HomeMy WebLinkAboutContracts & Agreements_35-2016 PUBLIC WORKS CONSTRUCTION CONTRACT
This Public Works Construction contract ("Contract") made and entered into this 16th day of
February, 2016, by and between the City of Redlands, a municipal corporation organized and
existing under the laws of the State of California, (hereinafter "City"), and E.L. Engineering
Corp. (hereinafter "Contractor"). City and Contractor are sometimes individually referred to
herein as a"Party" and, together, as the "Parties."
In consideration of the mutual promises contained herein, City and Contractor agree as follows:
1. SCOPE OF WORK: Contractor shall furnish all materials and perform all of the work for the
following: A.K. SMILEY PUBLIC LIBRARY WATERPROOFING PROJECT, complete all
items as required by the Contract Documents (as herein defined) and Specifications for City's
A.K. SMILEY PUBLIC LIBRARY WATERPROOFING PROJECT, Project No. 43051.
2. THE CONTRACT SUM: City shall pay Contractor the sum of$30,943.00 as consideration for
its performance of the Work in accordance with the terms and conditions set forth in the Contract
Documents. Pursuant to Public Contract Code Section 22300, Contractor has the option to deposit
securities with an escrow agent as a substitute for retention of earnings requirement to be withheld
by City pursuant to an escrow agreement as set forth in the Public Contract Code Section 22300.
3. TIME FOR COMPLETION: The Work shall be completed within 45 calendar days from and
after the date of the delivery to Contractor of a written Notice to Proceed by City.
4. LIQUIDATED DAMAGES: Contractor's failure to complete the work within the time allowed
will result in damages being sustained by City. Such damages are, and will continue to be,
impracticable and extremely difficult to determine. Accordingly, Contractor shall pay to City, or
have withheld from monies due to Contractor, the sum of$500 for each consecutive calendar day
in excess of the specified time for completion of Work.
Execution of the Contract shall constitute agreement by City and Contractor that $500 per day is
the estimated damage to City caused by the failure of the Contractor to complete the Work within
the allowed time. Such sum is for liquidated damages and shall not be construed as a penalty, and
may be deducted from payments due Contractor if such delay occurs.
5. CONTRACT DOCUMENTS: This Contract includes all of the Contract documents set forth
herein, to wit; Instructions to Bidders, Contractor's Proposal, Agreement, Performance Bond,
Labor and Material Bond, Plans, General Conditions, General Requirements, Technical
Specifications, and any addenda thereto.
6. ATTORNEYS' FEES: In the event any legal action is commenced to enforce or interpret the
terms or conditions of the Contract documents, the prevailing Party in such action, in addition to
any costs and other relief, shall be entitled to recover its reasonable attorneys' fees, including fees
for use of inhouse counsel by a Party.
CD I
7. RESOLUTION OF CONSTRUCTION CLAIMS: Claims by Contractor in the amount of
$375,000 or less shall be made by Contractor and processed by the City pursuant to the provisions
of Part 3, Chapter 1, Article 1.5 of the Public Contract Code (commencing with Section 20104).
All claims shall be in writing and include the documents necessary to substantiate the claim.
Nothing in subdivision (a) of Public Contract Code Section 20104.2 shall extend the time limit or
supersede the notice requirements provided in this case from fling claims by Contractor.
S. ELIGIBILITY OF CONTRACTOR/SUBCONTRACTOR: Contractor and all of its
subcontractors shall abide by California Public Contract Code, Section 6109, and California
Labor Code Sections 1777.1 and/or 1777.7, and certify that they are not debarred and are eligible
to work on this project.
9. ASSIGNMENT OF AGREEMENT: No assignment by a Party of any rights or interests under
this Contract shall be binding on another Party without the written consent of the Party sought to
be bound.
10. SUCCESSORS AND ASSIGNS: City and Contractor each binds itself and their respective
successors and assigns in respect to all covenants, agreements, and obligations contained in the
Contract Documents.
11. SEVERABILITY: Any provision or part of the Contract documents held to be void or
unenforceable under any law or regulation shall be deemed stricken, and all remaining provisions
shall continue to be valid and binding upon City and Contractor.
CD 2
IN WITNESS WHEREOF, the parties hereto have executed this Agreement the day and year first
written above..
