Subject to the Policy Aggregate Limit, such payments shall not reduce the General Aggregate Limit shown in the Declarations nor shall they reduce any other Designated Construction Project General Aggregate Limit for any other designated construction project shown in the Schedule above. 4. The limits shown In the Declarations for Each Occurrence continue to apply. However, instead of being subject to the General Aggregate Limit shown In the Declarations, such limits will be subject to the applicable Designated Construction Project General Aggregate Limit and the Total Policy Aggregate Limit. B. For all sums which the insured becomes legally obligated to pay as damages caused by "occurrences" under COVERAGE A BODILY INJURY AND PROPERTY DAMAGE LIABILITY (SECTION I — COVERAGES), which cannot be attributed only to ongoing operations at a single designated construction project shown In the Schedule above: 1. Any payments made under COVERAGE A for damages shall reduce the amount available under the General Aggregate Limit or the Products -Completed Operations Aggregate Limit, whichever is applicable; and 2. Such payments shall not reduce any Designated Construction Project General Aggregate Limit. 3. Such payments will reduce the Policy Aggregate Limit. CIS CGL 8001 12 15 Page 1 of 2 CIS COL 800I.q t C. E. F. When coverage for liability arlsing out of the "products -completed operations hazard" is provided, any payments for damages because of "bodily Injury" or "property damage" Included in the "products -completed operations hazard" will reduce the Products -Completed Operations Aggregate Limit, and not reduce the General Aggregate Limit or the Designated Location General Aggregate Limit or the Total Policy Aggregate Limit. The Total Policy Aggregate Limit scheduled in the Declarations of this policy Is the most we will pay for the sum of: (a) all damages covered under this policy and falling within the scheduled Designated Location(s) General Aggregate Limits described in Paragraph A. of this endorsement; and, (b) all damages covered under this policy and failing within the General Aggregate Limit, as described in Paragraph B. of this endorsement and as set forth In the provisions of Limits of Insurance (SECTION. 111) not otherwise modified by this endorsement. The Total Policy Aggregate Limit applies regardless of the sums Indicated in the Declarations for any General Aggregate Limit, or Designated Locatton(s) General Aggregate Limit, as applicable to all locations(s) set forth In the Schedule above. The Total Policy Aggregate Limit applies collectively, rather than separately, to all of your scheduled locations. The Total Policy Aggregate Limit is not reduced by payments fordamagescovered under this. policy and falling within the "products -completed operations hazard," but such payments will reduce the Products - Completed Operations Aggregate Limit, as described in Paragraph C. of this endorsement. For the purposes of this endorsement, DEFINITIONS (SECTION V) is amended by the addition of the following definition: "Location" means premises Involving the same or connecting lots, or premises whose connection is Interrupted only by a street, roadway, waterway or right-of-way of a railroad. The provisions of LIMITS OF INSURANCE (SECTION 111) not otherwise modified by this endorsement shall continue to apply as stipulated. ALL OTHER TERMS AND CONDITIONS OF THE POLICY REMAIN UNCHANGED. This endorsement is attached to and forms a part of the Policy as listed in the Declarations Page or Declarations Extension Schedule, effective on the Inception date of the Policy unless otherwise stated herein. (The following information is required only when this endorsement is Issued subsequent to preparation of the Policy.) Endorsement effective date: o8/isrzom Policy No.: CSAR.CGL.000842"1 Endorsement No.: Named Insured: B81 Paving, Inc. Authorized Representative CIS CGL 8001 12 15 Page 2 of 2 CIS CGL 8001.rpt THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED ENDORSEMENT This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM TRUCKERS COVERAGE FORM ADDITIONAL INSURED: As required by written contract A. In consideration of payment of the additional premium listed below, LIABILITY COVERAGE Is extended to include the additional insured named herein, provided that: 1) such insurance applies only to the ownership, maintenance or use of a covered "auto"; and 2) such Insurance applies only to acts or omissions by you, your agents or your "employees" while such covered auto is being used in your business; and 3) such insurance does not apply to the acts or omissions of the additional insured or any of the additional insured's agents or "employees" other than you; and 4) such insurance does not apply if the additional Insured is subject to motor carrier insurance requirements and is not insured for hired "autos" under an "auto" liability insurance form that insures on a primary basis the owners of the "autos" and their agents and "employees" while the "autos" are being used exclusively in.the additional insured's business and pursuant to operating rights granted to the additional insured by a public authority. R The insurance afforded to such additional insured: 1) Applies only to the extent permitted by law•, and 2) Will not be broader than that which you are required by a contract or agreement to provide for such additional insured. C. The most we will pay on behalf of the additional insured is the lesser of the amount of insurance: 1) That you are required by a contract or agreement to provide for such additional insured; or 2) That is available under the applicable Limits of Insurance shown in the Declarations. All other terms, conditions and agreements remain unchanged. Additional Premium: $ M-5887(0812017) Company Name Policy Number 72APS130389 .National Liability & Fire Insurance Company Endorsement Effective 01/1012026 12:01 PM Named Insured Countersigned by B-81 Paving, Inc. (Authorized Representative) (The Attaching Clause need be completed only when this endorsement Is issued subsequent to preparation of the policy .) M-5887 (0812017) 0711012024 POLICY NUMBER: 72APS130389 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM BUSINESS AUTO PHYSICAL DAMAGE COVERAGE FORM GARAGE COVERAGE FORM MOTOR CARRIER COVERAGE FORM TRUCKERS COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modi- fied by the endorsement. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated M-5144a (0012007) lelow. Endorsement Effective: Countersigned By: 01/1012026 12:01 PM Named Insured: B-81 Paving, Inc. Authorized Representative Of Person(s) or Organization(s): As required by written contract SCHEDULE Premium 1 $ (If no entry appears above, information required to complete this endorsement will be shown in the Declarations as applicable to this endorsement.) The Transfer Of Rights Of Recovery Against Others To Us Condition does not apply to the person (s) or organize- tion(s) shown in the Schedule. We will retain the additional premium shown above, regardless of any early termi- nation of this endorsement or the policy. Includes mpydghted material of Insurance Services Office, Inc. with its permission. WM44a (0612007) CITY OF REDLANDS BUSINESS TAX CERTIFICATE "For Services Provided in the City of Redlands, California Only" Business Name B-81 PAVING INC Business Location 34428 Yucaipa Blvd Ste E 343 Yucaipa, Ca 92399 Business Owner(s) ADALBERTO BEDOLLA B-81 PAVING INC 34428 YUCAIPA BLVD STE E 343 YUCAIPA, CA 92399 THIS BUSINESS TAX CERTIFICATE DOES NOT PERMIT A BUSINESS THAT IS OTHERWISE PROHIBITED. 2026 TO BE POSTED IN A CONSPICUOUS PLACE AND NOT TRANSFERABLE OR ASSIGNABLE Business Type Subcontractor Description PAVING Certificate Number: 08123406 Effective Date June 29, 2026 Expiration Date December 31, 2026 For all inquiries regarding this license, contact HdL Business Tax Support Center at (909) 479-2 t 11. B-81 PAVING INC: Thank you for your payment on your City of Redlands Business Tax Certificate. ALL CERTIFICATES MUST BE AVAILABLE FOR INSPECTION UPON REQUEST. If you have questions concerning your business tax certificate, contact the Business Tax Support Center via email at: Redlands@hdlgov.com or by telephone at: (909) 479-2111. Keep this portion for your tax certificate separate in case you need a replacement for any lost, stolen, or destroyed tax certificate. A fee may be charged for a replacement or duplicate tax certificate. This certificate does not entitle the holder to conduct business before complying with all requirements of Redlands Municipal code and other applicable laws, nor to conduct business in a zone where conducting such business violates law. If you have a fixed place of business within the city limits of City of Redlands, please display the Business Tax certificate above in a conspicuous place at the premises. Otherwise, every Business Tax Certificate holder not having a fixed place of business in the City shall keep the Business Tax Certificate upon his or her person, or affixed in plain view upon any cart, vehicle, van or other movable structure or device at all times if required by the Collector. Starting January 1, 2021, Assembly Bill 1607 requires the prevention of gender -based discrimination of business establishments. A full notice is available in English or other languages by going to: https://www.dca.ca.gov/publications/. BUSINESS SUPPORT CENTER 8839 N CEDAR AVE #212 p p FRESNO, CA 93720-1832 o4� B-81 PAVING INC 34428 YUCAIPA BLV❑ STE E 343 YUCAIPA, CA 92399 City of Redlands BUSINESS TAX CERTIFICATE Certificate Number: 08123406 Date of Issue: 06/2912026 Form (Rev. Much 2024) Department of the Treasury Internal Revenue Service Request for Taxpayer Identification Number and Certification Go to www.lrs.gov/FormW9 for instructions and the latest information. Before you begin. For guidance related to the purpose of Form W-9, see Purpose of Form, below. Give form to the requester. Do not send to the IRS. 1 Name of entity/individual, An entry Is required. (For a sole proprietor or disregarded entity, enter the owner's name on line 1, and enter the business/disregarded entity's name on line 2.) B- 81 PAVING INC 2 Business name/disregarded