City of Redlands
(SEAL) (0wneA-: w
�m
Y:
City NYAag •,'CitymofRedlands,
County of San Bernardino, California
ATTEST.,,,",,
City Clerk, y of edlands
County of San Bernardino, California (SEAL)
iia.. q
ane of Contr for
By:
Signature of Autlior�'A'ent
Title
Signature of Authorized Agent(if necessary)
Title
Contractor's License No.
CD3
WORKER'S COMPENSATION INSURANCE CERTIFICATION
Description of Contract: City of Redlands
Municipal Utilities & Engineering Department
AX SM11LEY PUBLIC LIBRARY WATERPROOFING
PROJECT,Project No,43051
Labor Code, Section 3700, provides, in part that:
"'Every employer except the State shall secure the payment of compensation in one or more of
the following ways:
(a) By being insured against liability to pay compensation in one or more insurer duly
authorized to write compensation insurance in this State,
(b) By securing from the Director of Industrial Relations a certificate of consent to self-
insure, either as an individual employer, oras one employer in a group of employers which may
be given upon furnishing proof satisfactory to the Director of Industrial Relations of ability to
self-insure and to pay any compensation that may become due to his or her employees.
I am aware of the provisions of Section 3700 of the Labor Code which requires every employer
to be insured against liability for worker's compensation or to undertake self-insurance in
accordance with the provisions of that Code, and I will comply with such provisions before
commencing the performance of the work of this contract, (Labor Code section 1861)
Dated this 16 day of February, 2016.
(CW'act
ign re)
..................... -----------
(Official Title)
(SEAL)
(Labor Code Section 1861 provides that the above certificate must be signed and filed by the
Contractor with the Owner prior to performing the work of the contract.)
CD 4
Bond No.:1001053171
Premium: $727.00
Premium Based On
Final Contract Price
FAITHFUL PERFORMANCE BOND
Whereas.. the City of Redlands("City'), Mate of California, and E. L. Engineering Corp.
(hereinafter des' mated as "Principal") have entered into an agreement dated
-- 02- —16— � _ 2016, ("Agreement") whereby Principal agrees to install and
complete certain public improvements(the"Work"), which said Agreement is identified as A.K.
SMILEY PUBLIC LIBRARY' 'WATERPROOFING PROJECT, Project No. 43051 and is
bereby referred to and made a part hereof; and
Whereas. said Principal is required under the terms of the Agreement to furnish a bond
Cor the faithful performance of the Agreement, now, therefore, we, the Principal and
American Contractors Indemnity Company, as Surety, are held and firmly bound unto the City in the penal
sum of Thirty Thousand Nine Hundred Forty 'Three Dollars (S 30,94-31) lawful money of the
United States, for the payment of which sura we bind ourselves, and our heirs, successors,
executors and administrators,jointly and severally, firmly by these presents.
The condition of this obligation is such that if the above bounded Principal, his or its
heirs, executors, administrators, successors or assigns, shall in all thinks stand to and abide hy,
and well. and truly keep and perform the covenants, conditions and provisions in the Agreement
and any alteration thereof made as thexein provided, on his or its part, to be kept and performed
at the time arid in the manner therein specified, and in all respects according,to their true intent
and meaning, and shall faithfully fulfill the one-year guarantee of all materials and workmanship,
and shall defend,indernnifyv and save harmless the City and its elected officials,officers,agents
and employees,as therein stipulated, then this obligation shall become null and void.otherwise.it
shall be and remain in full force and effect.
As a }Hart of the obligation secured hereby andin addition to the face amount specified
therefor, there shall be included costs and reasonable i::xpenses and tees, including reasouablc
avorneys' fees, incurred by the City in successlully enforcing such obligations,all to be taxed as
costs and included in the judgment rendered.
As a condition precedent to the satisfactory completion of the Agreement, the above
obligation shall hold good for a period of one (1) year or longer if required by the Agreement
after the acceptance of the work by the City, during which time if the Principal shall fail to make
full, complete, and satisfactory repair and replacements and totally protect the City from loss or
damage made evident during this period from the date of completion of the Work, and resulting
from or caused by defective materials or faulty workmanship, the above obligation in penal sum
thereof shall remain in full force and effect, The obligations of Surety hereunder shall continue
so long as any obligation of the Principal remains.
Whenever the Principal shall be, and is declared by the City to be, in default under the
Agreement, the City hawing performed the City obligations thereunder. the Surety shall promptly
remedy the default,or shall promptly, at the City's option;
I. Connpl.etc the Agreenic it in accordance with its terms and conditions; or
2. Obtain a bid or bids for completing the Agreement in accordance with its terms
and conditions, and upon determination by Surety of the lowest responsive and responsible
bidder, arrange for a contract between such bidder and the City, and make available tis work
progresses sufficient funds to pay the cost of completion of tine �Vurk less the balance of the
CD 5
Agreement price, bUt 110t eXCe(�k5ug, ilicluding other car sis Arld dainages for Which Surety I-1-my be
5able hereundor, the,aj,nount set forth above, '['no, term -bakmoc of the Agreement prcc,"tIs used
in this j.1aragraph, Shall Ineall thC 101al VIOLIM payable to the Principal by t,he City ander 1,110
ikgrCerticni and any mo&ficafions thereto, less the UMOUnt rcvim�sh -opcHy paid by tile ("0
to the Princip"IL , P y PI
SU-rctv expressly azurees that the City may re' 'Iclor or n""I
subcontctor Which
'�ect any Conti,,
may be 1)roposed by Surety in fulfillment of its obljj-;ations in tlae
Principal, evem of detault by the
Surety shal'i 1101 utilize tile Principal ill comptck;1g, the Agreemen'r nor shall Surety accept
,i, bid ftom The Principal tsar completion of the Work Tthe City, whea declaring the Pi incipal in
JCfitUlt, rwiifks Surety of the (JrY'S O�jection to the Princlpd's further participation i.n the
c'ompletion of the: Wtirk,
No ri-lit of action shall accrue on the bond to or f0lthe Use c)f`unV person or corporatiort
cither than the City named herein or thle successors or as'sig'ns ot.,the City, Any suiL under this
bond MILIst be instituted "Ithin the applicable statt)te of[injitatitaj,,s the triol'..
The said Surcty, for value mceived. hereby stipulzies arid agren, LhaL no change,
extension of time, allemlion or addition to the Terms of the Allp'een-iew or to the work to he
performed thereunder or the SI)ecifications accompanying the mme shall in any way affect ats
obligations on, this boad,and it does hereby waive notice otany sucli chjr, eN te,e. sio'n o'
g -I 11
tirnQ,
alteration or addiJon m the tems of the Agreement or to the Work or to the spocifications,
No final settlement between the City and the Principal shatabridge the right: of anv
heneFiciary 'teener nde-,r whow eittim may be unsatisried.
The Principal and SLWety apI'Ce that if the City is required (o engage the scrvice�,�, of any
twornev in CotIrJeCtion �Ond, cic sl'O pay Ifie City's masonable
with the enforcenient of flits 11
attrot'nt�v5' les hicurred. NN-'th 01'%Vithout suit,in addition to the above stazaae
In %&Yitm.ss whcrcoE thin instrument has been duk elves uted btfiv Principal and Surcty abovc
nanied,on February 16 2016.
(SEAL) (SEAL)
E.L. Engineering Corp.
American Contractors Mernnfty Company
R.'oqrae
BY:
4
atricia tt&r-Fe'-y-h
Ad -ess601 S.,Figueroa!
h Floor
(Se.d and Notariii Avkco%v[edgCuIQAI of Sorety) —L.os.Ange'Ies, CA 90017
Tclephone: 310 )649-0990
(,J)6
CALIFORNIA ALL-PURPOSE C L T CIVIL CODE§1189
A notary public or other officer cornpleting this certificate verifies only the identity of the individual who signed the
document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document.
State of California )
County of Los.Angeles
On FEB I e 911IR before me, Elisabete Salazar Notary Pudic
bate dere Insert Name and Title of the Officer
personally appeared Patricia Zenizo
Name(s)of Signer(s)
who proved to me on the basis of satisfactory evidence to be the person(s) whose names) is/aY
subscribed to the within instrument and acknowledged to me that she/tvi y executed the same in
Ufa/her/thd r authorized capacityogs),and that by*/her/tb#jr sig nature( )on the instrument the person(j),
or the entity upon behalf of which the person(s)acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws
of the State of California that the foregoing paragraph
is true and correct,
=#2122207
otaryLos11c WITNESS my hand and official seal.
omm
Commissilon
zw
Notary Public-Call ��ty
hl les les SrgnaLos ur nature o Notary Public
Place Notary Seal,Above
OP77ONAL
Though this section is optional, completing this information can anter alteration of the document or
fraudulent reattachment of this form to an unintended document.