entity name, if different from above. to 3a Check the appropriate box for federal tax classification of the entity/individual whose name Is entered on line 1. Check 4 Exemptions (codes apply only to only one of the following seven boxes. certain entities, not individuals; a Individual/sole proprietor ❑ C corporation ® 3 corporation ❑Partnership El see instructions on page 3): o ❑ LLC. Enter the tax classification (C = C corporation, S = S corporation, P = Partnership) . . . . Exempt payee code (If any) a e Note: Check the "LLC" box above and, in the entry space, enter the appropriate code (C, 3, or P) for the tax Exemption from Foreign Account Tax o 2 classification of the LLC, unless it is a disregarded entity. A disregarded entity should instead check the appropriate box for the tax classification of its owner. Compliance Act (FATCA) reporting c❑ Other (see instructions) code ff any) a c 3b If on line 3a you checked "Partnership" or "Trust estate;' or checked "LLC" and entered "P" as its tax classification, (Applies to accounts maintained 0 and you are providing this form to a partnership, trust, or estate in which you have an ownership interest, check ❑ beneficiaries. See instructions outside the United States.) to this box if you have any foreign partners, owners, or . . . . . . . 8 5 Address (number, street, and apt. or suite no.). See instructions. Requester's name and address (optional) 34428 Yucaipa Blvd Ste. E #343 6 City, state, and ZIP code YUCAIPA CA 92399 7 List account numbers) here (optional) 11111 Taxpayer Identification Number (TIN) Enter your TIN in the appropriate box. The TIN provided must match the name given on line 1 to avoid I locus security numoer backup withholding. For individuals, this is generally your social security number (SSN). However, for a - m - resident alien, sole proprietor, or disregarded entity, see the instructions for Part I, later. For other entities, it is your employer identification number (EIN). If you do not have a number, see How to get a or TIN, later. I c..,.u...,o. ,.,,,. h— Note: If the account is in more than one name, see the instructions for line 1. See also What Name and Number To Give the Requester for guidelines on whose number to enter. 8 2 - 2 6 5 0 0 3 4 Under penalties of perjury, I certify that: 1. The number shown on this form is my correct taxpayer identification number (or I am waiting for a number to be issued to me); and 2. 1 am not subject to backup withholding because (a) I am exempt from backup withholding, or (b) I have not been notified by the Internal Revenue Service (IRS) that I am subject to backup withholding as a result of a failure to report all interest or dividends, or (c) the IRS has notified me that I am no longer subject to backup withholding; and 3. 1 am a U.S. citizen or other U.S. person (defined below); and 4. The FATCA code(s) entered on this form (if any) indicating that I am exempt from FATCA reporting is correct. Certification instructions. You must cross out item 2 above if you have been notified by the IRS that you are currently subject to backup withholding because you have failed to report all interest and dividends on your tax return. For real estate transactions, item 2 does not apply. For mortgage interest paid, acquisition or abandonment of secured property, cancellation of debt, contributions to an individual retirement arrangement (IRA), and, generally, payments other than interest and dividends, you are not required to sign the certification, but you must. provide your correct TIN. See the instructions for Part 11, later. Sign I Signature of � p�a�h bate 01/30/2026 Here U.S. person General Instructions Section references are to the Internal Revenue Code unless otherwise noted. Future developments. For the latest information about developments related to Form W-9 and its instructions, such as legislation enacted after they were published, go to www.irs.gov/FormW9. What's New Line 3a has been modified to clarify how a disregarded entity completes this line. An LLC that is a disregarded entity should check the appropriate box for the tax classification of its owner. Otherwise, it should check the "LLC" box and enter its appropriate tax classification. New line 3b has been added to this form. A flow -through entity is required to complete this line to indicate that it has direct or indirect foreign partners, owners, or beneficiaries when it provides the Form W-9 to another flow -through entity in which it has an ownership interest. This change is intended to provide a flow -through entity with Information regarding the status of its Indirect foreign partners, owners, or beneficiaries, so that it can satisfy any applicable reporting requirements. For example, a partnership that has any indirect foreign partners may be required to complete Schedules K-2 and K-3. See the Partnership Instructions for Schedules K-2 and K-3 (Form 1065). Purpose of Form An individual or entity (Form W-9 requester) who is required to file an information return with the IRS is giving you this form because they Cat. No. 10231X Form W-9 (Rev. 3-2024)