Description of Attached Document
Title or Type of Document: Document Date: _
Number of Pages: Signer(s) Other Than Named Above:
Capacity(lies) Claimed by Signer(s)
Signer's Name: Signer's Name:
0 Corporate Officer -- Title(s): F'�Corporate Officer — Title(s):
�']Partner W: Limited L]General ID Partner -- l:l Limited 0 General
F1 Individual R1 Attorney in Fact El Individual I.--.i Attorney in Fact
i Trustee Cl Guardian or Conservator J Trustee 01 Guardian or Conservator
,: Other: f:! Other:
Signer Is Representing: Signer is Representing: -
@2014 National Notary Association •wwww.NationaiNotary.org.1-600-US NOTARY(1-800-876-6827) !tern#6007
Bond No..-1001053171
Premium Included on
Performance Bond
LABOR AND MATERIAL BOND
whereas. the C itw Council tit'11w Cilvol- Rcdfands, State J:A_ E.n<,hjeQj-irlg Corp.
(hereinafiter designated as "Principal") have entered into ata agreetwient (Ific v,,fierehy
Priacipal agrees to in.smil and cor iplQte certain dcsignated public irnprovenjeras Ctljc 'which said
2016, and idClltifie(] as A. K. S.NI11,J*Y KIBLIC LIBRARY,
WATER PROOFING PROJECT, Project No.43051 is hcrQby rcl7w-red to and wadre'l dart'hcrwr and
whereas, under the tarlivs of the Agrewrwln, Principril is required beforc, coamlGilding the
pel fujllaawof[lie work,10 file?as goodand qIfficient Labor and Mztcriaf bond aviffi the City of Redlands
W iCcUre,the cl,tinls to whic.li rcfelvnce is ITIU]c ire "f 3 (colllfnellcilq,' with Section 9y 50) of'Part 6 of
I)Msion 4 of the Civil Code ofilit-State ofCalifornin.
Now, therefore, slid Principal wid the undcriigned as corporate SUrCty, ZIN 11CId timely bound unto
the City and all contractom, SUIX0111raCtOrS, laborers, malerial Inca an(] Oiler persons ot-111,31oved ill tllQ
perfi)rinanix oC the Agrcevlent and referred to in the afbres,id Cotic c)f'Ci%/i I in the SLIM Of
Thirly ThOUsand Nine'-i-fundrQd I-orly I'firce Doilars 30,943)for materials furnished or labor there era of
any kind, or foramounts due under the U 111SLIT-4licc Act with respuct to tiiwh work or kibor,
that said surety kvill pay the sarlic in ,in.Illlkltlllt not
0woMing the amount hereimibwve scrforth. and:11so
m Case quit is brought upon. Chis bond, lVill PaY, i)) Otdditi011 to tier, ft= aaiarcaaaaat thereof", costs and
reasonable exposes anit fees, including reasonabiQ attoslicysfees. incurrod by the City iii sliccessi'lilly
-11forcing ,,tach obligatiom W Ile awarded steer[ fiwd by the court:, and to be UM as casts and to be
included in-lie jtld�jnerit therela rcaa<.ent d,
hcr6y cxpressly stipulatcd and agreed fliai this bund shail iastire to the benefiE cfally and ,all
parsons.companies arld corporations untitled to file clainl�s undal-Titte 1 tColrinwrlein
with Section 9550)
of 6 of'Divivjon 4 of the t..full Code,so as to give at right ofactioll to them oll.6air assiv'ris in anV
brought upon this,bond,
Sbotdd rhe condition of thin, frond he fully perforniod., [hurt this obligation shall becortle null and
void,otherwise, it shall fat:and reintifir in fiflt force and effect.
The surely 4errehv stipulates and ap-l-cks that.it(,) change, Mensioll of lime, adtcr2&cn or additioa to
the wmis of the Aarcellient ol, the Spel.4ficafions acemnpanying the same shall ill any manner affect its
obligations on this holld.and it does hereby waive notice cal-any SOO)&M19c, ilteration
oraddition.
In willies's whereof,0& illstf-Unlell't lrols been duly o%wilcd 1ty the Principal and soliviyabove narned,
Fattruary-,1-6-- 2016.
E.L. Enqineering Corp. American Contractors Indemnity Company
(C Oil �rol
"
By�
Pat icia Zenizo (Si,,nalul��
ttoiney-i r-Fa'
Add g6IS. Fiqueroa* tMoor e`
(Seal and'�,C'tarilrl
-1,o-s-AMgjqiqs, QA.9001 7
Telephone: ( 310 ) 49_Q9
9
0
CD 7
CALIFORNIA ALL-PURPOSE MIL CODE § 1159
A notary public or other officer completing thus certificate verifies only the identity of the individual who signed the
document to which this certificate is attached, and net the truthfulness, accuracy,or validity of that document.
State of California
County of-,,s oac f int, (A t.m)u
On before me,
Date dere Insert Name and Title of the Officer �
personally appeared ........__. ,a. � "N ',
Narrme(s) of Signer(s)
who proved to me on the basis of satisfactory evidence to be the persona s,)-whose narne�&} Ware-
subscribed
s/ __subscribed to the within instrument ,and acknowledged to me that he%he/they executed the same in
his/,hers, eir-816thori zed capacity0es), and that by his/her/their si natur*yon the instrument the persons
or,the entity upon behalf of wNch the person„( y°acted„ executed the instrument..
I certify under PENALTY OF PERJURY under the laws
of the State of California that the foregoing paragraph
Is true and correct.
HEATHER ANN MCGINNIS
ommil6i(m# WITNESS my hand and official seal.
,,.
Notary puii m Ce#itnrnle t
San Bernardino Count
. _...
Cern. fres Oct 2 „2018 SignatureQ
Signature of Notary Public
Place Notary Seal Above
_ OPTIONAL
Though this section is optional, completing this information can deter alteration of the document or
fraudulent reattachment of this form to an unintended document,
Description of Attached Document
Title or Type of Document: Document Cate:
Nlumber of Pages: Signer(s) Other Than Named Above: _
a ac (ies) Claimed by ii n:er( )
Signer's Dame: Signer's Name:
El Corporate Officer — Title(s): _._ � I_-1 Corporate Officer Title(s):
Partner -- 1__1 Limited 0 General ..[ Partner — [7 Limited 1:1 Oenerai _
F I Individual R Attorney in Fact 1 Individual L J Attorney in Fact
LI Trustee -:i Guardian or Conservator 1:::]Trustee I._1 Guardian or Conservator
Other; I ! Other:
Signer Is Representing: Signer Is Representing: _...._.
@2614 National Notary Association w www.NationalNotary.org 1-800-US NOTARY(1-800-876-6827) Item #5907
CALIFORNIA LL- P S C L E T CIVIL CODE§ 1189
A notary public or other officer completing this certificate verifies oniy the identity of the individual who signed the
document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document.
State of California }
OnLos Angeles
)
County 1821 o before me,� lisabete Salazar, Notary Public
Date Here Insert Name and Title of the Officer
personally appeared Patricia Zenizo
Name(s)of Signer(s)
who proved to me on the basis of satisfactory evidence to be the person(s) whose name() is/al'r`
subscribed to the within instrument and acknowledged to me that l /she/tH y executed the ;arae in
Wher/tMYf%r authorized capacity9gs),and that by Wp/her/tb#jr signature(p )on the instrument the person(p),
or the entity upon behalf of which the person(s)acted,executed the instrument.
I certify under PENALTY OF PERJURY under the lavas
of the Mate of California that the foregoing paragraph
Fi.i, A'iILTE AirATAft
is true and correct.
C�amIniSlo�n 21 ����T
m�.. WITNESS my hand and official seal.
Notary public 0al'al'rarn a
.
Los Anelas 0lytg
ounty •
Comm. Ex irea a 4, Signature
Signature of Notary Public
E
6
Place Notary Seal Above
OPTIONAL
Though this section is optional, completing this information can deter alteration of the document or
fraudulent reattachment of this form to an unintended document.
Description of Attached Document
P `title or Type of Document: Document Date:.
Number of Pages: Signer(s) Other Than Named Above:
Capacitylles) Claimed by Signer(s)
Signer's Name: Signer's Name.
1-i Corporate Officer — Title(s):_._ [...i Corporate Officer -- Title(s):
L.]Partner :a Limited !._l general 0 Partner -- F] Limited l_J general
F1 Individual K Attorney in Fact i_i Individual D Attorney in Fact
i I Trustee D guardian or Conservator F Trustee [='guardian or Conservator
]Other., I__1 Other:
Signer Is Representing: Signer Is Representing:
02014 National Notary Association www.NationaiNotary.org •1-800-US NOTARY(1-800-875-5827) Item#5907
POWER OF ATTORNEY
AMERICAN CONTRACTORS INDEMNITY COMPANY TEXAS BONDING COMPANY
UNITED STATES SURETY COMPANY U.S.SPECIALTY INSURANCE COMPANY
KNOW ALL MEN BY THESE PRESENTS: That American Contractors Indemnity Company, a California corporation, Texas
Bonding Company, an assumed name of American Contractors Indemnity Company, United States Surety Company, a M aryland
corporation and U.S. Specialty Insurance Company, a Texas corporation(collectively,the"Companies"), do by these presents make,
constitute and appoint:
Patricia Zenizo,Elisabete Salazar or Pietro Micciche of Los Angeles California
its true and lawful Attorney(s)-in-fact, each in their separate capacity if more than one is named above, with full power and authority
hereby conferred in its name,place and stead,to execute,acknowledge and deliver any and all bonds, recognizances,undertakings
or other instruments or contracts of suretyship to include riders, amendments, and consents of surety, providing the bond
penalty does not exceed *****Three Million***** Dollars ($• **3,000,000.00**
This Power of Attorney shall expire without further action on December 20,201.7. This Power of Attorney is granted under and by
authority of the following resolutions adopted by the Boards of Directors of the Companies:
Be it Resolved,that the President,any Vice-President,any Assistant Vice-President,any Secretary or any Assistant Secretary shall be and is hereby vested with full
power and authority to appoint any one or more suitable persons as Attorney(s)-in-Fact to represent and act for and on behalf of the Company subject to the following
provisions:
Arroruey-in-Fact may be given full power and authority for and in the name of and on behalf of the Company,to execute,acknowledge and deliver,any and all bonds,
recognizances, contracts, agreements or indemnity and other conditional or obligatory undertakings, including any and all consents for the release of retained
percentages and/or final estimates on engineering and construction contracts,and any and all notices and documents canceling or terminating the Company's liability
thereunder,and any such instruments so executed by any such Attorney-in-Fact shall be binding upon the Company as if signed by the President and sealed and effected
by the Corporate Secretary.
Be.ir Resolved that the signature of any authorized officer and seal of the Company heretofore or hereafter affixed to any power of attorney or any certificate relating
thereto byfacslmile,and any power of attorney or certificate bearing facsimile signature or facsimile seal shall be-valid and binding upon the Company with respect to
any bond br.undertaking.to which it is attached.
IN WITNESS WHEREOF,The Companies have caused this instrument to be signed and their corporate seals to be hereto affixed,this
1st day of December,2014.
AMERICAN CONTRACTORS INDEMNITY COMPANY TEXAS BONDING COMPANY
Corporate Seals UNITED STATES SURETY COMPANY U.S.SPECIALTY INSURANCE COMPANY
,oaSp0.CTORs"', ,,a�S.SURFTY�
B t
_W.,; .Z_ y•
=x �.
Daniel P.A uilar Vice President
}�r�'�iiFOHN�pa``���. '��iirruru nu+«apo" ��''•9TF OFi10�P�`�``` unrninnua``\".
Fotary-public or-other officer completing this certificate verifies only the identity of the individual who signed the
cument to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document..
State of California
County of Los Angeles SS:
On this 1 st day of December,2014, before me,Maria G.Rodriguez-Wong,a notary public, personally appeared Dan P.Aguilar,Vice President of American
Contractors Indemnity Company,Texas Bonding Company,United States Surety Company and U.S.Specialty Insurance Company who proved to me on
the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that he.executed the same in
his authorized capacity,and that by his signature on the instrument the person,or the entity upon behalf of which the person acted,executed the instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.
WITNESS my hand and official seal.
MARIA G.RODRIGUEZ-WQN_G
Commission#t 2049711
Signature (Seal) i ,� Notary Public:California z
' Angeles County
M Comm.Ex fres Dec 2D,2D17 W
1,Michael Chalekson,Assistant Secretary of American Contractors Indemnity Company,Texas Bonding Company,United States Surety Company
and U.S.Specialty Insurance Company,do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney,executed by
said Companies,which is still in full force and effect;furthermore,the resolutions of the Boards of Directors,set out in the Power of Attorney are in
full force and effect.
In Witness Whereof I have hereuntoset my hand and affixed the seals of said Companies at Los Angeles,California this l U t-h day
,
Corporate Seals .°zA. ......... . . s u,��., "NDINo ai
��su
�31f
Bond No. l eA,e
Michael Chalekson,Assistant Secretary
$ Y „yr
A enc 1Vo. 3057 �',�qu oR+;v *,,,.•, m,.°F.„e,a° „